Completion; Encroachment Sample Clauses

Completion; Encroachment. All Improvements necessary for the efficient use and operation of the Premises, including, without limitation, all Improvements which were included for purposes of determining the appraised value of the Property in the Appraisal, have been completed and none of said Improvements lie outside the boundaries and building restriction lines of the Premises. Except as set forth in the title insurance policy insuring the lien of this Security Instrument, no improvements on adjoining properties encroach upon the Premises.
Sample 1Sample 2Sample 3See All (11)
AutoNDA by SimpleDocs
Completion; Encroachment. All Improvements necessary for the efficient use and operation of the Premises, including, without limitation, all Improvements which were included for purposes of determining the appraised value of the Property in the Appraisal, have been completed and, except as disclosed on the survey of the Premises delivered to Lender in connection with the origination of the Loan, none of said Improvements lie outside the boundaries and building restriction lines of the Premises. Except as disclosed on the survey of the Premises delivered to Lender in connection with the origination of the Loan and as set forth in the title insurance policy insuring the lien of this Security Instrument, no improvements on adjoining properties encroach upon the Premises.
Sample 1Sample 2Sample 3See All (9)
Completion; Encroachment. All Improvements necessary for the efficient use and operation of the Premises have been completed and, other than as disclosed in the surveys of the Property delivered to Lender by Borrower in connection with the origination of the Loan, none of said Improvements lie outside the boundaries and building restriction lines of the Premises. Except as set forth in the title insurance policy insuring the lien of this Security Instrument, no improvements on adjoining properties encroach upon the Premises.
Sample 1Sample 2Sample 3See All (5)
Completion; Encroachment. All Improvements necessary for the efficient use and operation of the Projects have been completed and, except as shown on the surveys, none of said Improvements lie outside the boundaries and building restriction lines applicable to any Project. Except as set forth in each title insurance policy insuring the lien of each Mortgage, no improvements on adjoining properties encroach upon any Project.
Sample 1Sample 2
Completion; Encroachment. All Improvements necessary for the efficient use and operation of the Premises have been completed and, except as set forth in the title insurance policy insuring the lien of this Security Instrument or the survey delivered to Lender in connection with the origination of the Loan, none of said Improvements lie outside the boundaries and building restriction lines of the Premises. Except as set forth in the title insurance policy insuring the lien of this Security Instrument, no improvements on adjoining properties encroach upon the Premises.
Sample 1
Completion; Encroachment. All Improvements necessary for the efficient use and operation of the Premises, have been completed and none of said Improvements lie outside the boundaries and building restriction lines of the Premises. Except as set forth in the title insurance policy insuring the lien of this Mortgage, no improvements on adjoining properties encroach upon the Premises.
Sample 1
Completion; Encroachment. All Improvements necessary for the efficient use and operation of the Premises, including, without limitation, all Improvements which were included for purposes of determining the appraised value of the Trust Property in the Appraisal have been completed and none of said Improvements lie outside the boundaries and building restriction lines of the Premises. Except as set forth in the title insurance policy insuring the lien of this Deed of Trust, no improvements on adjoining properties encroach upon the Premises.
Sample 1
AutoNDA by SimpleDocs
Completion; Encroachment. All Improvements necessary for the efficient use and operation of the Projects, including, without limitation, all Improvements which were included for purposes of determining the appraised value of each Project in the Appraisal(s), have been completed and, except as shown on the surveys, none of said Improvements lie outside the boundaries and building restriction lines applicable to any Project. Except as set forth in each title insurance policy insuring the lien of each Mortgage, no improvements on adjoining properties encroach upon any Project.
Sample 1
Completion; Encroachment. To Borrower's knowledge, except as set forth in the survey and property condition of engineer's report for the Property delivered to Lender in connection with the origination of the Loan, all Improvements necessary for the efficient use and operation of the Premises, including, without limitation, all Improvements which were included for purposes of determining the appraised value of the Property in the Appraisal, have been completed and none of said Improvements lie outside the boundaries and building restriction lines of the Premises. Except as set forth in the title insurance policy insuring the lien of the Mortgage, no improvements on adjoining properties encroach upon the Premises.
Sample 1

Related to Completion; Encroachment

  • Encroachments If any of the Leased Improvements on any Leased Property shall, at any time, encroach upon any property, street or right-of-way adjacent to such Leased Property, then, promptly upon the request of Lessor or at the behest of any person affected by any such encroachment, Tenant shall, at its expense, subject to its right to contest the existence of any encroachment and, in such case, in the event of any adverse final determination, either (i) obtain valid and effective waivers or settlements of all claims, liabilities and damages resulting from each such encroachment, whether the same shall affect Lessor or Tenant, or (ii) make such changes in the Leased Improvements, and take such other actions, as Tenant, in good faith exercise of its judgment deems reasonably practicable, to remove such encroachment, including, if necessary, the alteration of any of the Leased Improvements, and in any event take all such actions as may be necessary in order to be able to continue the operation of the Leased Improvements for the Primary Intended Use substantially in the manner and to the extent the Leased Improvements were operated prior to the assertion of such encroachment. Any such alteration shall be made in conformity with the applicable requirements of ARTICLE X. Tenant’s obligations under this Section 9.2 shall be in addition to and shall in no way discharge or diminish any obligation of any insurer under any policy of title or other insurance and Tenant shall not be entitled to a credit for any sums recovered by Lessor under any such policy of title or other insurance.

