Costs of Correction Sample Clauses

Costs of Correction. The costs of correcting rejected or omitted Design- Build Work shall be borne by the Design-Builder. If it is determined by the parties or through dispute resolution pursuant to Section 8.12 (Non-Binding Dispute Resolution Procedures) that the corrective action was not necessary to conform the Design-Build Work with the requirements of this Design-Build Agreement, the Owner shall reimburse the Design-Builder for its costs and expenses incurred in correcting the Design-Build Work, subject to Cost Substantiation, and the Scheduled Acceptance Date shall be extended to reflect delays caused by such corrective work.
Sample 1Sample 2
AutoNDA by SimpleDocs
Costs of Correction. The costs of correcting rejected or omitted Design/Build Work shall be borne by the Company. If it is determined by the parties or through dispute resolution that the corrective action was not necessary to conform the Design/Build Work with the requirements of this Agreement, the County shall reimburse the Company for its costs and expenses incurred in correcting the Design/Build Work, subject to Cost Substantiation, and the Scheduled Operations Commencement Date shall be extended to reflect delays caused by such corrective work.
Sample 1

Related to Costs of Correction

  • Disbursements for Site Improvements All payments made by the OPWC for site improvements or other work shall be made directly to the Contractor that performed the work and originated the invoice, unless the request is for disbursement to the Recipient.

  • Construction With Other Parts Of The Tariff This ISA shall not be construed as an application for service under Part II or Part III of the Tariff.

  • Audits by The District and Correction of Accounts During the term of this Agreement and for a period of six (6) years following the termination of this Agreement, the District may begin an audit of Contractor’s provision of goods and/or services under this Agreement. Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, during the term of this Agreement and for at least six (6) years following the termination of this Agreement. If Contractor receives notice that The District is auditing its performance under this Agreement or litigation results from this Agreement, then Contractor agrees to retain and make available for inspection all of its records pertaining to its performance of this Agreement, including billing records and any banking records that may reflect proceeds from any transactions with the District, for an additional three (3) years following the conclusion of the audit or the entry of a final judgment in any such litigation and the final resolution of any possible appeals of a final judgment in any such litigation. If the District determines as result of its audit, that Contractor has failed to satisfy the invoicing or documentation requirements of this Agreement, has improperly billed the District for goods and/or services that were not actually provided, or has overcharged the District for goods and/or services that were actually provided by Contractor, then Contractor shall repay the District, without interest, for any improper payments or overpayments made by the District to Contractor within thirty (30) days of a written demand by the District. If Contractor fails to repay the District for any improper payments or overpayments within thirty (30) days of the District’s written demand, then Contractor will owe the District interest accrued daily at the rate of 7.0% per annum from the date of the District’s written demand until the improper payment and/or overpayment is repaid in full by Contractor. Conversely, if an audit initiated by the District reveals that the District owes additional compensation to Contractor pursuant to the terms of this Agreement, then the District will pay the additional compensation to Contractor, without interest, within thirty (30) days of the completion of its audit. If the District fails to pay Contractor for any additional compensation owed under this Agreement within thirty (30) days after completion of its audit, then the District will pay Contractor interest on the additional compensation accrued daily at the rate of 7.0% per annum from the date of the completion of the District’s audit.

  • COLLECTION AND PROCESSING OF ITEMS In processing items You have deposited for collection, We are only Your agent and assume no responsibility beyond the exercise of ordinary care. Any item deposited is subject to final settlement in cash or credit. We may use any method We feel is appropriate to collect items, which may include use of a Federal Reserve Bank. We are not responsible for the acts of any third party We use for the collection of items including responsibility for lost items. If We use a local clearinghouse in the collection of items, You authorize Us to do so and to act in accordance with any applicable rules and regulations. We may permit You to withdraw funds from Your Account before final settlement has been made, however, if final settlement is not made, We have the right to charge Your Account or otherwise require You to repay such funds. In processing items presented for payment on Your Account, We will pay such items each business day in an order of Our choosing, all of which means that the transactions may not be processed in the order in which they occurred and that You could incur multiple fees in a single day should there be insufficient funds to pay all items presented that day.

  • DOCUMENTATION; RECORDS OF PROCESSING Each party is responsible for its compliance with its documentation requirements, in particular maintaining records of processing where required under Data Protection Law. Each party shall reasonably assist the other party in its documentation requirements, including providing the information the other party needs from it in a manner reasonably requested by the other party (such as using an electronic system), in order to enable the other party to comply with any obligations relating to maintaining records of processing.

