Meeting Space and Facilities The Employer’s offices and facilities may be used by the Union to hold meetings, subject to the agency’s policy, availability of the space and with prior authorization of the Employer.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
LEASE ALTERATIONS The Owner hereby gives power to the Agent to initiate, sign, renew, modify, or cancel rental agreements and leases for the Property, or any part thereof and collect and give receipts for rents, other fees, charges, and security deposits.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Alterations to Premises Tenant shall make no structural or interior alterations to the Premises. If Tenant requests such alterations and such alterations are structural in nature, then Tenant shall provide Landlord with a complete set of construction drawings. If Landlord consents to the alterations, then the Landlord shall determine the actual cost of the work to be done. Tenant may then either agree to pay Landlord to have the work done or withdraw its request for alterations; provided, however, that at Tenant’s request, Landlord shall not unreasonably withhold its consent to allowing Tenant and/or Tenant’s contractors to perform such work. All such alterations are subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed. Subject to the terms of this paragraph, and notwithstanding any provision of this Lease to the contrary, Landlord agrees to allow Tenant to construct (i) a data center within the Premises and to install equipment (which may include generator, condensers, UPS, etc.) in the Building and around the land surrounding the Building necessary to facilitate the operation of Tenant’s data center, and (ii) an opening in the curtain wall of Floor 1 of Building C, to install two (2) four foot doors within such opening, to improve the outside area for delivery access and to install other improvements (which may include a large dumpster) to the Building and the land surrounding the Building necessary to facilitate the operation of Tenant’s Fulfillment Center. All such alterations shall be performed by Tenant’s contractors (which shall be subject to Landlord’s approval, not to be unreasonably withheld), at Tenant’s sole cost and expense. Notwithstanding the above paragraph, Tenant shall have the right to make nonstructural and nonsystems related alterations (“Tenant Alterations”) up to a value of $15,000.00 per occurrence (not to exceed $60,000 during any 12-month period) without Landlord’s prior written consent (which consent shall not be unreasonably withheld), provided Tenant shall provide notice to Landlord of its intent to make the Tenant Alterations. Such notice shall include a copy of plans and specifications (if such alterations are of a character that would reasonably require plans and specifications) and copies of all permits, if required by the appropriate municipality, and any contracts for such Tenant Alterations. All Tenant Alterations shall be performed by contractors approved by Landlord which approval shall not be unreasonably withheld, and in accordance with all applicable laws and the rules and regulations described in Section 12b.
Utility Charges Tenant shall pay or cause to be paid all charges for electricity, power, gas, oil, water and other utilities used in connection with the Leased Property.
WORK CLOTHING Two sets of cotton drill protective clothing will be issued to all employees, upon request, within two weeks of commencing work with the Company. Employees will be made aware of these entitlements at the time of employment. A set of clothing will consist of either: • Two pairs of overalls; or • Two combination bib and brace; or • Two pairs of long trousers and two long sleeved shirt; or • Work denims at cost no greater than the above three choices • Clothing and footwear will be replaced on a fair wear and tear basis.
Construction Cost 3.1. Construction Cost does not include the fees of the ARCHITECT/ENGINEER and consultants, the cost of the land, rights- of-way, or other costs, which is the responsibility of the State as provided in Paragraphs 2.2 through 2.3. or any of the contingencies available for the project unless specifically stated otherwise.
3.2. Labor furnished by the State for the Project, however, with respect only to the construction of such components thereof as have been designed by the ARCHITECT/ENGINEER, shall be included in the Construction Cost at current market rates. Materials and equipment furnished by the State shall be included at current market prices, except that used materials and equipment shall be included as if purchased new for the Project.
Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter Agreement. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the "Renovations") the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord's actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant's business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant's personal property or improvements resulting from the Renovations or Landlord's actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord's actions.
The Site The site of the Project Highway (the “Site”) shall comprise the site described in Schedule-A in respect of which the Right of Way shall be provided by the Authority to the Contractor. The Authority shall be responsible for:
(a) acquiring and providing Right of Way on the Site in accordance with the alignment finalised by the Authority, free from all encroachments and encumbrances, and free access thereto for the execution of this Agreement; and
(b) obtaining licences and permits for environment clearance for the Project Highway.