  • No Encroachments To Seller’s knowledge based solely on surveys obtained in connection with origination and the lender’s Title Policy (or, if such policy is not yet issued, a pro forma title policy, a preliminary title policy with escrow instructions or a “marked up” commitment) obtained in connection with the origination of each Mortgage Loan, all material improvements that were included for the purpose of determining the appraised value of the related Mortgaged Property at the time of the origination of such Mortgage Loan are within the boundaries of the related Mortgaged Property, except encroachments that do not materially and adversely affect the value or current use of such Mortgaged Property or for which insurance or endorsements were obtained under the Title Policy. No improvements on adjoining parcels encroach onto the related Mortgaged Property except for encroachments that do not materially and adversely affect the value or current use of such Mortgaged Property or for which insurance or endorsements were obtained under the Title Policy. No improvements encroach upon any easements except for encroachments the removal of which would not materially and adversely affect the value or current use of such Mortgaged Property or for which insurance or endorsements obtained with respect to the Title Policy.

  • Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.

  • The Property The term “Property” shall also include the following:

  • Location of Improvements; No Encroachments All improvements which were considered in determining the Appraised Value of the Mortgaged Property lay wholly within the boundaries and building restriction lines of the Mortgaged Property, and no improvements on adjoining properties encroach upon the Mortgaged Property. No improvement located on or being part of the Mortgaged Property is in violation of any applicable zoning law or regulation;

  • Encroachments, Restrictions, Etc Lessor represents and warrants that the Leased Improvements do not materially encroach upon any property, street or right-of-way adjacent to the Leased Property, or violate the agreements or conditions contained in any lawful restrictive covenant or other agreement affecting the Leased Property, or any part thereof, or impair the rights of others under any easement or right-of-way to which the Leased Property is subject. Except to the extent that such representation and warranty is breached by Lessor, if any of the Leased Improvements, at any time hereafter, materially encroach upon any property, street or right-of-way adjacent to the Leased Property, or violate the agreements or conditions contained in any lawful restrictive covenant or other agreement affecting the Leased Property, or any part thereof, or impair the rights of others under any easement or right-of-way to which the Leased Property is subject, then promptly upon the request of Lessor or at the behest of any Person affected by any such encroachment, violation or impairment, Lessee shall, at its expense, subject to its right to contest the existence of any encroachment, violation or impairment and in such case, in the event of an adverse final determination, either (a) obtain valid and effective waivers or settlements of all claims, liabilities and damages resulting from each such encroachment, violation or impairment, whether the same shall affect Lessor or Lessee or (b) make such changes in the Leased Improvements, and take such other actions, as Lessee in the good faith exercise of its judgment deems reasonably practicable to remove such encroachment, and to end such violation or impairment, including, if necessary, the alteration of any of the Leased Improvements, and in any event take all such actions as may be necessary in order to be able to continue the operation of the Leased Improvements for the Primary Intended Use substantially in the manner and to the extent the Leased Improvements were operated prior to the assertion of such violation, impairment or encroachment. Any such alteration shall be made in conformity with the applicable requirements of Article 10. Lessee’s obligations under this Section 9.2 shall be in addition to and shall in no way discharge or diminish any obligation of any insurer under any policy of title or other insurance held by Lessor.

  • Project The Land and all improvements thereon, including the Building, the Parking Facilities, and all Common Areas.

  • Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.

  • Landlord’s Title Landlord’s title is and always shall be paramount to the title of Tenant. Nothing herein contained shall empower Tenant to do any act which can, shall or may encumber the title of Landlord.

  • Landlord Improvements Landlord shall substantially complete the Landlord Improvements prior to Tenant’s taking occupancy of the Expansion Space. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by May 1, 2014. “Substantial Completion” shall mean the Landlord Improvements have been constructed in material accordance with the above referenced drawing, save and except for minor “punch list” items such that Tenant can occupy the Expansion Space and conduct its business, Landlord has obtained all approvals from the applicable governmental authorities for the legal occupancy of the Expansion Space and Landlord has delivered possession of the Expansion Space to Tenant in the required condition, which date is currently anticipated to be May 1, 2014. Upon Substantial Completion, Landlord shall deliver possession of the Expansion Space to Tenant in good, vacant, broom clean condition, with all building systems in good working order and the roof water-tight, and in compliance with all laws applicable to Landlord or Tenant. In the event that construction of the Landlord Improvements is not substantially completed by May 1, 2014, then the Expansion Space Commencement Date shall be automatically amended to be that date the Expansion Space is delivered to Tenant with the Landlord Improvements substantially complete. Upon Substantial Completion of the Landlord Improvements, Landlord shall give Tenant (i) written notice (“Notice of Completion”) that the Expansion Space are ready for occupancy. Within seven (7) days following Landlord’s giving of the Notice of Completion, Landlord and Tenant shall meet at a mutually convenient time to perform a walk-through of the Expansion Space to inspect the Landlord Improvements and to prepare a punch list of minor items needing correction and Landlord shall promptly cause such items to be corrected.

Time is Money Join Law Insider Premium to draft better contracts faster.