Delays by Buyer Sample Clauses

Delays by Buyer. If for any reason Buyer delays or postpones Buyer’s or Seller’s performance, including without limitation, delays in the manufacture, procurement or delivery of the building or structure or Special Products, the order shall be subject to re-costing to include the Increased Costs that occur or are incurred after the Acceptance Date. Xxxxx specifically acknowledges and agrees that it shall pay Seller all Increased costs as a part of this Contract when such Increased Costs are confirmed in writing by Seller and the Total Purchase Price for the order shall be deemed increased by the amount of all Increased Costs. Without limiting or waiving the remedies or rights available to Seller under Section 3(A) or(3)(C) hereof or any other provision of this Contract, if Buyer does not, within, seven (7) days of receipt of notice from Seller accept the delivery of the building or structure or the other goods ordered hereunder on the delivery date or during the delivery period scheduled by Seller, (i) any future delivery date requested by Buyer shall be subject to Seller’s schedule at the time of request by Xxxxx (and Seller may therefore need to postpone delivery from Buyer’s desired rescheduled date), and (ii) after such future delivery date is rescheduled by Seller, Seller may notify Buyer of any Increased Costs that are due to the Buyer’s delay or postponement of its or Seller’s performance and Xxxxx agrees that it shall pay Seller all Increased Costs upon demand. Buyer specifically acknowledges and agrees that Seller will not under any circumstances ship or deliver the building or structure or any ordered goods to Buyer until all Increased Costs and other increases, amounts, costs, and charges due to Seller, whether by reason of re-costing, Buyer’s delay, Change Orders, changes to drawings, or increases due under any provision of this Contract, are first paid in full by Buyer to Seller in advance of shipment, such that the only amount to be due and payable COD upon delivery of the building or structure ordered hereunder is the original COD balance due on delivery set forth on the face of this Contract. Failure by Buyer to pay Increased Costs and all other increases, amounts, costs and charges described in this Section 21 shall be a Breach by Buyer of this Contract entitling Seller to the damages and remedies described in Sections 5 and 6 above, respectively.
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Delays by Buyer. In the event that Goods cannot be shipped to Buyer when ready due to any cause not attributable to Seller, upon notice to Buyer, Seller may ship such Goods to storage. If such Goods are placed in storage, including storage at the facility where manufactured, the following conditions shall apply: (i) all risk of loss or damage shall thereupon pass to Buyer; (ii) any amounts otherwise payable to Seller upon delivery shall be payable upon presentation of Seller’s invoice; (iii) the Goods shall be deemed as shipped and the warranty time period shall commence; (iv) all expenses incurred by Seller, such as preparation for and placement into storage, handling, inspection, preservation, insurance, storage and removal charges and any taxes shall be payable by Buyer; and (v) when conditions permit and upon payment of all amounts due hereunder, Seller shall resume delivery of Goods to the originally agreed point of delivery.
Sample 1

Related to Delays by Buyer

  • Deliveries by Buyer At the Closing, Buyer shall deliver to Seller the following:

  • Deliveries by Seller At the Closing, Seller shall deliver, or cause to be delivered, to Buyer the following:

  • Indemnity by Buyer Buyer shall release, indemnify and hold harmless Seller, its directors, officers, agents, and representatives against and from any and all loss, Claims, actions or suits, including costs and attorney’s fees resulting from, or arising out of or in any way connected with the Product delivered by Seller under this Agreement after the Delivery Point, including any loss, Claim, action or suit, for or on account of injury to, bodily or otherwise, or death of persons, or for damage to or destruction of property belonging to Buyer, Seller, or others, excepting only such loss, Claim, action or suit as may be caused solely by the willful misconduct or gross negligence of Seller, its Affiliates, or Seller’s and Affiliates’ respective agents, employees, directors or officers.

  • Seller’s Remedies If Purchaser fails to perform its obligations pursuant to this Contract at or prior to Closing for any reason except failure by Seller to perform hereunder, or if prior to Closing any one or more of Purchaser's representations or warranties are breached in any material respect, and this failure or breach is not cured within three (3) Business Days after written notice from Seller to Purchaser (other than failure to close for any reason unrelated to a default by Seller, for which there shall be no notice or cure period), then Seller, as its SOLE and EXCLUSIVE remedy (except as provided in Sections 6(c) and 9), may (i) terminate this Contract and receive the Xxxxxxx Money as liquidated damages and not as penalty, in full satisfaction of claims against Purchaser hereunder, or (ii) waive Purchaser’s failure or breach and proceed to Closing. Seller and Purchaser agree that Seller's damages resulting from Purchaser's default are difficult, if not impossible, to determine, and the Xxxxxxx Money is a fair estimate of those damages and has been agreed to in an effort to cause the amount of damages to be certain. Notwithstanding anything in this Section 11(a) to the contrary, in the event of Purchaser's default or termination of this Contract, Seller shall have all remedies available at law or in equity if Purchaser or any party related to or affiliated with Purchaser is asserting any claims or right to the Property that would otherwise delay or prevent Seller from having clear, indefeasible and marketable title to the Property other than as a result of Purchaser’s exercise of its remedies under subsection (b) hereof. If Closing is consummated, then Seller shall have all remedies available at law or in equity if Purchaser fails to perform any post-closing obligation of Purchaser under this Contract.

