Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Contract Consistency With Other Laws The contract shall govern if State and local environmental quality laws conflict with or preclude performance of contractual requirements.
Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.
Construction Administration Redeveloper shall be responsible for all components of the Redeveloper Improvements constructed by Redeveloper including construction management, coordination of contractors and regulatory permitting and other requirements. Redeveloper and its contractor(s) shall reasonably cooperate with City contractors performing work in the vicinity of the Redevelopment Project Area including, but not limited to, Redeveloper's scheduling of its work to provide for a smooth sequence of operations. The Redeveloper will be solely responsible for payment of all construction costs for the Redeveloper Improvements as set forth in this Redevelopment Agreement.
Regulatory and Special Allocations Notwithstanding the provisions of Section 6.1:
(a) If there is a net decrease in Company Minimum Gain (determined according to Treasury Regulations Section 1.704-2(d)(1)) during any Fiscal Year, each Member shall be specially allocated income and gain for such Fiscal Year (and, if necessary, subsequent Fiscal Years) in an amount equal to such Member’s share of the net decrease in Company Minimum Gain, determined in accordance with Treasury Regulations Section 1.704-2(g). The items to be so allocated shall be determined in accordance with Treasury Regulations Sections 1.704-2(f)(6) and 1.704-2(j)(2). This Section 6.2(a) is intended to comply with the “minimum gain chargeback” requirement in Treasury Regulation Section 1.704-2(f) and shall be interpreted consistently therewith.
(b) Member Nonrecourse Deductions shall be allocated in the manner required by Treasury Regulations Section 1.704-2(i). Except as otherwise provided in Treasury Regulations Section 1.704-2(i)(4), if there is a net decrease in Member Nonrecourse Debt Minimum Gain during any Fiscal Year, each Member that has a share of such Member Nonrecourse Debt Minimum Gain shall be specially allocated income and gain for such Fiscal Year (and, if necessary, subsequent Fiscal Years) in an amount equal to that Member’s share of the net decrease in Member Nonrecourse Debt Minimum Gain. Items to be allocated pursuant to this paragraph shall be determined in accordance with Treasury Regulations Sections 1.704-2(i)(4) and 1.704-2(j)(2). This Section 6.2(b) is intended to comply with the “minimum gain chargeback” requirements in Treasury Regulations Section 1.704-2(i)(4) and shall be interpreted consistently therewith.
(c) In the event any Member unexpectedly receives any adjustments, allocations or Distributions described in Treasury Regulations Section 1.704-1(b)(2)(ii)(d)(4), (5) or (6), income and gain shall be specially allocated to such Member in an amount and manner sufficient to eliminate the Adjusted Capital Account Deficit created by such adjustments, allocations or Distributions as quickly as possible. This Section 6.2(c) is intended to comply with the qualified income offset requirement in Treasury Regulations Section 1.704-1(b)(2)(ii)(d) and shall be interpreted consistently therewith.
(d) The allocations set forth in paragraphs (a), (b) and (c) above (the “Regulatory Allocations”) are intended to comply with certain requirements of the Treasury Regulations under Code Section 704. Notwithstanding any other provisions of this Article VI (other than the Regulatory Allocations), the Regulatory Allocations shall be taken into account in allocating Net Income and Net Losses among Members so that, to the extent possible, the net amount of such allocations of Net Income and Net Losses and other items and the Regulatory Allocations to each Member shall be equal to the net amount that would have been allocated to such Member if the Regulatory Allocations had not occurred.
(e) The Company and the Members acknowledge that allocations like those described in Proposed Treasury Regulation Section 1.704-1(b)(4)(xii)(c) (“Forfeiture Allocations”) result from the allocations of Net Income and Net Loss provided for in this Agreement. For the avoidance of doubt, the Company is entitled to make Forfeiture Allocations and, once required by applicable final or temporary guidance, allocations of Net Income and Net Loss shall be made in accordance with Proposed Treasury Regulation Section 1.704-1(b)(4)(xii)(c) or any successor provision or guidance.
Fire Department Service Charge We will pay up to $500 for your liability assumed by contract or agreement for fire department charges incurred when the fire department is called to save or protect covered property from a Peril Insured Against. We do not cover fire department service charges if the property is located within the limits of the city, municipality or protection district furnishing the fire department response. This coverage is additional insurance. No deductible applies to this coverage.
COSTS DISTRIBUTED THROUGH COUNTYWIDE COST ALLOCATIONS The indirect overhead and support service costs listed in the Summary Schedule (attached) are formally approved as actual costs for fiscal year 2022-23, and as estimated costs for fiscal year 2024-25 on a “fixed with carry-forward” basis. These costs may be included as part of the county departments’ costs indicated effective July 1, 2024, for further allocation to federal grants and contracts performed by the respective county departments.
Construction With Other Parts Of The Tariff This ISA shall not be construed as an application for service under Part II or Part III of the Tariff.
Servicing Agreement General Summary The Sellers and the Purchasers intend this Agreement to amend and restate that certain “Servicing Agreement,” dated March 23, 2021, for purposes of the Purchase Agreement and wish to set forth herein the terms upon which each Purchaser will, to the fullest extent permitted by applicable Law and the applicable Corporate Trust Contract, and subject to the applicable provisions of this Agreement, assume the responsibility (as agent of the applicable Seller) to supervise, manage, administer and otherwise discharge the duties of the applicable Seller in a Corporate Trust Capacity under (a) any Restricted Appointment and (b) any Excluded Appointment (collectively, the “Serviced Appointments”), and the Purchasers will discharge and perform when due, and indemnify the Sellers for, the Assumed Servicing Liabilities.
Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.
