Contractor’s Breach of Contract Sample Clauses

Contractor’s Breach of Contract. 16.2.1 Circumstances in which the Contractor breaches the Contract Other circumstances in which the contractor breaches the contract: a) If the Contractor replaces the Project Manager or the main technical, safety and quality persons in charge without the permission of the Employer, the Employer has the right to require them to revoke the decision; if the Contractor's Project Manager or technical person in charge is not competent for the Project, the Employer has the right to require them to be replaced and approved by the Employer. If the Contractor refuses to comply with the above requirements of the Employer, the Employer has the right to terminate this Contract. b) If the contractor fails to keep the construction site clean and tidy due to the contractor's fault, which causes adverse effects to the employer, the contractor shall bear all the expenses and losses caused thereby, and pay the employer a liquidated damages of 0.5% of the total contract price; if the contractor violates the relevant regulations of Shangrao City, Jiangxi Province or the employer on dust emission, noise control or waste disposal, the contractor shall bear all the expenses and losses caused thereby, and pay the employer a liquidated damages of 1/1000 of the total contract price. The contractor shall manage the construction site in accordance with the requirements of the city's civilized construction site and strive to create a civilized construction site in the city. c) If the Contractor fails to complete the project control time nodes and final completion time with quality and quantity as stipulated in this Contract, or if certain facts cause the Employer to believe that the Contractor is not competent for the Project, the Employer has the right to terminate this Contract. d) If the contractor fails to execute or fails to execute the instructions of the supervisor or the contractor's representative in a timely manner, the losses caused to the contractor shall be borne by the contractor. If the above behavior occurs three times repeatedly, the contractor has the right to terminate this contract. e) Ensure that the quality of the project meets the one-time acceptance standard. If the project fails to meet this standard, the contractor shall be responsible for rectification until the project passes the acceptance standard, and the resulting costs and fines shall be borne by the contractor. f) Delays in construction period due to rectification or rework will still be subject to a ...
Sample 1
AutoNDA by SimpleDocs
Contractor’s Breach of Contract. 16.2.1 Circumstances in which the contractor breaches the contract The following circumstances occurring during the performance of the contract shall constitute breach of contract by the contractor: ( 1 ) The contractor violates the contract by subcontracting or illegally sub-contracting; ( 2 ) The contractor violates the contract by purchasing and using substandard materials and engineering equipment; ( 3 ) The quality of the project does not meet the contract requirements due to the contractor's fault; ( 4 ) The Contractor violates the provisions of Clause 8.9 [Special Requirements for Materials and Equipment] and, without approval, privately removes materials or equipment that have been brought into the construction site in accordance with the contract from the construction site; ( 5 ) The contractor fails to complete the work agreed in the contract in a timely manner according to the construction schedule, resulting in delay in the construction period; ( 6 ) The contractor fails to repair the defects in the roject within a reasonable period of time during the defect liability period and the warranty period, or refuses to repair the defects as required by the employer; ( 7 ) The contractor expressly states or demonstrates through his actions that he will not perform the main obligations of the contract; ( 8 ) The contractor fails to perform other obligations as agreed in the contract. the contractor commits any other breach of contract other than that stipulated in Item ( 7 ) of this clause, the supervisor may issue a rectification notice to the contractor requiring it to make corrections within a specified period of time.
Sample 1
Contractor’s Breach of Contract 
Sample 1

Related to Contractor’s Breach of Contract

  • NO BREACH OF CONTRACT The Executive hereby represents to the Company that: (i) the execution and delivery of this Agreement by the Executive and the performance by the Executive of the Executive’s duties hereunder shall not constitute a breach of, or otherwise contravene, the terms of any other agreement or policy to which the Executive is a party or otherwise bound, except for agreements entered into by and between the Executive and any member of the Group pursuant to applicable law, if any; (ii) that the Executive has no information (including, without limitation, confidential information and trade secrets) relating to any other person or entity which would prevent, or be violated by, the Executive entering into this Agreement or carrying out his duties hereunder; (iii) that the Executive is not bound by any confidentiality, trade secret or similar agreement (other than this) with any other person or entity except for other member(s) of the Group, as the case may be.

  • Breach of Contract The failure of the Contractor to comply with any of the provisions, covenants or conditions of this Contract shall be a material breach of this Contract. In such event the County may, and in addition to any other remedies available at law, in equity, or otherwise specified in this Contract: a) Terminate the Contract immediately, pursuant to Section K herein; b) Afford the Contractor written notice of the breach and ten (10) calendar days or such shorter time that may be specified in this Contract within which to cure the breach; c) Discontinue payment to the Contactor for and during the period in which the Contractor is in breach; and d) Offset against any monies billed by the Contractor but yet unpaid by the County those monies disallowed pursuant to the above.

  • Material Breach of Contract In the event Contractor fails to deliver the product and services as contracted for herein, to the satisfaction of the City of Sparks or otherwise fails to perform any provisions of this Contract, the City, after providing five (5) days written notice and Contractor’s failure to cure such breach within the time specified in the notice, may without waiving any other remedy, make good the deficiencies and deduct the actual cost of providing alternative products and/or services from payment due the Contractor. Non-performance after the first notice of non-performance shall be considered a material breach of contract.

  • Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.] 19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor: 12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. 12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University. 12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,

  • VIOLATION OF CONTRACT TERMS/BREACH OF CONTRACT Violation of contract terms or breach of contract by Engineer shall be grounds for termination of this Contract, and any increased costs arising from Engineer’s default, breach of contract, or violation of contract terms shall be paid by Engineer.

  • BREACH OF CONTRACT TERMS The State reserves its right to all administrative, contractual, or legal remedies, including but not limited to suspension or termination of this contract, in instances where the Contractor or any of its subcontractors violate or breach any contract term. If the Contractor or any of its subcontractors violate or breach any contract term, they shall be subject to such sanctions and penalties as may be appropriate. The duties and obligations imposed by the contract documents and the rights and remedies available thereunder shall be in addition to and not a limitation of any duties, obligations, rights and remedies otherwise imposed or available by law.

  • Liability for Breach of Contract 1. Party A and Party B shall strictly perform the terms stipulated in the agreement. If one party breaches the contract, the breaching party shall bear the liability for breach of contract according to the contract. 2. If the product is delivered by Party A to Party B and Party B fails to raise any objection to the product quality within the acceptance period, Party B shall not apply for return or replacement; If the product quality problems caused by Party B due to Party B's reasons or the intervention of a third party, which are not caused by the product itself, and caused by Party B's failure to raise any objection within the time limit since the date of acceptance, Party A can repair and rework the products, and Party B shall bear the rework service fee, material fee, processing fee, labor wages and other expenses incurred by Party A; 3. If the payment is not made in advance and then delivered, the ownership of the goods stipulated in this agreement still belongs to Party A before Party B pays off the payment, and Party A has the right to take back the goods at any time. Meanwhile, before this, Party B shall properly keep the goods and ensure that they are intact. If there is any damage, Party B shall compensate Party A according to the price of the goods agreed in the agreement. If the amount is not enough to make up for the losses, it shall also compensate Party A for all losses. 4. If Party B violates the agreement or refuses to perform the cooperation content during the cooperation period of this agreement, and refuses to perform or even withdraws from the cooperation after being urged by Party A, Party A has the right not to return the initial fee paid by Party B as a security deposit; At the same time, Party B shall cooperate with Party A to return all cooperation materials such as cooperation project materials and trademark product authorization documents, and compensate all economic losses suffered by Party A; 5. If Party B violates this agreement and causes losses to Party A, all expenses (including but not limited to attorney fees, legal fees, arbitration fees, announcement fees, preservation fees, guarantee fees, appraisal fees and auction evaluation fees) incurred by Party A for safeguarding its own legitimate rights and interests shall be borne by Party B; 6. If Party B cancels or changes the order without authorization, it shall pay 20% of the order price as liquidated damages and compensate Party A for all losses such as stocking, labor and profit.

  • Liabilities for Breach of Contract 11.1 The Parties agree and acknowledge that, if any Party (“Defaulting Party”) is materially in breach of any provision of this Agreement, or materially fails to perform or delays in performing any of its obligations hereunder, such breach, failure or delay shall constitute a default hereunder (the “Default”), and the non-defaulting Party shall be entitled to demand the Defaulting Party to rectify such Default or take remedial actions within a reasonable period of time. If the Defaulting Party fails to rectify such Default or take remedial actions within such reasonable period of time or ten (10) days from the receipt of the written notice from the non-defaulting Party requiring such rectification, the non-defaulting Party shall be entitled to make a decision at its sole discretion: 11.1.1 the WFOE shall be entitled to terminate this Agreement and claim from the Defaulting Party for damages if the Defaulting Party is any of the Existing Shareholders or the Company; 11.1.2 the non-defaulting Party shall be entitled to claim from the Defaulting Party for damages if the Defaulting party is the WFOE, provided that under no circumstances shall the Non-defaulting Party be entitled to terminate or rescind this Agreement unless otherwise provided by laws. 11.2 Notwithstanding anything to the contrary in this Agreement, this Article shall survive the termination of this Agreement.

  • Breach of Covenant The Borrower breaches any material covenant or other term or condition of this Note or the Purchase Agreement in any material respect and such breach, if subject to cure, continues for a period of thirty (30) days after the occurrence thereof.

  • FALSE STATEMENTS; BREACH OF REPRESENTATIONS The Parties acknowledge that this Agreement has been negotiated, and is being executed, in reliance upon the information contained in the Application, and any supplements or amendments thereto, without which the Comptroller would not have approved this Agreement and the District would not have executed this Agreement. By signature to this Agreement, the Applicant: A. represents and warrants that all information, facts, and representations contained in the Application are true and correct to the best of its knowledge; B. agrees and acknowledges that the Application and all related attachments and schedules are included by reference in this Agreement as if fully set forth herein; and C. acknowledges that if the Applicant submitted its Application with a false statement, signs this Agreement with a false statement, or submits a report with a false statement, or it is subsequently determined that the Applicant has violated any of the representations, warranties, guarantees, certifications, or affirmations included in the Application or this Agreement, the Applicant shall have materially breached this Agreement and the Agreement shall be invalid and void except for the enforcement of the provisions required by Section 9.2 of this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!