DBI Review – Complete Construction Documents Application Sample Clauses

DBI Review – Complete Construction Documents Application. In accordance with the ICA, DBI shall provide final comments on each Complete Construction Documents Application, including changes responding to comments received from the Authority and City Agencies or others during the 30-day Authority and City Agency review period, within sixty (60) days (for Applications pertaining to buildings seventy (70) feet in height and under) or within eighty (80) days (for Applications pertaining to buildings over seventy (70) feet in height) following the Complete Application Delivery Date. Notwithstanding the foregoing, if one or more Vertical Developers (including Developer acting as a Vertical Developer), submits a subsequent Complete Construction Documents Application for a different Lot within fifteen (15) days of the date of submittal of a previous Construction Documents Application, then DBI shall be entitled to an additional fifteen (15) days to review and determine whether additional application materials are required to complete its review for purposes of establishing the Complete Application Delivery Date. Any such extension shall not be the basis for Excusable Delay. In its comments on the Construction Documents Application, DBI may propose changes to the Construction Documents Application that do not conflict with the Redevelopment Requirements. If DBI proposes any such changes, then DBI, the Authority and Vertical Developer shall promptly meet and confer in good faith for a period of not more than thirty (30) days, as such period may be extended by mutual agreement, to reach agreement on any such changes proposed by DBI; provided such meet and confer period shall run concurrently with, and shall not extend, the sixty (60) and eighty (80) day period specified above (as extended for multiple Applications as set forth above) unless agreed to by Developer, DBI and Authority Staff. Vertical Developer shall have the right at any time after such period has run to require that DBI and the Executive Director consider the submitted Complete Construction Documents Application. Within thirty (30) days after the close of the periods described above in this Section 7.4.2, DBI and the Executive Director shall take action on each Complete Construction Documents Application in accordance with the standards in Section 7.4.3.
Sample 1
AutoNDA by SimpleDocs

Related to DBI Review – Complete Construction Documents Application

  • Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.

  • Construction Documents Phase Bidding or Negotiation Phase:

  • Construction Documents The architectural and engineering documents setting forth the design for the Project prepared by the Design Professional. Construction Documents include, but are not limited to, the Specifications, the Drawings, the Supplementary Conditions, the General Conditions, and all Addenda.

  • REVIEW OF CONTRACT DOCUMENTS 4.2.1 The Contractor shall carefully study and compare the Contract Documents and shall immediately report in writing to the Architect and the State any error, inconsistency or omission he may discover. The Contractor shall not be liable to the State or the Architect for any damage resulting from any such errors, inconsistencies or omissions in the Contract Documents. The

  • Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Copies of Contract Documents to Contractor Without charge to the Contractor the Design Professional shall furnish to the Contractor up to five sets of completed Contract Documents in hardcopy, one set of reproducible and electronic background floor and reflected ceiling plan drawings and, if requested, one copy in read-only electronic format. The Contractor may obtain such additional sets of Contract Documents, as the Contractor deems necessary and shall pay the cost of reproduction of such additional sets to the Design Professional.

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!