Right to Proceed The Sponsor acknowledges the rights of Holders to institute a Direct Action as set forth in Section 2.8(d) hereto.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Fund's Right to Proceed Notwithstanding anything to the contrary contained herein, each Fund shall have, at its election upon reasonable notice to the Custodian, the right to enforce, to the extent permitted by any applicable agreement and applicable law, the Custodian's rights against any Subcustodian, Securities System, Eligible Securities Depository or other Person for loss, damage or expense caused such Fund by such Subcustodian, Securities System, Eligible Securities Depository or other Person, and shall be entitled to enforce the rights of the Custodian with respect to any claim against such Subcustodian, Securities System, Eligible Securities Depository or other Person, which the Custodian may have as a consequence of any such loss, damage or expense, if and to the extent that such Fund has not been made whole for any such loss or damage. If the Custodian makes such Fund whole for any such loss or damage, the Custodian shall retain the ability to enforce its rights directly against such Subcustodian, Securities System, Eligible Securities Depository or other Person. Upon such Fund's election to enforce any rights of the Custodian under this Section 5.05, such Fund shall reasonably prosecute all actions and proceedings directly relating to the rights of the Custodian in respect of the loss, damage or expense incurred by such Fund; provided that, so long as such Fund has acknowledged in writing its obligation to indemnify the Custodian under Section 5.03 hereof with respect to such claim, such Fund shall retain the right to settle, compromise and/or terminate any action or proceeding in respect of the loss, damage or expense incurred by such Fund without the Custodian's consent and provided further, that if such Fund has not made an acknowledgment of its obligation to indemnify, such Fund shall not settle, compromise or terminate any such action or proceeding without the written consent of the Custodian, which consent shall not be unreasonably withheld or delayed. The Custodian agrees to cooperate with each Fund and take all actions reasonably requested by such Fund in connection with such Fund's enforcement of any rights of the Custodian. Each Fund agrees to reimburse the Custodian for all reasonable out-of-pocket expenses incurred by the Custodian on behalf of such Fund in connection with the fulfillment of its obligations under this Section 5.05; provided, however, that such reimbursement shall not apply to expenses occasioned by or resulting from the negligence, misfeasance or misconduct of the Custodian.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.
Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT.
B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate.
B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner.
B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment.
B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
Landlord’s Right to Enter Landlord and its agents shall have the right to enter the Leased Premises during normal business hours after giving Tenant reasonable notice and subject to Tenant’s reasonable security measures for the purpose of (i) inspecting the same; (ii) showing the Leased Premises to prospective purchasers, mortgagees or tenants; (iii) making necessary alterations, additions or repairs; and (iv) performing any of Tenant’s obligations when Tenant has failed to do so. Landlord shall have the right to enter the Leased Premises during normal business hours (or as otherwise agreed), subject to Tenant’s reasonable security measures, for purposes of supplying any maintenance or services agreed to be supplied by Landlord. Landlord shall have the right to enter the Outside Areas during normal business hours for purposes of (i) inspecting the exterior of the Building and the Outside Areas; (ii) posting notices of nonresponsibility (and for such purposes Tenant shall provide Landlord at least thirty days’ prior written notice of any work to be performed on the Leased Premises); and (iii) supplying any services to be provided by Landlord. Any entry into the Leased Premises or the Outside Areas obtained by Landlord in accordance with this paragraph shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of, the Leased Premises, or an eviction, actual or constructive of Tenant from the Leased Premises or any portion thereof.
LANDLORD'S RIGHT TO PERFORM TENANT'S OBLIGATIONS (a) Without limiting the rights and remedies of Landlord contained in Sections 20.2 and 20.3 above, if Tenant shall be in default in the performance of any of the terms, provisions, covenants or conditions to be performed or complied with by Tenant pursuant to this Lease, then Landlord may at Landlord’s option, without any obligation to do so, and without notice to Tenant perform any such term, provision, covenant, or condition, or make any such payment and Landlord by reason of so doing shall not be liable or responsible for any loss or damage thereby sustained by Tenant or anyone holding under or through Tenant or any of Tenant’s Agents.
(b) Without limiting the rights of Landlord under Sections 20.2 and 20.3 above, Landlord shall have the right at Landlord’s option, without any obligation to do so, to perform any of Tenant’s covenants or obligations under this Lease without notice to Tenant in the case of an emergency, as determined by Landlord in its sole and absolute judgment, or if Landlord determines, in its sole and absolute judgment, that such action is necessary or desirable to avoid imminent harm to the Premises or any persons.
(c) If Landlord performs any of Tenant’s obligations hereunder in accordance with this Section 20.4, the full amount of the cost and expense incurred or the payment so made or the amount of the loss so sustained shall immediately be owing by Tenant to Landlord, and Tenant shall promptly pay to Landlord upon demand, as Additional Charges, the full amount thereof with interest thereon from the date of payment by Landlord at the lower of (i) ten percent (10%) per annum, or (ii) the highest rate permitted by applicable law.
LANDLORD'S RIGHT TO INSPECT Tenant shall permit Landlord and its authorized representatives to inspect the Leased Property, or any portion thereof, during usual business hours upon not less than forty-eight (48) hours’ notice and to make such repairs as Landlord is permitted or required to make pursuant to the terms of this Agreement, provided that any inspection or repair by Landlord or its representatives will not unreasonably interfere with Tenant’s use and operation of the Leased Property and further provided that in the event of an emergency, as determined by Landlord in its reasonable discretion, prior Notice shall not be necessary.
