Compensation for Overtime 9.5.1 All overtime hours, except those overtime hours exceeding twelve (12) hours in one day, shall be compensated at a rate of pay equal to time and one-half the regular rate of pay of the employee. Those overtime hours exceeding twelve (12) in one day shall be compensated at a rate of pay equal to two times the regular pay of the employee.
Compensation for Delay The time allowed for carrying out the work, as entered in the tender form, shall be strictly observed by the contractor and shall be deemed to be the essence of the contract and shall be reckoned from the fifteenth day after the date on which the order to commence the work is issued to the contractor, for a work where completion is up to 6 months For works, for which the completion period is beyond six months: - The period will be reckoned from the thirtieth day after the date on which the order to commence the work is issued to contractor .The work shall throughout the stipulated period of contract be proceeded with all due diligence, keeping in view that time is the essence of the contract. The contractor shall be bound in all cases, in which the time allowed for any work exceeds one month, to complete 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed, 3/8th of the work before 1/2 of such time has elapsed and 3/4th of the work before 3/4th of such time has elapsed. In the event of the contractor failing to comply with the above conditions, the Commissionor/CMO shall levy on the contractor, as compensation an amount equal to: 0.5% (zero point five percent) of the value of work (contract sum) for each week of delay, provided that the total amount of compensation under this provision of the clause shall be limited to 6% (six percent) of the value of work. (Contract sum) Provided further that if the contractor fails to achieve 30% (thirty percent) progress in half (1/2) of original or validly extended period of time (reference clause 5 below) the contract shall stand terminated after due notice to the contractor and his contract finallised, with xxxxxxx money and or security deposit forfeited and levy of further compensation at the rate of 10% of the balance amount of contract left incomplete, either from the bill, and or from available security/performance guarantee or shall be recovered as "Arrears of land revenue". The decision of the Competent Authority in the matter of grant of extension of time only (reference clause 5 below) shall be final, binding and conclusive. But he has no right to change either the rate of compensation or reduce and or condone the period of delay- once such an order is passed by him (on each extension application of the contractor). It shall not be open for a revision. Where the Commissioner/CMO or Competent Authority or Commissioner/CMO as the case may decides that the contractor is liable to pay compensation for not giving proportionate progress under this clause and the compensation is recommended during the intermediate period, such compensation shall be kept in deposit and shall be refunded if the contractor subsequently makes up the progress for the lost time, within the period of contract including extension granted, if any. failing which the compensation amount shall be forfeited in favour of the Nagar Xxxxx/Nagar Palika Parishad/Nagar Panchayat Clause 3 -:Action when the work is left incomplete abandoned or delayed beyond the time limit permitted by the Commissioner/CMO or Competent Authority: -
Termination Compensation Termination Compensation equal to two (2) times the Executive's Base Period Income shall be paid to the Executive in a single sum payment in cash on the thirtieth (30th) business day after the later of (a) the Control Change Date and (b) the date of the Executive's employment termination; provided that if at the time of the Executive's termination of employment the Executive is a Specified Employee, then payment of the Termination Compensation to the Executive shall be made on the first day of the seventh (7th) month following the Executive's employment termination.
Final Compensation Final Compensation for an employee, who is employed by the State for the first time and becomes a member of CalPERS prior to January 15, 2011, is based on the highest average monthly pay rate during twelve (12) consecutive months of employment. Final Compensation for an employee, who is employed by the State for the first time and becomes a member of CalPERS on or after January 15, 2011, is based on the highest average monthly pay rate during thirty-six (36) consecutive months of employment.
Total Compensation Contractor shall include Total Compensation in XXX for each of its five most highly compensated Executives for the preceding fiscal year if:
Compensation for Unused Sick Leave 1. Employees who enter County service after July 1, 1979, shall not be eligible for compensation for any of their unused sick leave credits.
Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.
Payment of Compensation Consultant shall submit to City a monthly itemized statement which indicates work completed and hours of Services rendered by Consultant. The statement shall describe the amount of Services and supplies provided since the initial commencement date, or since the start of the subsequent billing periods, as appropriate, through the date of the statement. City shall, within 30 days of receiving such statement, review the statement and pay all approved charges thereon.
