Delays, Penalties Sample Clauses

Delays, Penalties. The Supplier undertakes to immediately inform SEPHORA of any event which is likely to result in a delay in delivering the products and/or in performing the services in relation to the deadline mentioned in the purchase order. The Supplier undertakes to implement any means to make up for this delay, at its own cost, being agreed that SEPHORA can demand an express shipment at the Supplier’s own cost. In the event of a delay in delivery, SEPHORA reserves the right to apply a penalty of 100 euros per reference item ordered plus 0.2 % per day of delay calculated on the total amount of the purchase order excluding VAT, without prejudice to any damages which SEPHORA may claim from the Supplier. Confidential 15 SEPHORA – MILK MAKEUP
AutoNDA by SimpleDocs
Delays, Penalties. 1. In case the Seller is in delay with delivery of any Component to the Buyer, the Buyer shall be entitled starting with the first day of the eleventh week of the delay to claim a contractual penalty against the Seller in the amount of 0.3% of the price of the undelivered Component for each commenced day of delay; such contractual penalty shall not exceed 20% of the price of the undelivered Component. 2. In case the Seller is in delay with rectifying defects, claimed by the Buyer during the warranty term, within the deadlines defined herein, the Seller shall starting with the first day of the fifth week of the delay pay a contractual penalty in the amount of 0.1% of the price of the defective Component for each commenced day of delay; such contractual penalty shall not exceed 10% of the price of the defective Component. 3. In case the Buyer is in delay with any payment due, the Buyer shall be obliged to pay late interest to the Seller in the amount specified by applicable legislation (Government Resolution No. 351/2013 Coll., as amended, or law replacing this resolution). 4. Contractual penalties shall be payable within 15 days of delivery of their enumeration by the other Party. Payment of contractual penalty does not prejudice the right to damages in the extent such damages exceed the amount of the contractual penalty. 5. The Buyer shall be entitled to unilaterally set off any contractual penalty against any payments invoiced by the Seller, even against those which have not become due yet.
Delays, Penalties. 1. In cases when the Seller is in delay with delivery of any Equipment to the Buyer within the deadlines specified herein, the Buyer shall be entitled to claim a contractual penalty against the Seller in the amount of 0.1% of the price of the undelivered Equipment for each commenced day of delay; such contractual penalty shall not exceed 10% of the price of the undelivered Equipment. 2. In cases when the Seller is in delay with rectifying defects, claimed by the Buyer during the warranty term, within the deadlines defined herein, the Seller undertakes to pay a contractual penalty in the amount of 0.1% of the price of such defective Equipment for each commenced day of delay; such contractual penalty shall not exceed 10% of the price of the defective Equipment. In cases when the Seller is in delay with rectifying defects or providing service during post-warranty or out-of-warranty service within the deadlines defined herein, the Seller undertakes to pay a contractual penalty in the amount of 0.01% of the price of such defective Equipment for each commenced day of delay, such contractual penalty shall not exceed 5% of the price of such Equipment. 3. In cases when the Buyer is in delay with payment of invoices, the Buyer shall be obliged to pay late interest to the Seller in the amount specified by applicable legislation (Government Resolution No. 351/2013 Coll., as amended, or law replacing this resolution). 4. Contractual penalties shall be payable within 15 days of delivery of the claim to the other Party. Payment of contractual penalty does not prejudice the right to damages in the extent such damages exceed the amount of contractual penalty. 5. The Buyer shall be entitled to unilaterally set off any contractual penalty against any payments invoiced by the Seller, even against those which have not become payable yet.
Delays, Penalties. 1. In case the Seller is in delay with due delivery of any Motion drive to the Place of Delivery within the deadline stipulated in Art. II.4, the Buyer shall be entitled to claim a contractual penalty against the Seller in the amount of 0.2% of the price of the undelivered Motion drive for each commenced day of delay; such contractual penalty shall not exceed 10% of the price of the undelivered Motion drive. If a Motion drive is delivered within the deadline stipulated in Art. II.4 hereof defective but is taken over despite defects in it (Art. 6.2), the contractual penalty does not apply if the defects are removed in time. 2. In case the Seller is in delay with removing a defect, the Seller shall pay a contractual penalty in the amount of 0.1% of the price of the defective Motion drive for each commenced day of delay; such contractual penalty shall not exceed 3% of the price of the defective Motion drive. 3. In case the Buyer is in delay with any payment due, the Buyer shall be obliged to pay late interest to the Seller in the amount specified by applicable legislation (Government Resolution No. 351/2013 Coll., as amended, or law replacing this resolution). 4. Contractual penalties shall be payable within 15 days from receipt of their enumeration by the other Party. Payment of contractual penalty does not prejudice the right to damages in the extent such damages exceed the amount of the contractual penalty. 5. The Buyer shall be entitled to unilaterally set off any contractual penalty against any payments invoiced by the Seller, even against those which have not become due yet.
Delays, Penalties. 1. In case the Seller is in delay with delivery of any Unit to the Buyer, the Seller shall pay to the Buyer a contractual penalty in the amount of FILL IN of the price of the undelivered Unit for each commenced day of delay; such contractual penalty shall not exceed 20% of the price of the undelivered Unit. 2. In case the Seller is in delay with rectifying defects, claimed by the Buyer during the warranty term, within the deadlines defined herein, the Seller shall pay to the Buyer a contractual penalty in the amount of FILL IN of the price of the undelivered Unit for each commenced day of delay; such contractual penalty shall not exceed 20% of the price of the undelivered Unit. 3. In case the Buyer is in delay with any payment due, the Buyer shall be obliged to pay late interest to the Seller in the amount specified by applicable legislation (Government Resolution No. 351/2013 Coll., as amended, or law replacing this resolution). 4. Contractual penalties shall be payable within 15 days of delivery of their enumeration by the other Party. Payment of contractual penalty does not prejudice the right to damages in the extent such damages exceed the amount of the contractual penalty. 5. The Buyer shall be entitled to unilaterally set off any contractual penalty against any payments invoiced by the Seller, even against those which have not become due yet.

