Construction Services Procurement Phase Sample Clauses

Construction Services Procurement Phase. 5.1. A/E shall participate in the Construction Services Procurement phase of the Project by attending the Pre-submittal Conference, issuing Addenda to the Construction Documents as required, and by assisting Owner in evaluating proposed alternate materials or approaches for completing the work associated with the Project.
Sample 1
AutoNDA by SimpleDocs
Construction Services Procurement Phase. Construction Phase – Administration of the Construction Contract
Sample 1
Construction Services Procurement Phase. Engineer shall participate in the Construction Services Procurement phase of the Project by attending the Pre-submittal Conference, issuing Addenda to the Construction Documents as required, and by assisting Owner in evaluating proposed alternate materials or approaches for completing the work associated with the Project.
Sample 1
Construction Services Procurement Phase. 1.5.1 Project A/E shall assist Owner in obtaining and evaluating bids or proposals, and assist in awarding contracts for construction services including preparation for and attendance at Pre-Submittal Conferences and HUB meetings. Project A/E shall answer inquiries from prospective respondents to requests for bids or proposals, at Owner’s request, and shall prepare and issue any necessary addenda to the Construction Documents. Project A/E shall maintain a register of procurement documents, arrange for the distribution of documents to prospective respondents, and plan rooms, and, when so requested by Owner, obtain and administer deposits. 1.5.2 For solicitations based upon competitive sealed bidding, Project A/E shall review and inquire about the responsibility of apparent low bidders and inform Owner in writing of Project A/E’s findings and recommendations. For solicitations based upon competitive sealed proposals, Project A/E shall review and inquire about qualifications and other pertinent proposal information and inform Owner in writing of Project A/E’s findings and recommendations. 1.5.3 In the event the best value proposal or lowest responsible bid received for the Project exceeds the Construction Cost Limitation following the completion of the Construction Document Phase, Project A/E, without charge to Owner, and if so directed by Owner, shall revise the Construction Documents as necessary to bring the cost of the Project within the Construction Cost Limitation. Owner reserves the right to accept a proposal or bid and award a construction contract that exceeds the Construction Cost Limitation, if such award is determined by Owner to be in Owner’s best interest.
Sample 1
Construction Services Procurement Phase. 1.5.1 In conjunction with the development of the GMP, the awarding of subcontracts for construction services and at other times as appropriate to the Project, Project A/E shall assist Owner and Construction Manager by receiving and recording Invitation to Bid (“ITB”) and Request for Proposal (“RFP”) documents, issuing procurement documents, and accounting for procurement documents issued; receiving and resolving questions about procurement documents; preparing addenda, issuing addenda, and accounting for addenda issued; attending pre-submittal conferences and HUB meetings; obtaining and evaluating Bids and Proposals; and assisting in preparing and awarding subcontracts for construction. Project A/E shall answer inquiries from prospective respondents to ITBs and RFPs at Owner’s request, and shall prepare and issue any necessary addenda to the subcontract procurement documents.
Sample 1

Related to Construction Services Procurement Phase

  • Construction Services 3.1.1 Basic Construction Services. 3.1.2 Meetings and Schedule Updates.

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • Preconstruction Services During the Design & Preconstruction Phase, the Design-Builder shall provide such design and preconstruction services as are necessary to properly advance the Project. Without limiting the generality of the foregoing, during the Preconstruction Phase, the Design-Builder shall: (i) work with its Architect and any design consultants to advance the design for the Project in consultation with Client Agency, the Department and its Program Manager; (ii) obtain bids from trade subcontractors to perform the work described in the Design Development Documents and provide bid tabulations to the Department; (iii) engage in any value engineering and scoping exercises necessary to return the cost of the work to the Project Budget; (iv) engage in preconstruction activities, including identifying any long-lead items; (v) develop a GMP proposal for the Project; and (vi) enter into a GMP for the Project. Throughout the Design & Preconstruction Phase, the Design-Builder shall schedule and attend regular meetings with the Department, the Program Manager and the Architect. A list of preconstruction deliverables is set forth in Exhibit C.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Installation Services The Bitstream 2a Service includes a Standard Install as set out below (in each case to the extent that the relevant provisioning works are not already complete for the relevant Service Order).1

  • Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.

  • PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:

  • Implementation Services Vendor shall provide the Implementation Services, if any, described in Exhibit A. The Services Fees for any Implementation Services shall be described in Exhibit A.

  • PROJECT SERVICES Landlord shall furnish services as follows:

  • Equipment Procurement If responsibility for construction of the Connecting Transmission Owner’s Attachment Facilities or System Upgrade Facilities or System Deliverability Upgrades is to be borne by the Connecting Transmission Owner, then the Connecting Transmission Owner shall commence design of the Connecting Transmission Owner’s Attachment Facilities or System Upgrade Facilities or System Deliverability Upgrades and procure necessary equipment as soon as practicable after all of the following conditions are satisfied, unless the Developer and Connecting Transmission Owner otherwise agree in writing: 5.5.1 NYISO and Connecting Transmission Owner have completed the Interconnection Facilities Study pursuant to the Interconnection Facilities Study Agreement; 5.5.2 The NYISO has completed the required cost allocation analyses, and Developer has accepted his share of the costs for necessary System Upgrade Facilities and System Deliverability Upgrades in accordance with the provisions of Attachment S of the NYISO OATT; 5.5.3 The Connecting Transmission Owner has received written authorization to proceed with design and procurement from the Developer by the date specified in Appendix B hereto; and 5.5.4 The Developer has provided security to the Connecting Transmission Owner in accordance with Article 11.5 by the dates specified in Appendix B hereto.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!