Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
Maintenance Repairs and Alterations 6.01 Tenant's Obligations to Repair ------------------------------ Tenant shall at its sole cost and expense, maintain in clean and safe condition, and make all repairs and replacements to the Premises and every part thereof, structural and non-structural, so as to keep, maintain and preserve the Premises in first class condition and repair, including, without limitation, the roof, the foundation, the heating, ventilation and air conditioning system ("HVAC"), elevators, if any, all plumbing and sewage facilities, fire sprinklers, electrical and lighting facilities, systems, appliances, and equipment within the Premises, fixtures, interior and exterior walls, floors, ceilings, windows, doors, entrances, all interior and exterior glass (including plate glass), and skylights located within the Premises, and all sidewalks, service areas, parking areas and landscaping comprising part of the Premises. All repairs and replacements required to be made by Tenant shall be made promptly with new materials of like kind and quality to those used in the original construction of the Premises. If the repair or replacement work affects the structural parts of the Premises, or if the estimated cost of any item or repair or replacement exceeds $10,000, then Tenant shall first obtain Landlord's written approval of the scope of work, plans therefor, and materials to be used. Any such work shall be performed by Landlord's contractor or by such contractor as Tenant may choose from an approved list to be submitted by Landlord. Landlord shall have the right to make any repairs or replacements which are not promptly made by Tenant and charge Tenant, as Additional Rent, for the cost thereof together with interest thereon at the Agreed Rate from the date of payment thereof by Landlord. Without limiting any of Tenant's obligations hereunder, during the Lease Term Tenant, at its expense, shall obtain and keep in force an HVAC service contract and a roof maintenance program satisfactory to Landlord. Tenant hereby waives the benefit of any statute now or hereafter in effect which would otherwise afford Tenant the right to make repairs at Landlord's expense or to terminate this Lease because of Landlord's failure to keep the Premises in good condition, order and repair. Tenant specifically waives all rights it may have under Sections 1932(1), 1941 and 1942 of the California Civil Code, and any similar or successor statute or law. Notwithstanding anything to the contrary contained herein, Landlord shall exercise its rights under any guaranties or warranties relating to the original construction of the Premises if the need to make repairs arises due to a defect therein; provided, however, Landlord shall not have any liability or be required to expend any funds if such guaranties or warranties are not honored by the makers hereof.
Tenant Repairs To repair, maintain and keep the Leased Premises and all trade fixtures and improvements therein in good and substantial repair subject only to defects in construction of the structural members of the Building, reasonable wear and tear and damage by fire, lightning and tempest or other casualty against which the Landlord is insured (herein collectively referred to as "Tenant Repair Exceptions"); and that the Landlord may enter and view state of repair and that the Tenant will repair according to notice in writing, except for Tenant Repair Exceptions and that the Tenant will leave the Leased Premises in good repair, except for Tenant Repair Exceptions. Notwithstanding anything hereinbefore contained, the Landlord may in any event make repairs to the Leased Premises without notice if such repairs are, in the Landlord's opinion, necessary for the protection of the Building and the Tenant covenants and agrees with the Landlord that if the Landlord exercises any such option to repair, the Tenant will pay to the Landlord together with the next instalment of Monthly Rent which shall become due after the exercise of such option all sums which the Landlord shall have expended in making such repairs and that such sums, if not so paid within such time, shall be recoverable from the Tenant as rent in arrears. Provided further that in the event that the Landlord from time to time makes any repairs as hereinbefore provided, the Tenant shall not be deemed to have been relieved from the obligation to repair and leave the Leased Premises in a good state of repair.
Required Repair Funds 70 7.1.1 Deposits .................................................... 70 7.1.2 Release of Required Repair Funds ............................ 70 Section 7.2 Tax and Insurance Escrow Fund ............................ 71 Section 7.3 Replacements and Replacement Reserve .................... 72 7.3.1
Required Repairs (a) Borrower shall make the repairs and improvements to each Individual Property set forth on Schedule 9.1 and as more particularly described in the Property Condition Report prepared in connection with the closing of the Loan (such repairs hereinafter referred to as “Required Repairs”). Borrower shall complete the Required Repairs in a good and workmanlike manner on or before the date that is twelve (12) months from the Closing Date or within such other time frame for completion specifically set forth on Schedule 9.1.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Cost of Tenant Improvements Unless specified otherwise herein, Landlord shall bear and pay the cost of the Tenant Improvements (which cost shall include, without limitation, the costs of construction, the cost of permits and permit expediting, the costs of code compliance work, if such work is required as a result of, or is a condition imposed by appropriate governmental authorities for, construction of the Tenant Improvements, and all architectural and engineering services obtained by Landlord in connection with the Tenant Improvements, the Contractor's fees, Landlord's fee for construction administration in an amount which shall not exceed three percent (3%) of hard costs, utilities, and Landlord's Insurance Costs (including, without limitation, course of construction insurance), from the date of this Work Letter until the Lease Commencement Date up to a maximum of $450,000.00 (the "Tenant Improvement Allowance"). The Tenant Improvement Allowance shall be utilized only for building improvements to the Building, and not for signage, furniture costs, any third party consulting or contracting fees, any telecom/cabling costs, or any other purpose. Tenant shall bear and pay the cost of the Tenant Improvements (including but not limited to all of the foregoing fees and costs) in excess of the Tenant Improvement Allowance, if any. The cost of the Tenant Improvements shall exclude the cost of furniture, fixtures and inventory and other items of Tenant's Work (as defined below). Tenant shall have the right to elect to increase the Tenant Improvement Allowance by up to an additional $450,000.00 (the "Additional Allowance"), subject to the following terms and conditions: (i) Tenant shall make such election, if at all, no later than August 15, 1998; (ii) such amount shall be paid to Landlord in equal monthly installments over the seven (7) year Lease Term with interest at 10%, as additional Base Monthly Rent in the manner specified by Article 3 of the Lease; and (iii) the Additional Allowance shall otherwise constitute a part of the Tenant Improvement Allowance and shall be subject to the restrictions and conditions on such Tenant Improvement Allowance provided in this Work Letter. Notwithstanding anything to the contrary contained herein or in the Lease, Landlord shall be responsible at its sole cost and expense for the incremental costs incurred by either Landlord or Tenant for asbestos removal within the interior of the Leased Premises required solely as a result of the construction of the Tenant Improvements. 5.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2
Maintenance and Repair; Return (a) Lessee, at its sole cost and expense, shall maintain each Property in good condition, repair and working order (ordinary wear and tear excepted) and in the repair and condition as when originally delivered to Lessor and make all necessary repairs thereto and replacements thereof, of every kind and nature whatsoever, whether interior or exterior, ordinary or extraordinary, structural or nonstructural or foreseen or unforeseen, in each case as required by Section 9.1 and on a basis consistent with the operation and maintenance of properties or equipment comparable in type and function to the applicable Property, such that such Property is capable of being immediately utilized by a third party and in compliance with standard industry practice subject, however, to the provisions of Article XV with respect to Casualty and Condemnation.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
