DELIVERY OF THE SAID APARTMENT Sample Clauses

DELIVERY OF THE SAID APARTMENT. 7.1 Schedule for delivery of the said Apartment:- The Promoter agrees and understands that timely delivery of possession of the said Apartment to the Allottee is the essence of the Agreement subject to full payment and compliance by the Allottee under this Agreement including as mentioned in Clause 7.1A below. The Promoter assures to hand over the said Apartment unless there is delay or failure due to war, floor, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”) or due to reasons beyond control. If, however, the completion of the Project is delayed due to Force Majeure conditions or due to reasons beyond control, then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the said Apartment Provided that such Force Majeure conditions or reasons are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall be terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the Allottee within 45 days from that date or within such further time as may be agreed between the parties. The Promoter shall intimate the Allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/she shall not have any rights, claims etc. whatsoever against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement and no other amount whatsoever shall be payable by the Promoter.
AutoNDA by SimpleDocs
DELIVERY OF THE SAID APARTMENT. 7.1 Schedule for delivery of the said Apartment:- The Promoter agrees and understands that timely delivery of possession of the said Apartment to the Allottee is the essence of the Agreement subject to full payment and compliance by the Allottee under this Agreement including as mentioned in Clause 7.1A below. The Promoter assures to hand over the said Apartment unless there is delay or failure due to unforeseen occurrences, acts, events, omissions or accidents which are beyond the reasonable control of the Vendors, including, without limitation, war, flood, drought, fire, cyclone, tsunami, earthquake, natural calamities, Acts of God, abnormally inclement weather, lightning, storms, tempests, explosion, subsidence, structural damage, epidemic or other natural physical disaster, or any other calamity caused by nature affecting the regular development of the real estate project, riots, crowd disorder, civil commotion, civil wars, air raids, military operations, strikes, lockouts, bandh or other like cause, civil/labor unrest, or other industrial action, terrorist action/threat, transport strikes, failure or shortage or non-availability of power supply, failure or shortage or non-availability of water supply, shortage or unavailability of construction materials including steel, cement, other building materials, etc., delays due to municipal elections, acquisitions, strike by material suppliers or transporters or contractors or workers and/or employees, requisitions, litigation, attachments, notices or prohibitory or injunction orders from Corporation or any other statutory body or any Court, tribunal, government action or regulations, new and/or changes in corporation or other rules, laws or policies affecting or likely to affect the Project, any notification, legislation, regulation, ruling, omissions, refusals or orders by Government or Court or tribunal or any relevant authorities including delay or failure to grant of electricity, water, sewerage and drainage connection or any other necessary permissions, approvals or sanctions (“Force Majeure”) or due to reasons beyond control. If, however, the completion of the Project is delayed due to Force Majeure conditions or due to reasons beyond control, then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the said Apartment Provided that such Force Majeure conditions or reasons are not of a nature which make it impossible for the contract to be imple...
DELIVERY OF THE SAID APARTMENT 

Related to DELIVERY OF THE SAID APARTMENT

  • Delivery of the Shares Delivery of the Firm Shares and the Optional Shares shall be made through the facilities of The Depository Trust Company unless the Representatives shall otherwise instruct. Time shall be of the essence, and delivery at the time and place specified in this Agreement is a further condition to the obligations of the Underwriters.

  • Delivery of the Securities The Company shall deliver, or cause to be delivered, to Banc of America Securities LLC for the accounts of the several Initial Purchasers certificates for the Securities at the Closing Date against the irrevocable release of a wire transfer of immediately available funds for the amount of the purchase price therefor. The certificates for the Securities shall be in such denominations and registered in the name of Cede & Co., as nominee of the Depository, pursuant to the DTC Agreement, and shall be made available for inspection on the business day preceding the Closing Date at a location in New York City, as the Initial Purchasers may designate. Time shall be of the essence, and delivery at the time and place specified in this Agreement is a further condition to the obligations of the Initial Purchasers.

  • Delivery of the Property The Fund will deliver or arrange for delivery to PFPC Trust, all the Property owned by the Portfolios, including cash received as a result of the distribution of Shares, during the term of this Agreement. PFPC Trust will not be responsible for any assets until actual receipt.

