Contractor Responsibility for Damages Without Termination Sample Clauses

Contractor Responsibility for Damages Without Termination. 1. Reimbursement of damages resulting from the Contractor’s errors, omissions or negligent performance of the Work, breaches of the Contractor’s Contract, and failures by the Contractor to comply with the applicable standard of care shall be pursued actively by APS. Within a reasonable time after APS has actual knowledge of such error, omission or negligent performance or breach and has made a determination that there may be Contractor financial responsibility, the Contractor shall be given Notice of the error, omission, negligent performance or breach and that APS intends to hold the Contractor financially responsible. The Contractor shall in no more than fourteen (14) Days from the date of the Notice provide a technical solution to the identified problem, including cost estimate. The Contractor also shall coordinate with APS to determine required technical support and timing to minimize delays and costs to the construction project for which the Work is being provided (“Project”) resulting from the issue. Pending final decision by the Owner, the Contractor will be invited to attend all price negotiations for the corrective work with the person or entity under contract with APS to perform the construction work on the Project (“Construction Contractor”).
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs

Related to Contractor Responsibility for Damages Without Termination

  • CONTRACTOR RESPONSIBILITY FOR SYSTEM AGENCY’S TERMINATION COSTS If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.

  • Responsibility for Damages Contractor is responsible for all damage that occurs as a result of Contractor’s fault or negligence or that of its’ employees, agents, or representatives in connection with the performance of this Contract. Contractor shall immediately report any such damage to people and/or property to the Contract Administrator.

  • Responsibility for Damage Resident is solely responsible for any damage, defacement or loss within the assigned bedroom space. All assigned residents of an apartment are jointly and severally responsible for any damage, defacement or loss to common areas, other parts of the facility, fixtures or appliances, except for the portion of damages over $100,000 where it is finally established that Resident or one or more other residents of the apartment were solely at fault for the entire loss, in which case such person(s) will be solely responsible. Resident is fully responsible for the conduct of Resident’s guests, visitors, licensees and invitees (“Guests”), including without limitation harm to individuals or damage or defacement of any part of the Property or its fixtures or property of third parties (including other residents) by such Guests.

  • OUR RESPONSIBILITY FOR LOSS OR DAMAGE SUFFERED BY YOU 14.1 We are responsible to you for foreseeable loss and damage caused by us. If we fail to comply with this Agreement, we are responsible for loss or damage you suffer that is a foreseeable result of our breaking this Agreement or our failure to use reasonable care and skill, but we are not responsible for any loss or damage that is not foreseeable. Loss or damage is foreseeable if either it is obvious that it will happen, or if, at the time the Agreement is made, both we and you knew it might happen. We are not responsible for any loss or damage you suffer which is a result of you breaking this Agreement or you acting fraudulently.

  • CAISO Responsibility The Parties acknowledge that the CAISO is responsible for the efficient use and reliable operation of the CAISO Controlled Grid consistent with achievement of planning and Operating Reserve criteria no less stringent than those established by the Western Electricity Coordinating Council and the North American Electric Reliability Corporation and further acknowledges that the CAISO may not be able to satisfy fully these responsibilities if the Participating Generator fails to fully comply with all of its obligations under this Agreement.

  • Cost Responsibility for Network Upgrades 9 5.1 Applicability 9 5.2 Network Upgrades 9

  • Consultant’s Responsibility Nothing herein shall be construed as limiting in any way the extent to which Consultant may be held responsible for damages resulting from Consultant’s operations, acts, omissions, or negligence. Insurance coverage obtained in the minimum amounts specified above shall not relieve Consultant of liability in excess of such minimum coverage, nor shall it preclude NCTC from taking other actions available to it under this Agreement or by law, including but not limited to, actions pursuant to Consultant’s indemnity obligations.

  • Responsibility For Damages Or Injury The County its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) shall not be answerable or accountable in any manner: for any loss or damage that may happen to the Project or any part thereof; for any loss or damage to any of the materials or other things used or employed in performing the Project; for injury to or death of any person either workers or the public; or for damage to property from any cause which might have been prevented by the Contractor, or his workers, or anyone employed by him. The Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects or obstructions or from any cause whatsoever during the progress of the Project or at any time before its completion and final acceptance. The Contractor shall indemnify, defend with counsel approved in writing by County and save harmless the County Indemnitees from all claims, suits or actions of every name, kind and description, brought for, or on account of, injuries to or death of any person or damage to property resulting from the construction of the Project or by or in consequence of any negligence in guarding the Project; use of improper materials in construction of the Project; or by or on account of any act or omission by the Contractor or his agents during the progress of the Work or at any time before the completion and final acceptance of the Project. In addition to any remedy authorized by law, so much of the money due the Contractor under and by virtue of the Contract as shall be considered necessary by the County may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County and County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither Party shall request a jury apportionment. Notwithstanding anything stated above, nothing contained herein shall relieve Contractor of any insurance requirements of obligations created elsewhere in this Contract.

  • PERFORMING AGENCY RESPONSIBILITY FOR SYSTEM AGENCY’S TERMINATION COSTS If the System Agency terminates the Contract for cause, the Performing Agency shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Performing Agency. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Performing Agency’s failure to perform any Work in accordance with the terms of the Contract.

  • Grantee Responsibility for System Agency’s Termination Costs If the System Agency terminates the Grant Agreement for cause, the Grantee shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Grantee. These costs include, but are not limited to, the costs of procuring a substitute grantee and the cost of any claim or litigation attributable to Xxxxxxx’s failure to perform any work in accordance with the terms of the Grant Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.