Delay due to reasons beyond the control of the Company Sample Clauses

Delay due to reasons beyond the control of the Company. If, however, the completion of the said Building/ said Complex is delayed by reason of non- availability of steel and/ or cement or other building materials or water supply or electric power, man power or slow down, strike or due to dispute with the construction agency(ies) employed by the Company, lock-out or civil commotion, by reason of war or enemy action or terrorist action or earthquake or any act of God or if non-delivery for possession is as a result of any Act, Notice, Order, Rule or Notification of the Government and/ or any other Public or Competent Authority or due to delay in sanction of building/ zoning plans/ grant of completion/ occupation certificate by any Competent Authority or for any other reasons beyond the control of the Company then the Allottee agrees that the Company shall be automatically entitled to the extension of time for delivery of possession of the said Apartment. The Company as a result of such a contingency arising reserves the right to alter or vary the terms and conditions of this Agreement or if the circumstances beyond the control of the Company so warrant, the Company may suspend the Scheme for such period as it may consider expedient and the Allottee agrees not to claim compensation of any nature whatsoever (including the compensation stipulated in Clause (11.5) of this Agreement during the period of suspension of the Scheme).
Sample 1
AutoNDA by SimpleDocs

Related to Delay due to reasons beyond the control of the Company

  • Parental Leave Beyond Thirty Seven (37)

  • Termination Due To Lack of Funds a. In the event funds to finance this Contract become unavailable, the Department may terminate the Contract upon no less than twenty-four (24) hours written notice to the Vendor. Said notice shall be delivered by certified mail, return receipt requested, or in person with proof of delivery. The Department shall be the final authority as to the availability of funds.

  • Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.

  • Factors Beyond the HSP’s Control Despite the foregoing, if the Funder, acting reasonably, determines that the Performance Factor is, in whole or in part, a Factor Beyond the HSP’s Control:

  • Drawings Submitted During the Contract Term Where required to develop maintain and deliver diagrams or other technical schematics regarding the scope of work, Contractor shall do so on an ongoing basis at no additional charge, and must, as a condition of payment, update drawings and plans during the Contract term to reflect additions, alterations, and deletions. Such drawings and diagrams shall be delivered to the Authorized User’s representative.

  • Events Beyond Our Control If an Event Beyond Our Control occurs and prevents Us from performing any of Our obligations under this Contract to any extent, then We are not required to perform that obligation to the extent and for as long as We are prevented by that Event Beyond Our Control. If such an Event Beyond Our Control occurs and We consider it appropriate to do so, We may notify You of the Event Beyond Our Control by any reasonable means, including by a public announcement.

  • What Will Happen After We Receive Your Letter When we receive your letter, we must do two things:

  • Happen After We Receive Your Letter When we receive your letter, we must do two things:

  • REAPPOINTMENT AFTER ABSENCE DUE TO CHILDCARE a) Employees who resign to care for a dependent pre-school child or children may apply to their former employer for preferential appointment to a position which is substantially the same in character and at the same or lower grading as the position previously held.

  • Leave Without Pay for the Care and Nurturing of Pre-School Age Children Subject to operational requirements, an employee shall be granted leave without pay for the personal care and nurturing of the employee's pre-school age children in accordance with the following conditions:

Time is Money Join Law Insider Premium to draft better contracts faster.