Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Child Abuse Reporting Requirement Grantee will:
Child Abuse Reporting Requirements A. Grantees shall comply with child abuse and neglect reporting requirements in Texas Family Code Chapter 261. This section is in addition to and does not supersede any other legal obligation of the Grantee to report child abuse.
General Program Requirements Subrecipient shall adhere, but not be limited to, the following requirements for all programs:
Forecasting Requirements 19.5.1 The Parties shall exchange technical descriptions and forecasts of their Interconnection and traffic requirements in sufficient detail necessary to establish the Interconnections necessary for traffic completion to and from all Customers in their respective designated service areas.
Trunk Forecasting Requirements 14.2.1 Initial trunk forecast requirements. At least ninety (90) days before initiating interconnection in a LATA, Alltel shall provide Verizon a two (2)-year traffic forecast that complies with the Verizon Interconnection Trunking Forecast Guide, as revised from time to time. This initial traffic forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Interconnection Trunk groups in the LATA over the next eight (8) quarters.
Requirement to Utilize HUB Compliance Reporting System Pursuant to Texas Administrative Code, Title 34, Part 1, Sections 20.285(f) and 20.287(b), TFC administers monthly administration HSP-PAR compliance monitoring through its HUB Compliance Reporting System commonly known as B2G. PSP and PSP’s subcontractors/subconsultants shall submit required PAR information into the B2G system. Any delay in the timely submission of PAR information into the B2G system will be treated as an invoicing error subject to dispute under Texas Government Code Section 2251.042.
Specification and Service Levels The Specification sets out the Services that the Contractor has undertaken to provide. The Specification includes Service Levels setting out particular levels of service that the Contractor has undertaken to meet.
Meteorological Data Reporting Requirement (Applicable to wind generation facilities only) The wind generation facility shall, at a minimum, be required to provide the Transmission Provider with site-specific meteorological data including: • Temperature (degrees Fahrenheit) • Wind speed (meters/second) • Wind direction (degrees from True North) • Atmosphere pressure (hectopascals) • Forced outage data (wind turbine and MW unavailability)
EDD Independent Subrecipient Reporting Requirements Effective January 1, 2001, the County of Orange is required to file in accordance with subdivision (a) of Section 6041A of the Internal Revenue Code for services received from a “service provider” to whom the County pays $600 or more or with whom the County enters into a contract for $600 or more within a single calendar year. The purpose of this reporting requirement is to increase child support collection by helping to locate parents who are delinquent in their child support obligations. The term “service provider” is defined in California Unemployment Insurance Code Section 1088.8, Subparagraph B.2 as “an individual who is not an employee of the service recipient for California purposes and who received compensation or executes a contract for services performed for that service recipient within or without the State.” The term is further defined by the California Employment Development Department to refer specifically to independent Subrecipients. An independent Subrecipient is defined as “an individual who is not an employee of the ... government entity for California purposes and who receives compensation or executes a contract for services performed for that ... government entity either in or outside of California.” The reporting requirement does not apply to corporations, general partnerships, limited liability partnerships, and limited liability companies. Additional information on this reporting requirement can be found at the California Employment Development Department web site located at xxxx://xxx.xxx.xx.xxx/Employer_Services.htm