  • Construction Reports Each Constructing Entity shall issue reports to each other Construction Party on a monthly basis, and at such other times as reasonably requested, regarding the status of the construction and installation of the Interconnection Facilities. Each Construction Party shall promptly identify, and shall notify each other Construction Party of, any event that the Construction Party reasonably expects may delay completion, or may significantly increase the cost, of the Interconnection Facilities. Should a Construction Party report such an event, Transmission Provider shall, within fifteen days of such notification, convene a technical meeting of the Construction Parties to evaluate schedule alternatives.

  • Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.

  • VERIFICATION OF LICENSES, CREDENTIALS AND OTHER DOCUMENTS CONTRACTOR shall submit to LEA a staff list, and copies of all current licenses, certifications, credentials, permits and/or other documents which entitle the holder to provide special education and/or related services by CONTRACTOR and all individuals employed, contracted, and/or otherwise hired or sub-contracted by CONTRACTOR. CONTRACTOR shall ensure that all licenses, certifications, credentials, permits or other documents are on file at the office of the County Superintendent of Schools. CONTRACTOR shall notify LEA in writing within thirty (30) days when personnel changes occur which may affect the provision of special education and/or related services to students as specified in the LEA procedures. CONTRACTOR shall provide the LEA with the verified dates of fingerprint clearance, Department of Justice clearance and Tuberculosis Test clearance for all employees, approved subcontractors and/or volunteers prior to such individuals starting to work with any student. CONTRACTOR shall monitor the status of licenses, credentials, certifications, permits and/or other documents for all individuals employed, contracted, and/or otherwise hired by CONTRACTOR. CONTRACTOR shall notify LEA and CDE in writing within thirty (30) days when personnel changes occur which may affect the provision of special education and/or related services to LEA students. CONTRACTOR shall notify LEA within thirty (30) days if any such licenses, certifications or waivers are expired, suspended, revoked, rescinded, challenged pursuant to an administrative or legal complaint or lawsuit, or otherwise nullified during the effective period of this Master Contract. The LEA shall not be obligated to pay for any services provided by a person whose such licenses, certifications or waivers are expired, suspended, revoked, rescinded, or otherwise nullified during the period during which such person is providing services under this Master Contract. Failure to notify the LEA and CDE of any changes in credentialing/licensed staff may result in suspension or revocation of CDE certification and/or suspension or termination of this Master Contract by the LEA.

  • Disbursements to Contractors to Pay Costs of the Project The Recipient shall require that as work on the Project and as specified in its contract is performed a Contractor shall promptly submit a detailed project specific invoice to the Project Manager. Within three (3) Business Days following receipt of such invoice from a Contractor, the Project Manager shall review the invoice and, if found to be accurate, shall so certify in writing, forwarding such certification together with a copy of the invoice to the Chief Fiscal Officer. Within five (5) Business Days following receipt of such invoice and certification from the Project Manager, the Chief Fiscal Officer shall conduct such reviews as he considers appropriate and, if he approves such invoice, shall submit to the Director a Disbursement Request together with the information and certifications required by this Section 6(b). The dollar amount set forth in the Disbursement Request shall be calculated based on the Participation Percentage as set forth originally in Appendix D of this Agreement or as may be adjusted from time to time to account for changed conditions in the project financing scheme. Within five (5) Business Days following receipt of the Disbursement Request and all required information and certifications, the Director shall, if such items are deemed by the Director to be accurate and completed, initiate a voucher in accordance with applicable State requirements for the payment of the amount set forth in the Disbursement Request. Upon receipt of a warrant from the Auditor of State drawn in connection with a voucher initiated in accordance with the terms of the preceding sentence, the Director shall forward it by regular first class United States mail or electronic funds transfer, to the contractor or other authorized recipient designated in the Disbursement Request. Prior to any disbursement from the Fund, the following documents shall be submitted to the Director by the Recipient:

  • Project Monitoring by the State The State may conduct on-site or off-site monitoring reviews of the Project during the term of this Grant Agreement and for up to ninety (90) days after it expires or is otherwise terminated. The Grantee shall extend its full cooperation and give full access to the Project site and to relevant documentation to the State or its authorized designees for the purpose of determining, among other things:

Time is Money Join Law Insider Premium to draft better contracts faster.