  • Delivery of the Shares and Payment Therefor Delivery to the Underwriters of the Firm Shares and payment therefor shall be made at the offices of Raymond James & Associates, Inc., 880 Carillon Parkway, St. Petersburg, Xxxxxdx xx 10:00 a.m., St. Peterxxxxx, Xxxxxxx xxxx, xxxx xxxxxxxx xxxx xxxxx the date of this Agreement (the "Closing Date"). The place of closing for the Firm Shares and the Closing Date may be varied by agreement between the Representatives and the Company. Delivery to the Underwriters of and payment for any Additional Shares to be purchased by the Underwriters shall be made at the offices of Raymond James & Associates, Inc., 880 Carillon Parkway, St. Petersburg, Xxxxxdx, xx 10:00 a.m., St. Petexxxxxx, Xxxxxxx xxxx, xx xxxx xxxx xx xxxxx (the "Additional Closing Date") (which may be the same as the Closing Date, but shall in no event be earlier than the Closing Date nor earlier than three nor later than ten business days after the giving of the notice hereinafter referred to) as shall be specified in a written notice, from the Representatives on behalf of the Underwriters to the Company, of the Underwriters' determination to purchase a number, specified in such notice, of Additional Shares. Such notice may be given at any time within 30 days after the date of the Prospectus. The place of closing for the Additional Shares and the Additional Closing Date may be varied by agreement between you and the Company. Certificates for the Firm Shares and for any Additional Shares to be purchased hereunder shall be registered in such names and in such denominations as you shall request prior to 1:00 p.m., St. Petersburg, Florida time, not later than the second full business day preceding the Closing Date or the Additional Closing Date, as the case may be. Such certificates shall be made available to you in St. Petersburg, Florida for inspection and packaging not later than 9:30 a.m., St. Petersburg, Florida time, on the business day immediately preceding the Closing Date or the Additional Closing Date, as the case may be. The certificates evidencing the Firm Shares and any Additional Shares to be purchased hereunder shall be delivered to you on the Closing Date or the Additional Closing Date, as the case may be, against payment of the purchase price therefore by wire transfer of immediately available funds to an account specified in writing, not later than the close of business on the business day next preceding the Closing Date or the Additional Closing Date, as the case may be, by the Company. Payment for the Shares sold by the Company hereunder shall be delivered by the Representatives via wire transfer to the Company. It is understood that the Representatives have been authorized, for their own account and the accounts of the several Underwriters, to accept delivery of and receipt for, and make payment of the purchase price per Share for the Firm Shares and the Additional Shares, if any, that the Underwriters have agreed to purchase. Raymond James and Associates, Inc., individually and not as Representaxxxxx xf xxx Underwriters, may, but shall not be obligated to, make payment for any Shares to be purchased by any Underwriter whose funds shall not have been received by the Representatives by the Closing Date or the Additional Closing Date, as the case may be, for the account of such Underwriter, but any such payment shall not relieve such Underwriter from any of its obligations under this Agreement.

  • Purchase, Sale and Delivery of the Shares (a) On the basis of the representations, warranties, covenants and agreements herein contained, but subject to the terms and conditions herein set forth, the Company agrees to sell to each Underwriter and each Underwriter, severally and not jointly, agrees to purchase from the Company, at a purchase price per share of $____, the number of Firm Shares set forth opposite their respective names on Schedule A hereto together with any additional number of Shares which such Underwriter may become obligated to purchase pursuant to the provisions of Section 10 hereof. (b) Payment of the purchase price for, and delivery of certificates representing, the Firm Shares shall be made at the offices of the Underwriters’ Counsel, 000 Xxxxxxxxx Xxxxxx, Xxx Xxxx, Xxx Xxxx 00000, or at such other place as shall be agreed upon by the Representatives and the Company, at 10:00 A.M., New York City time, on the third (3rd) or, as permitted under Rule 15c6-1 under the Exchange Act, fourth (4th) business day (unless postponed in accordance with the provisions of Section 10 hereof) following the date of the effectiveness of the Registration Statement, or such other time not later than ten (10) business days after such date as shall be agreed upon by the Representatives and the Company as permitted under Rule 15c6-1 under the Exchange Act (such time and date of payment and delivery being herein called the “Closing Date”). The closing of the payment of the purchase price for, and delivery of certificates representing, the Firm Shares is referred to herein as the “Closing.” (c) Payment of the purchase price for the Firm Shares shall be made by wire transfer in immediately available funds to or as directed by the Company upon delivery of certificates for the Firm Shares to the Representatives through the facilities of The Depository Trust Company for the respective accounts of the several Underwriters. Certificates for the Firm Shares shall be registered in such name or names and shall be in such denominations as the Representatives may request at least two (2) business days before the Closing Date. The Company will permit the Representatives to examine and package such certificates for delivery at least one (1) full business day prior to the Closing Date.

  • Issuance, Sale and Delivery of the Shares The Shares have been duly authorized and, when issued, delivered and paid for in the manner set forth in this Agreement, will be duly authorized, validly issued, fully paid and nonassessable, and will conform in all material respects to the description thereof set forth in the Private Placement Memorandum. No preemptive rights or other rights to subscribe for or purchase exist with respect to the issuance and sale of the Shares by the Company pursuant to this Agreement. No stockholder of the Company has any right (which has not been waived or has not expired by reason of lapse of time following notification of the Company's intent to file the Registration Statement) to require the Company to register the sale of any shares owned by such stockholder under the Securities Act of 1933, as amended (the "Securities Act"), in the Registration Statement. No further approval or authority of the stockholders or the Board of Directors of the Company will be required for the issuance and sale of the Shares to be sold by the Company as contemplated herein.

