Construction Phase Performance Security Sample Clauses

Construction Phase Performance Security. 6.1.1 For due and faithful performance of its obligations during the Construction Phase under this Concession Agreement, the Concessionaire shall provide the ADA within a period of 30 days from the Execution Date, a Construction Phase Performance Security in the form of an irrevocable and unconditional Bank Guarantee of an amount equal to 10 Lakh in single or multiple form of Bank Guarantees as may be instructed by the ADA, issued by SBI or any of its subsidiary or a nationalized bank, having its branch at Amritsar in favour of Chief Administrator, Amritsar Development Authority, Government of Punjab and such security shall be maintained and valid at all times from the date of issue thereof until 30 days following the COD; 6.1.2 On successful completion of the Construction Phase and achieving the COD, the Construction Phase Performance Security shall be released by ADA to the Concessionaire in the following manner: (a) on 100% Construction Completion as certified by the Independent Expert, 50% of the amount of Construction Phase Performance Security will be released to the Concessionaire ; (b) the balance 50% of the amount of Construction Phase Performance Security will be release after the concession period For avoidance of doubt it is clarified that the Construction Completion shall be linked to the approved Drawings building plans, layouts and specifications sanctioned by the concerned Statutory Authority and submitted with the ADA by the Concessionaire and the Concessionaire shall furnish the appropriate documents supporting Construction Completion such as Construction Completion Certificate issued by the Independent Expert, as may be required by ADA, prior to release of such Construction Phase Performance Security.
Sample 1
AutoNDA by SimpleDocs

Related to Construction Phase Performance Security

  • The Performance Improvement Process (a) The Performance Improvement Process will focus on the risks of non- performance and problem-solving. It may include one or more of the following actions: (1) a requirement that the HSP develop and implement an improvement plan that is acceptable to the LHIN; (2) the conduct of a Review; (3) a revision and amendment of the HSP’s obligations; and (4) an in-year, or year end, adjustment to the Funding, among other possible means of responding to the Performance Factor or improving performance. (b) Any performance improvement process begun under a prior service accountability agreement that was not completed under the prior agreement will continue under this Agreement. Any performance improvement required by a LHIN under a prior service accountability agreement will be deemed to be a requirement of this Agreement until fulfilled or waived by the LHIN.

  • Performance Security 47.1 Within twenty-one (21) days of the receipt of Letter of Acceptance from the Procuring Entity, the successful Tenderer, if required, shall furnish the Performance Security in accordance with the GCC 18, using for that purpose the Performance Security Form included in Section X, Contract Forms. If the Performance Security furnished by the successful Tenderer is in the form of a bond, it shall be issued by a bonding or insurance company that has been determined by the successful Tenderer to be acceptable to the Procuring Entity. A foreign institution providing a bond shall have a correspondent financial institution located in Kenya, unless the Procuring Entity has agreed in writing that a correspondent financial institution is not required. 47.2 Failure of the successful Tenderer to submit the above-mentioned Performance Security or sign the Contract shall constitute sufficient grounds for the annulment of the award and forfeiture of the Tender Security. In that event the Procuring Entity may award the Contract to the Tenderer offering the next lowest Evaluated Tender. 47.3 Performance security shall not be required for a contract, if so specified in the TDS.

  • CONTRACTOR PERFORMANCE AUDIT The Contractor shall allow the Authorized User to assess Contractor’s performance by providing any materials requested in the Authorized User Agreement (e.g., page load times, response times, uptime, and fail over time). The Authorized User may perform this Contractor performance audit with a third party at its discretion, at the Authorized User’s expense. The Contractor shall perform an independent audit of its Data Centers, at least annually, at Contractor expense. The Contractor will provide a data owner facing audit report upon request by the Authorized User. The Contractor shall identify any confidential, trade secret, or proprietary information in accordance with Appendix B, Section 9(a), Confidential/Trade Secret Materials.

  • Appropriation of Performance Security (i) Upon occurrence of a Contractor’s Default, the Authority shall, without prejudice to its other rights and remedies hereunder or in law, be entitled to encash and appropriate the relevant amounts from the Performance Security as Damages for such Contractor’s Default. (ii) Upon such encashment and appropriation from the Performance Security, the Contractor shall, within 30 (thirty) days thereof, replenish, in case of partial appropriation, to its original level the Performance Security, and in case of appropriation of the entire Performance Security provide a fresh Performance Security, as the case may be, and the Contractor shall, within the time so granted, replenish or furnish fresh Performance Security as aforesaid failing which the Authority shall be entitled to terminate the Agreement in accordance with Article 23. Upon replenishment or furnishing of a fresh Performance Security, as the case may be, as aforesaid, the Contractor shall be entitled to an additional Cure Period of 30 (thirty) days for remedying the Contractor’s Default, and in the event of the Contractor not curing its default within such Cure Period, the Authority shall be entitled to encash and appropriate such Performance Security as Damages, and to terminate this Agreement in accordance with Article 23.

