Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.
Shift Schedule The words "shift schedule" when used in this Agreement shall mean a timetable of the shifts and off days assigned to a position or group of positions which commences at the beginning of a pay period and includes one complete rotation of said shifts.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Tariff Elimination 1. Except as otherwise provided in this Agreement, no Party may increase any existing customs duty, or adopt any new customs duty, on an originating good.
Evaluation Schedule CLIENT REFERENCES The Tenderer shall provide details of his performance on each of the previous projects listed in the “Relevant Experience” returnable schedule. “Client Reference Scorecards” will be completed by each of the respective Clients for the projects listed in the “Relevant Experience” returnable schedule. The following are to be completed by the Client and Principal Agent and is to be supported in each case by a letter of award and the works completion certificate. Both Client and Principal Agent must sign and stamp the documents, failure to obtain both signatures and stamps will result in no allocation of points. PROJECT NAME and SCOPE OF WORK: Principal agent: ................................................................................................................................. Client: .. ..............................................................................................................................................
Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement.
Compensation Schedule Except as otherwise provided herein, employees shall be compensated within the pay range assigned to the classification of the position in which they are employed and in accordance with the pertinent conditions of employment enumerated in this Agreement. Sec. 503 REGULAR PAY DAY: Employees shall be paid on or about the Friday following the end of the biweekly payroll period.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Escrow Format Specification 3.1. Deposit’s Format. Registry objects, such as domains, contacts, name servers, registrars, etc. will be compiled into a file constructed as described in draft-xxxxx-xxxxxxx-registry-data-escrow, see Part A, Section 9, reference 1 of this Specification and draft-xxxxx-xxxxxxx-dnrd-objects-mapping, see Part A, Section 9, reference 2 of this Specification (collectively, the “DNDE Specification”). The DNDE Specification describes some elements as optional; Registry Operator will include those elements in the Deposits if they are available. If not already an RFC, Registry Operator will use the most recent draft version of the DNDE Specification available at the Effective Date. Registry Operator may at its election use newer versions of the DNDE Specification after the Effective Date. Once the DNDE Specification is published as an RFC, Registry Operator will implement that version of the DNDE Specification, no later than one hundred eighty (180) calendar days after. UTF-8 character encoding will be used.
RDO Schedule a) The Schedule of RDO’s to be observed each year will generally be as provided under the VBIA.