  • Delivery of the Premises When Landlord’s Work is Substantially Complete, subject to the remaining terms and provisions of this Section 3(e), Tenant shall accept the Premises. Tenant’s taking possession and acceptance of the Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any non-compliance of Landlord’s Work with applicable Legal Requirements, or (iii) any claim that Landlord’s Work was not completed substantially in accordance with the TI Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period, in which case Landlord shall have no further obligation with respect to such Construction Defect other than to cooperate, at no cost to Landlord, with Tenant should Tenant elect to pursue a claim against such contractor. Tenant shall be entitled to receive the benefit of all construction warranties and manufacturer’s equipment warranties relating to equipment installed in the Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and suppliers of such equipment, but the cost of any such extended warranties shall be borne solely out of the TI Fund. Landlord shall promptly undertake and complete, or cause to be completed, all punch list items.

  • Delivery of Services Axon personnel will work Monday through Friday, 8:30 a.m. to 5:30 p.m., except holidays. Axon will perform all on-site tasks over a consecutive timeframe. Axon will not charge Agency travel time by Axon personnel to Agency premises as work hours.

  • Delivery of the Purchase Price At least one business day prior to the effective date of the Company’s registration statement relating to the IPO (“Registration Statement”), or the date of the exercise of the Over-Allotment Option, if any, the Purchaser agrees to deliver the Initial Purchase Price or Additional Purchase Price, as the case may be, by certified bank check or wire transfer of immediately available funds denominated in United States Dollars to Continental Stock Transfer & Trust Company, a New York corporation (“CST”), which is hereby irrevocably authorized to deposit such funds on the applicable Closing Date to the trust account which will be established for the benefit of the Company’s public shareholders, managed pursuant to that certain Investment Management Trust Agreement to be entered into by and between the Company and CST and into which substantially all of the proceeds of the IPO will be deposited (the “Trust Account”). If the IPO is not consummated within 14 days of the date the Initial Purchase Price is delivered to CST, the Initial Purchase Price shall be returned to the Purchaser by certified bank check or wire transfer of immediately available funds denominated in United States Dollars, without interest or deduction.

  • Delivery of Software 1. SAP will deliver the Software as described in the Documentation and the Price List and will also provide the appropriate license key for the relevant End User. With regard to the features, quality and functionality of the Software the product description in the Documentation and the Price List is solely decisive. SAP does not own any additional features, quality or functionality. Distributor can, in particular, not assert any additional feature, quality or functionality from any public statements, publications or advertisements by SAP except to the extend SAP has expressly confirmed such additional feature, quality or functionality in writing. Any representation, warranty, undertaking or guarantee regarding additional features, quality or functionality is effective only if expressly confirmed by SAP’s management in writing. 2. After acceptance of an order, SAP will deliver to Distributor one copy of the relevant Software: a) on discs or other data media (“Physical Shipment”); or b) by making it available for downloading through the internet (usually on the SAP ServiceMarket Place (xxxx://xxxxxxx.xxx.xxx/swdc)) (“Electronic Delivery”). 3. The relevant Software and Documentation will be deemed delivered (including but not limited for the purpose of fixed delivery dates or timely delivery) and the risk passes to Distributor: a) in case of Physical Shipment, when the relevant disc or other data media thereof is handed over to the freight carrier (FCA - Free Carrier (named place of delivery), Incoterms 2010); or b) in case of Electronic Delivery, when SAP has made an electronic copy thereof available for downloading and has informed Distributor accordingly, (“Delivery”). 4. Upon Distributor’s request or if stipulate in the order, SAP may agree to provide Software and/or the appropriate license key directly to the relevant Open Ecosystem Partner instead (“Open Ecosystem Partner Delivery”). In case of Open Ecosystem Partner Delivery, the provisions set out in this Article 5 (Delivery of Software) will apply analogously; delivery to Distributor will be deemed to occur upon Delivery to the Open Ecosystem Partner. 5. Upon Distributor’s request or if stipulate in the order, SAP may agree to provide Software and/or the appropriate license key directly to the relevant End User instead (“End User Delivery”). In case of End User Delivery, the provisions set out in this Article 5 (Delivery of Software) will apply analogously; delivery to Distributor will be deemed to occur upon Delivery to the End User. 6. SAP might be entitled to suspend the delivery of the Software, Maintenance Services, applicable license key or both to Distributor, Open Ecosystem Partner or End User or both as further set out in this Sell On Premise Distribution Model as well as the Distribution GTCS. 7. If Distributor receives a new copy of the Software, Documentation and/or other SAP Materials that replaces previously provided Software, Documentation and/or other SAP Materials, Distributor must distribute that newest copy provided and either destroy or upon SAP’s request return previous copies. 8. Distributor must not make the Software, Documentation and/or other SAP Materials available to the Open Ecosystem Partner or End User by any means other than by delivering the Software, Documentation and/or other SAP Materials as originally provided by SAP. Distributor’s right to pass on the Software, Documentation and/or other SAP Materials is subject to the provisions of this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!