  • Performance Improvement Plan timely and accurate completion of key actions due within the reporting period 100 percent The Supplier will design and develop an improvement plan and agree milestones and deliverables with the Authority 3.2 The Authority may from time to time make changes to the KPIs measured as set out in paragraph 3.1 above and shall issue a replacement version to the Supplier. The Authority shall give notice In Writing of any such change to the KPIs measured and shall specify the date from which the replacement KPIs must be used for future reports. Such date shall be at least thirty (30) calendar days following the date of the notice to the Supplier.

  • Performance Delay Time is of the essence in the Vendor’s performance of this Agreement. If at any time it appears to Vendor that it may not meet any of the performance schedules or the scheduled completion date of the services to be performed for any reason, including labor disputes, Vendor shall immediately by verbal means (to be confirmed in writing) notify Customer of the reasons for and the estimated duration of such delay. If requested by Customer, Vendor shall make every effort to avoid or minimize the delay to the maximum extent possible including the expenditure of premium time. Any additional cost caused by these requirements of Customer shall be borne by Vendor, unless the delay in performance arises out of causes beyond the control and without the fault or negligence of Vendor or its subcontractors within the meaning of the Cancellation- Default clause herein. The foregoing requirements are in addition to any of Customer’s other rights and remedies as may be provided by law or this Agreement.

  • Quarterly Contractor Performance Reporting Customers shall complete a Contractor Performance Survey (Exhibit I) for each Contractor on a Quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated in Contract Exhibit D, Section 17, Additional Special Contract Conditions. The completed Contractor Performance Survey(s) will be used by the Department as a performance-reporting tool to measure the performance of Contractors. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MyFloridaMarketPlace or on the Department's website).

  • Performance Assessment 6.1 The Performance Plan (Annexure A) to this Agreement sets out key performance indicators and competencies that needs to be evaluated in terms of – 6.1.1 The standards and procedures for evaluating the Employee’s performance; and 6.1.2 During the intervals for the evaluation of the Employee’s performance. 6.2 Despite the establishment of agreed intervals for evaluation, the Employer may in addition review the Employee’s performance at any stage while the contract of employment remains in force; 6.3 Personal growth and development needs identified during any performance review discussion must be documented in a Personal Development Plan as well as the actions agreed to and implementation must take place within set time frames; 6.4 The Employee’s performance will also be measured in terms of contributions to the goals and strategies set out in the Employer’s Integrated Development Plan (IDP) as described in 6.6 – 6.13 below; 6.5 The Employee will submit quarterly performance reports (SDBIP) and a comprehensive annual performance report at least one week prior to the performance assessment meetings to the Evaluation Panel Chairperson for distribution to the panel members for preparation purposes; 6.6 Assessment of the achievement of results as outlined in the performance plan: 6.6.1 Each KPI or group of KPIs shall be assessed according to the extent to which the specified standards or performance targets have been met (qualitative and quantitative) and with due regard to ad-hoc tasks that had to be performed under the KPI; 6.6.2 A rating on the five-point scale described in 6.9 below shall be provided for each KPI or group of KPIs which will then be multiplied by the weighting to calculate the final score; 6.6.3 The Employee will submit his self-evaluation to the Employer prior to the formal assessment; 6.6.4 In the instance where the employee could not perform due to reasons outside the control of the employer and employee, the KPI will not be considered during the evaluation. The employee should provide sufficient evidence in such instances; and 6.6.5 An overall score will be calculated based on the total of the individual scores calculated above.

  • Ongoing Performance Measures The Department intends to use performance-reporting tools in order to measure the performance of Contractor(s). These tools will include the Contractor Performance Survey (Exhibit H), to be completed by Customers on a quarterly basis. Such measures will allow the Department to better track Vendor performance through the term of the Contract(s) and ensure that Contractor(s) consistently provide quality services to the State and its Customers. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MFMP or on the Department's website).

  • Release of Performance Security (i) The Authority shall return the Performance Security to the Contractor within 60 (sixty) days of the expiry of the Maintenance Period or the Defects Liability Period, whichever is later, under this Agreement. Notwithstanding the aforesaid, the Parties agree that the Authority shall not be obliged to release the Performance Security until all Defects identified during the Defects Liability Period have been rectified. (ii) The Authority shall return the Additional Performance Security to the Contractor within 28 (twenty eight) days from the date of issue of Completion Certificate under Article 12 of this Agreement. (iii) The Authority shall be liable to pay interest @ 9% (nine per cent) per annum for any delay in the return of Performance Security and Additional Performance Security, if any, beyond the period prescribed above for the period of delay.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!