DELAY/DISRUPTION. The Contractor shall coordinate the DO work effort with the Maintenance Team, on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays in obtaining access to spaces and operation of equipment are to be expected. A minor delay is defined as eight (8) hours or less in duration. Minor delays and/or disruptions are considered normal rather than unusual occurrences during the performance of requirements ordered under this contract. If, during DO performance, delays greater than a minor delay indicated above are encountered, the Contractor shall immediately (verbally) notify the Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, and action taken to minimize impact.
DELAY/DISRUPTION. 10.1 The Contractor undertakes to use all reasonable endeavours to complete the works within a reasonable time. the Contractor shall incur no liability however for any delays or non-performance arising from force majeure, adverse weather conditions, strikes, lock-outs, war or other hostilities or any active event beyond his reasonable control in whole or in part.
DELAY/DISRUPTION. The contractor shall coordinate the work effort with the assigned Government Representative on a daily basis to prevent changing situations from causing delays and disruptions. Disruption due to minor delays is to be expected. A minor delay is defined as two hours or less per event. These disruptions are considered normal rather than unusual occurrences during the performance of tasks ordered under this contract. If, during contract performance, delays greater than two hours per event are encountered, the Contractor shall immediately verbally notify the assigned Government Representative and Contracting Officer, followed by a written statement within 24 hours after occurrence of delay, stating time of impact, reason for delay, duration of impact, number of people affected, action taken to properly schedule the work, action taken to minimize impact, and the names of Government person(s) contacted.
DELAY/DISRUPTION. The contractor shall coordinate the work effort on ordered tasks on a daily basis with Ship's Force to prevent changing situations on board ship causing delays and disruptions. Disruptions due to drills, shifting berths, inspections, delay in obtaining access, serving meals and operation of equipment are to be expected and are considered to be normal rather than unusual occurrences during the performance of work on tasks ordered under this contract.
DELAY/DISRUPTION. C.27.1. The Contractor shall coordinate the work effort with the maintenance team project manager daily to prevent changing situations from causing delays and disruptions. Disruption due to minor delays is to be expected.