  • Buyer’s Remedies If the Closing has not occurred due to a breach by Seller in any material respect any of its obligations or representations or warranties contained in this Agreement, or if Seller fails to consummate this Agreement for any reason other than Buyer's default or the permitted termination of this Agreement by Seller or Buyer as herein expressly provided, Buyer shall be entitled, as its sole remedy, either (a) to terminate this Agreement and receive the return of the entire Deposit (including both the First Deposit and Second Deposit, and whether or not the Inspection Period was extended), which return shall operate to terminate this Agreement and release Seller from any and all liability hereunder, or (b) to enforce specific performance of Seller's obligation to execute the documents required to convey the Property to Buyer, it being understood and agreed that the remedy of specific performance shall not be available to enforce any other obligation of Seller hereunder. Buyer shall be deemed to have elected to terminate this Agreement (as provided in subsection (a) above) if Buyer fails to file a cause of action for specific performance against Seller on or before ninety (90) days after written notice of termination from Seller or ninety (90) days after the originally scheduled Closing Date, whichever shall occur first. If specific performance is not available due to the fact that Seller has conveyed the Property to a third party, then upon termination of this Agreement by Buyer, in addition to receiving the immediate return of the Deposit, anything in the Agreement contained to the contrary notwithstanding, Buyer shall also receive from Seller, upon demand, Buyer’s actual, documented out-of-pocket costs and expenses associated with conducting its due diligence related to the Property; provided, however, Seller’s maximum reimbursement liability with respect to the foregoing shall not exceed $300,000.00. The rights and remedies of this Article VI shall survive Closing or any termination of this Agreement. THE FOREGOING REMEDIES ARE IN ADDITION TO AND ARE NOT INTENDED TO LIMIT SELLER'S OR BUYER’S INDEMNITY OBLIGATIONS UNDER OTHER SECTIONS HEREOF.

  • Contractor’s Remedies If the State is in breach of any provision of this Contract and does not cure such breach, Contractor, following the notice and cure period in §14.B and the dispute resolution process in §16 shall have all remedies available at law and equity. If a Purchasing Entity is in breach of a provision of an Order, Contractor shall have all remedies available to it under that Order and available at law and equity.

  • Purchaser’s Remedies If Seller fails to perform its obligations pursuant to this Agreement for any reason except failure by Purchaser to perform its obligations hereunder, or if before Closing any one or more of Seller’s representations or warranties are breached in any material respect, and such failure (other than the failure to sell the Property when it is obligated to do so under the terms of this Agreement) is not cured within one (1) Business Day after written notice from Purchaser, then Purchaser may, as its sole and exclusive remedy, either: (i) terminate this Agreement by giving Seller timely written notice of its election before or at Closing and recover the Xxxxxxx Money and Seller shall reimburse Purchaser for Purchaser’s out-of-pocket expenses not to exceed Fifty Thousand and No/100 Dollars ($50,000.00); (ii) enforce specific performance of Seller’s obligations under this Agreement; or (iii) waive Seller’s failure or breach and proceed to Closing. Notwithstanding anything herein to the contrary, Purchaser shall be deemed to have elected to terminate this Agreement if Purchaser fails to deliver to Seller written notice of its intent to file a claim or assert a cause of action for specific performance against Seller on or before ten (10) Business Days following the scheduled Closing Date or, having given that notice, fails to file a lawsuit asserting the claim or cause of action in Salt Lake County, Utah, within thirty (30) days following the scheduled Closing Date. Unless Purchaser in good faith either (1) disputes an allegation of Purchaser’s default and promptly files suit for declaratory judgment or (2) alleges a Seller default that continues after the notice and cure period set forth above and timely files suit for specific performance and the action is pending, Purchaser may not place a lis pendens against all or any portion of the Property unless such lis pendens is in connection with the suit for specific performance, and Purchaser hereby waives and releases any right it may have under applicable law to file any lis pendens. In no event or circumstance shall Purchaser be entitled to any consequential, special or punitive damages. Purchaser’s remedies shall be limited to those described in this Section 11(b). The provisions of this Section 11(b) shall survive the Closing or any termination of this Agreement.

  • LIABILITY FOR FAILURE TO COMPLETE TRANSACTIONS If We do not properly complete a transaction to or from Your Account according to this Agreement, We will be liable for Your losses or damages. However, We will not be liable if: (a) Your Account does not contain enough available funds to make the transaction through no fault of Ours; (b) the ATM where You are making the transfer does not have enough cash; (c) the terminal was not working properly and You knew about the breakdown when You started the transaction; (d) circumstances beyond Our control prevent the transaction despite reasonable precautions that We have taken; (e) Your Card is retrieved or retained by an ATM;

  • Use of Roads by Purchaser Except as provided herein, Purchaser is authorized to use existing National Forest system roads and Specified Roads listed in A7, when Forest Service determines that such use will not cause damage to the roads or National Forest re- sources. If Purchaser’s use of an existing temporary or Na- tional Forest system road, not listed in A7, cannot be sat- isfactorily accommodated without reconstruction, Pur- chaser shall be authorized to use such road upon agree- ment as to the minimum reconstruction work that Pur- chaser shall perform before hauling. When appropriate, such road shall be included in A7 as an alternate facility under B5.26.

  • Our Liability for Failure to Complete Transactions If we do not properly complete a transaction from your Card on time or in the correct amount according to our Agreement with you, we will be liable for your losses or damages. However, there are some exceptions. We will not be liable, for instance:

Time is Money Join Law Insider Premium to draft better contracts faster.