Related to Delays, Penalties

  • Judgments; Penalties One or more fines, penalties or final judgments, orders or decrees for the payment of money in an amount, individually or in the aggregate, of at least Two Hundred Fifty Thousand Dollars ($250,000.00) (not covered by independent third-party insurance as to which liability has been accepted by such insurance carrier) shall be rendered against Borrower by any Governmental Authority, and the same are not, within ten (10) days after the entry, assessment or issuance thereof, discharged, satisfied, or paid, or after execution thereof, stayed or bonded pending appeal, or such judgments are not discharged prior to the expiration of any such stay (provided that no Credit Extensions will be made prior to the satisfaction, payment, discharge, stay, or bonding of such fine, penalty, judgment, order or decree);

  • CONTRACTUAL PENALTIES 1. Should the Accommodated Person fail to pay the price for the accommodation in the agreed amount, by the due date and under the correct variable symbol, he/she is obliged to pay interest on late payments under Section 10(2) of Act No. 176/2004 Coll., on the Disposal of the Property of Public Institutions and the Amendment to Act Xx. 000/0000 xx xxx Xxxxxxxx Xxxxxxx xx xxx Xxxxxx Xxxxxxxx, on the Slovak Forestry Chamber, as amended by Act No. 464/2002 Coll., as amended. In addition, he/she is obliged to pay a contractual penalty (even if the contractual obligations are breached not through a fault of the Accommodated Person, e.g., by error of the financial institution) in the amount of 0.3 % of the due amount for each day of delay. The agreement regarding the contractual penalty shall not affect the Landlord’s entitlement to demand compensation for damages. Both entitlements can be exercised by the Landlord concurrently. Both the contractual penalty and the interest on late payments are to be paid via a separate bank transfer to the Landlord’s account stated in Article I in the “Landlord” section hereof (separately from the price for the accommodation). 2. If the payment is to be searched for due to the incorrectly stated variable symbol, the Accommodated Person shall pay a contractual penalty amounting to EUR 5. 3. In the case of loss or theft of the accommodation card, the Accommodated Person shall pay the Landlord the sum for issuing a new card in the amount of EUR 13, and in the case of loss or theft of the key to the room, he/she shall pay the sum for making an extra key in the amount of EUR 20. The sum for issuing a new card and making an extra key is to be paid by the Accommodated person by a stand- alone wire transfer to the bank account of the Landlord provided in Article I, part “Landlord” of this Contract (separately from the price for accommodation and settlement of contractual penalties and default interest). The Landlord shall provide the Accommodated Person with a replacement key or a new accommodation ID only after the sum stipulated under this paragraph is paid. 4. In compliance with Section 544(1) of the Civil Code, the Accommodated Person is also obliged to pay the contractual penalty even though the Landlord did not incur any damage as a result of a breach of the obligations of the Accommodated Person.

