Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.
Damage Limitation IN NO EVENT SHALL THE COMPANY BE LIABLE TO THE SUBSCRIBER FOR ANY LOST PROFITS OR SPECIAL, CONSEQUENTIAL OR PUNITIVE DAMAGES, EVEN IF INFORMED OF THE POSSIBILITY OF SUCH DAMAGES. THE FOREGOING SHALL BE INTERPRETED AND HAVE EFFECT TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, RULE OR REGULATION.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
B. Such liquidated damages shall be calculated as an amount equaling the difference between:
1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and
2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract.
C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.
Liability Limitation Subsequent to the issuance of a Certificate of Completion pursuant to this Agreement, Applicant shall be entitled to the Liability Limitation set forth at ECL § 27-1421, subject to the terms and conditions stated therein and to the provisions of 6 NYCRR §§ 375-1.9 and 375-3.9.
LIMITATION OF OUR LIABILITY We are not responsible or liable to you or any supplementary cardmember for: • any delay or failure by a merchant to accept the card, • goods and services you charge to your account, including any dispute with a merchant about goods and services charged to your account, • any costs, damages or expenses arising out of our failure to carry out our obligations under this agreement if that failure is caused by a third party or because of a systems failure, data processing failure, industrial dispute or other action outside our control, and • loss of profits or any incidental, indirect, consequential, punitive or special damages regardless of how they arise. For example, we will not be liable to you or any supplementary cardmember for any malfunction or failure of the card or refusal by a merchant to accept the card. Clause required under the Consumer Protection Act. (Open credit contract for the use of a credit card)
Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.]
19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor:
12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims.
12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University.
12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,
Liability Limitations This paragraph limits the liabilities arising under this Agreement or any SOW and is a bargained-for and material part of our business relationship with you. You acknowledge and agree that Verticomm would not enter into any SOW or this Agreement unless Verticomm could rely on the limitations described in this paragraph. In no event shall either party be liable for any indirect, special, exemplary, consequential, or punitive damages, such as lost revenue, loss of profits (except for fees due and owing to Verticomm), savings, or other indirect or contingent event-based economic loss arising out of or in connection with this Agreement, any SOW, or the Services, or for any loss or interruption of data, technology or services, or for any breach hereof or for any damages caused by any delay in furnishing Services under this Agreement or any SOW, even if a party has been advised of the possibility of such damages; however, reasonable attorneys’ fees awarded to a prevailing party (as described below), your indemnification obligations, and any amounts due and payable pursuant to the non-solicitation provision of this Agreement shall not be limited by the foregoing limitation. Except for the foregoing exceptions, a responsible party’s (“Responsible Party’s”) aggregate liability to the other party (“Aggrieved Party”) for damages from any and all claims or causes whatsoever, and regardless of the form of any such action(s), that arise from or relate to this Agreement (collectively, “Claims”), whether in contract, tort, indemnification, or negligence, shall be limited solely to the amount of the Aggrieved Party’s actual and direct damages, not to exceed the amount of fees paid by you (excluding hard costs for licenses, hardware, etc.) to Verticomm for the specific Service upon which the applicable claim(s) is/are based during the three (3) month period immediately prior to the date on which the cause of action accrued. The foregoing limitations shall not apply to the extent that the Claims are caused by a Responsible Party’s willful or intentional misconduct, or gross negligence. Similarly, a Responsible Party’s liability obligation shall be reduced to the extent that a Claim is caused by, or the result of, the Aggrieved Party’s willful or intentional misconduct, or gross negligence.
OUR LIABILITY FOR FAILURE TO STOP PAYMENT If You order Us to place a stop payment on one of Your pre-authorized payments 3 business days or more before the transfer is scheduled, and We do not do so, We will be liable for losses or damages, to the extent provided by law. TRANSACTION SLIPS. Except for mail-in transactions and certain small-value transactions, You can get a receipt at the time You make any transaction to or from Your Account through the use of Your Card. When an electronic fund transfer has been made during any given month, You will receive a monthly statement to reflect all electronic fund transfers to or from Your Account during that statement period. In any case, You will receive a statement at least quarterly. FEES. We may assess reasonable charges against Your Account for transactions performed at electronic terminals. If so, We will specify any charges for these or other types of electronic transactions, including automatic transfers, on an accompanying pricing document. We will explain the charges to You when You open Your Account. You will be provided with a fee schedule, and other specified information after Your Account is established. Additional fee schedules are available at any of Our office locations. When You use an ATM not owned by Us, You may be charged a fee by the ATM operator, or any network used, and You may be charged a fee for a balance inquiry even if You do not complete a fund transfer.
Expenses; Indemnity; Damage Waiver (a) The Borrower shall pay (i) all reasonable out-of-pocket expenses incurred by the Administrative Agent, and its Affiliates, including the reasonable fees, charges and disbursements of counsel for the Administrative Agent in connection with the syndication of the credit facilities provided for herein, the preparation and administration of this Agreement or any amendments, modifications or waivers of the provisions hereof (whether or not the transactions contemplated hereby or thereby shall be consummated) and (ii) all reasonable out-of-pocket expenses incurred by the Administrative Agent or any Lender, including the fees, charges and disbursements of any counsel for the Administrative Agent or any Lender, in connection with the enforcement or protection of its rights in connection with this Agreement, including its rights under this Section, or in connection with the Loans made hereunder, including in connection with any workout, restructuring or negotiations in respect thereof including, without limitation, actions in connection with this Agreement or the Loans, arising, occurring or continuing subsequent to the Maturity Date (other than any such expenses directly related to a court enforcement action in which the Borrower prevails on the merits in a final and nonappealable judgment).
(b) The Borrower shall indemnify the Administrative Agent and each Lender, and each Related Party of any of the foregoing Persons (each such Person being called an "Indemnitee") against, and hold each Indemnitee harmless from, any and all losses, claims, damages, liabilities and related expenses, including the fees, charges and disbursements of any counsel for any Indemnitee, incurred by or asserted against any Indemnitee arising out of, in connection with, or as a result of (i) the execution or delivery of this Agreement or any agreement or instrument contemplated hereby, the performance by the parties hereto of their respective obligations hereunder or the consummation of the Transactions or any other transactions contemplated hereby, (ii) any Loan or the use of the proceeds therefrom, (iii) any actual or alleged presence or release of Hazardous Materials on or from any property owned or operated by the Borrower or any of its Subsidiaries, or any Environmental Liability related in any way to the Borrower or any of its Subsidiaries, or (iv) any actual or prospective claim, litigation, investigation or proceeding relating to any of the foregoing, whether based on contract, tort or any other theory and regardless of whether any Indemnitee is a party thereto; provided that such indemnity shall not, as to any Indemnitee, be available to the extent that such losses, claims, damages, liabilities or related expenses are determined by a court of competent jurisdiction by final and nonappealable judgment to have resulted from the gross negligence or wilful misconduct of such Indemnitee.
(c) To the extent that the Borrower fails to pay any amount required to be paid by it to the Administrative Agent under paragraph (a) or (b) of this Section, each Lender severally agrees to pay to the Administrative Agent such Lender's Applicable Percentage (determined as of the time that the applicable unreimbursed expense or indemnity payment is sought) of such unpaid amount; provided that the unreimbursed expense or indemnified loss, claim, damage, liability or related expense, as the case may be, was incurred by or asserted against the Administrative Agent in its capacity as such.
(d) To the extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement or any agreement or instrument contemplated hereby, the Transactions, any Loan or the use of the proceeds thereof.
(e) All amounts due under this Section shall be payable promptly after written demand therefor.
Violation; liability for unpaid wages; liquidated damages In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
