DELAYS AND EXTENSIONS OF TIME. § 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by (1) an act or neglect of the Owner or Architect, of an employee of either, or of a Separate Contractor; (2) by changes ordered in the Work;
Appears in 4 contracts
Samples: www.kgbak.us, go.boarddocs.com, www.bigskyeconomicdevelopment.org
DELAYS AND EXTENSIONS OF TIME. § §8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work work by (1) an act or neglect of the Owner or Architect/Engineer, or of an employee of either, or of a Separate Contractor; (2) separate contractor employed by Owner, or by changes ordered in the Work;, or by industry-wide labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond Contractor’s control, or by delay authorized by Owner pending mediation and arbitration, then the following shall apply:
Appears in 2 contracts
Samples: County Services Contract Contract, Recording Stamp Only
DELAYS AND EXTENSIONS OF TIME. § 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by (1) an the negligence or other improper act or neglect of the Owner or the Architect, of an or by any employee of either, or of a Separate Contractor; (2) by any separate contractor employed by the Owner, or by changes ordered in the Work;, or by any other cause that the Owner determines may justify the delay, then the completion date shall be extended by Change Order for such reasonable time as the Owner may determine.
Appears in 2 contracts
Samples: Large Construction Agreement, Construction Agreement
DELAYS AND EXTENSIONS OF TIME. § 8.3.1 If the Contractor is delayed at any time in the commencement or progress of the Work by (1) an act or neglect of the Owner or the Architect, of an employee of either, or of a Separate Contractor; (2) by changes ordered in the Work;
Appears in 1 contract
Samples: resources.finalsite.net
DELAYS AND EXTENSIONS OF TIME. § 8.3.1 If the Contractor is delayed at any time in the commencement or progress in performing work that is critical to overall completion of the Work by (1) an act or neglect of the Owner or Architect, of an employee of either, or of a Separate Contractorseparate contractor employed by the Owner; (2) Owner, or by changes ordered in the Work;; or by labor disputes, fire, unusual delay in
Appears in 1 contract
Samples: www.boarddocs.com