  • Fines and Penalties Qwest shall be liable to pay to CLEC fines and penalties for resold services in accordance with the Commission's retail service requirements that apply to Qwest retail services, if any. Such credits shall be limited in accordance with the following: a) Qwest's fines and penalties paid to CLEC shall be subject to the wholesale discount; b) Qwest shall only be liable to provide fines and penalties in accordance with the resold services provided to CLEC. Qwest is not required to pay fines and penalties for service failures that are the fault of CLEC; c) Intentionally Left Blank. d) In no case shall Qwest's fines and penalties to CLEC exceed the amount Qwest would pay the Commission under the service quality plan, less any wholesale discount applicable to CLEC's resold services; and e) In no case shall Qwest be required to provide duplicate reimbursement or payment to CLEC for any service quality failure incident.

  • Submitting False Claims; Monetary Penalties The AOC shall be entitled to remedy any false claims, as defined in California Government Code section 12650 et seq., made to the AOC by the Contractor or any Subcontractor under the standards set forth in Government Code section 12650 et seq. Any Contractor or Subcontractor who submits a false claim shall be liable to the AOC for three times the amount of damages that the AOC sustains because of the false claim. A Contractor or Subcontractor who submits a false claim shall also be liable to the AOC for (a) the costs, including attorney fees, of a civil action brought to recover any of those penalties or damages, and (b) a civil penalty of up to $10,000 for each false claim.

  • - FINANCIAL PENALTIES By virtue of the Financial Regulation applicable to the general budget of the European Communities, any beneficiary declared to be in grave breach of his obligations shall be liable to financial penalties of between 2% and 10% of the value of the grant in question, with due regard for the principle of proportionality. This rate may be increased to between 4% and 20% in the event of a repeated breach in the five years following the first. The beneficiary shall be notified in writing of any decision by the Commission to apply such financial penalties.

  • Stipulated Penalties for Failure to Comply with Certain Obligations As a contractual remedy, the Friendship Entities and OIG hereby agree that failure to comply with certain obligations as set forth in this CIA may lead to the imposition of the following monetary penalties (hereinafter referred to as “Stipulated Penalties”) in accordance with the following provisions. 1. A Stipulated Penalty of $2,500 (which shall begin to accrue on the day after the date the obligation became due) for each day the Friendship Entities fail to establish and implement any of the following obligations as described in Sections III and IV: a. a Compliance Officer; b. a Compliance Committee; c. the Board of Directors compliance obligations and the engagement of a Compliance Expert, the performance of a Compliance Program Review and the preparation of a Compliance Program Review Report, as required by Section III.A.3.; d. the management certification obligations; e. a written Code of Conduct; f. written Policies and Procedures; g. the development and/or implementation of a Training Plan for the training of Covered Persons, Relevant Covered Persons, and Board Members; h. a risk assessment and internal review process as required by Section III.E; i. a Disclosure Program; j. Ineligible Persons screening and removal requirements; k. notification of Government investigations or legal proceedings; l. policies and procedures regarding the repayment of Overpayments; m. the repayment of Overpayments as required by Section III.I and Appendix B; n. reporting of Reportable Events; and o. disclosure of changes to business units or locations. 2. A Stipulated Penalty of $2,500 (which shall begin to accrue on the day after the date the obligation became due) for each day the Friendship Entities fail to engage and use an IRO, as required by Section III.D, Appendix A, or Appendix B. 3. A Stipulated Penalty of $2,500 (which shall begin to accrue on the day after the date the obligation became due) for each day the Friendship Entities fail to submit the Implementation Report or any Annual Reports to OIG in accordance with the requirements of Section V by the deadlines for submission. 4. A Stipulated Penalty of $2,500 (which shall begin to accrue on the day after the date the obligation became due) for each day the Friendship Entities fail to submit any Claims Review or Additional Items Review Report in accordance with the requirements of Section III.D and Appendix B. 5. A Stipulated Penalty of $1,500 for each day the Friendship Entities fail to grant access as required in Section VII. (This Stipulated Penalty shall begin to accrue on the date the Friendship Entities fail to grant access.) 6. A Stipulated Penalty of $50,000 for each false certification submitted by or on behalf of the Friendship Entities as part of their Implementation Report, any Annual Report, additional documentation to a report (as requested by the OIG), or otherwise required by this CIA. 7. A Stipulated Penalty of $1,000 for each day the Friendship Entities fail to comply fully and adequately with any obligation of this CIA. OIG shall provide notice to the Friendship Entities stating the specific grounds for its determination that the Friendship Entities have failed to comply fully and adequately with the CIA obligation(s) at issue and steps the Friendship Entities shall take to comply with the CIA. (This Stipulated Penalty shall begin to accrue 10 days after the date the Friendship Entities receive this notice from OIG of the failure to comply.) A Stipulated Penalty as described in this Subsection shall not be demanded for any violation for which OIG has sought a Stipulated Penalty under Subsections 1- 6 of this Section.

  • Payment of Stipulated Penalties EPA may send Purchaser a demand for stipulated penalties. The demand will include a description of the noncompliance and will specify the amount of the stipulated penalties owed. Purchaser may initiate dispute resolution under Section XIII regarding the demand. Purchaser shall pay the amount demanded or, if Purchaser initiates dispute resolution, the uncontested portion of the amount demanded, within 30 days after receipt of the demand. Purchaser shall pay the contested portion of the penalties determined to be owed, if any, within 30 days after the resolution of the dispute. Each payment for: (a) the uncontested penalty demand or uncontested portion, if late, and; (b) the contested portion of the penalty demand determined to be owed, if any, must include an additional amount for Interest accrued from the date of receipt of the demand through the date of payment. Purchaser shall make payment at xxxxx://xxx.xxx.xxx using the link for “EPA Miscellaneous Payments Cincinnati Finance Center,” including a reference to the CERCLA docket number and Site/Spill ID number listed in ¶ 92, and the purpose of the payment. Purchaser shall send a notice of this payment to DOJ and EPA. The payment of stipulated penalties and Interest, if any, does not alter any obligation by Purchaser under this Settlement. Nothing in this Settlement limits the authority of the United States: (a) to seek any remedy otherwise provided by law for Purchaser’s failure to pay stipulated penalties or interest; or (b) to seek any other remedies or sanctions available by virtue of Purchaser’s noncompliance with this Settlement or of the statutes and regulations upon which it is based including penalties under section 106(b) of CERCLA provided, however, that the United States may not seek civil penalties under section 106(b) for any noncompliance for which a stipulated penalty is provided herein, except in the case of a willful noncompliance with this Settlement or in the event that EPA assumes performance of a portion or all of the Work pursuant to ¶ 30 (Work Takeover). Notwithstanding any other provision of this Section, the United States may, in its unreviewable discretion, waive any portion of stipulated penalties that have accrued under this Settlement.

  • Penalties Business Associate understands that: (a) there may be civil or criminal penalties for misuse or misappropriation of PHI and (b) violations of this Agreement may result in notification by Covered Entity to law enforcement officials and regulatory, accreditation, and licensure organizations.

  • Civil Penalty ORLY shall issue two separate checks for a total amount of five hundred dollars ($500.00) as penalties pursuant to California Health & Safety Code § 25249.12 as follows: (a) one check made payable to the State of California’s Office of Environmental Health Hazard Assessment (OEHHA) in the amount of three hundred and seventy five dollars ($375.00), representing 75% of the total penalty; and (b) one check to Xxxx Xxxxxxx in the amount of one hundred and twenty five dollars ($125.00), representing 25% of the total penalty. Additionally, two separate 1099’s shall be issued for the above payments. The first 1099 shall be issued to OEHHA, PO Box 4010, Sacramento, CA 95184 (EIN: 00-0000000) in the amount of $375.00. The second 1099 shall be issued in the amount of $125.00 to Xxxx Xxxxxxx be addressed to Xxxx Xxxxxxx C/O Xxxxxx X. Xxxxxxxx, Law Corporation and shall be delivered to Xxxxxx X. Xxxxxxxx, Law Corporation, 0000 X. Xxxxxxxxx, #649, Manhattan Beach, CA 90266. At ORLY's request, Xxxxxxx'x counsel shall provide ORLY with a W-9 for Xxxxxxx prior to the Effective Date.

  • Interest; Penalties In the event the Company or any Sponsor Affiliate should fail to make any of the payments to the County required under this Fee Agreement, then the item or installment so in default shall continue as an obligation of the Company or such Sponsor Affiliate until the Company or such Sponsor Affiliate shall have fully paid the amount, and the Company and any Sponsor Affiliates agree, as applicable, to pay the same with interest thereon at a rate, unless expressly provided otherwise herein and in the case of FILOT payments, of 5% per annum, compounded monthly, to accrue from the date on which the payment was due and, in the case of FILOT payments, at the rate for non-payment of ad valorem taxes under State law and subject to the penalties the law provides until payment.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!