Design Review
(a) Where so specified in Schedule A (Scope of Goods and Services) or as otherwise instructed by the City, the Supplier shall submit design-related Documentation for review by the City, and shall not proceed with work on the basis of such design Documentation until the City’s approval of such Documentation has been received in writing.
(b) None of:
(i) the submission of Documentation to the City by the Supplier;
(ii) its examination by or on behalf of the City; or
(iii) the making of any comment thereon (including any approval thereof) shall in any way relieve the Supplier of any of its obligations under this Agreement or of its duty to take reasonable steps to ensure the accuracy and correctness of such Documentation, and its suitability to the matter to which it relates.
Project Review A. Programmatic Allowances
1. If FEMA determines that the entire scope of an Undertaking conforms to one or more allowances in Appendix B of this Agreement, with determinations for Tier II Allowances being made by SOI-qualified staff, FEMA shall complete the Section 106 review process by documenting this determination in the project file, without SHPO review or notification.
2. If the Undertaking involves a National Historic Landmark (NHL), FEMA shall notify the SHPO, participating Tribe(s), and the NPS NHL Program Manager of the NPS Midwest Regional Office that the Undertaking conforms to one or more allowances. FEMA shall provide information about the proposed scope of work for the Undertaking and the allowance(s) enabling FEMA’s determination.
3. If FEMA determines any portion of an Undertaking’s scope of work does not conform to one or more allowances listed in Appendix B, FEMA shall conduct expedited or standard Section 106 review, as appropriate, for the entire Undertaking in accordance with Stipulation II.B, Expedited Review for Emergency Undertakings, or Stipulation II.C, Standard Project Review.
4. Allowances may be revised and new allowances may be added to this Agreement in accordance with Stipulation IV.A.3, Amendments.
B. Expedited Review for Emergency Undertakings
MOTION FOR PRELIMINARY APPROVAL The Parties agree to jointly prepare and file a motion for preliminary approval (“Motion for Preliminary Approval”) that complies with the Court’s current checklist for Preliminary Approvals.
Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.
Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
New Project Approval Consultant and District recognize that Consultant’s Services may include working on various projects for District. Consultant shall obtain the approval of District prior to the commencement of a new project.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Final Approval Hearing “Final Approval Hearing” shall mean the hearing at which the Court will consider and finally decide whether to enter the Final Judgment.
Review Scope The parties confirm that the Asset Representations Review is not responsible for (a) reviewing the Receivables for compliance with the representations and warranties under the Transaction Documents, except as described in this Agreement or (b) determining whether noncompliance with the representations and warranties constitutes a breach of the Eligibility Representations. For the avoidance of doubt, the parties confirm that the review is not designed to determine why an Obligor is delinquent or the creditworthiness of the Obligor, either at the time of any Asset Review or at the time of origination of the related Receivable. Further, the Asset Review is not designed to establish cause, materiality or recourse for any Test Fail (as defined in Section 3.05).
Preliminary Approval A. As soon as practicable after this Agreement is fully executed, for settlement purposes only, the Plaintiffs and Co-Lead Counsel shall request the Court to make preliminary findings, enter the Preliminary Approval Order granting conditional certification of the Class, subject to final findings and ratification in the Final Order and Judgment, and appoint the Plaintiffs as class representatives and Co-Lead Counsel as counsel for the Class. Neither Defendant nor Defendant’s Counsel will object to such requests for the purposes of effectuating the Settlement. Such agreement not to object to class certification shall extend only as necessary to effectuate the Settlement. As set forth in the draft Preliminary Approval Order, the Plaintiffs shall request the Court to enter an order:
1. preliminarily approving and finding this Agreement and the Settlement as being fair, reasonable, and adequate;
2. conditionally certifying the Litigation as a settlement class action under Rule 23(b)(3) and (e) of the Federal Rules of Civil Procedure;
3. appointing Plaintiffs as class representatives and Co-Lead Counsel as counsel for the Class;
4. preliminarily approving the form, manner, and content of the Class Notice, as provided herein, and finding that notice is fair, reasonable, and the best notice practicable under the circumstances in connection with notifying the Class Members of their rights and responsibilities under the Settlement and satisfying due process and Rule 23 of the Federal Rules of Civil Procedure;
5. appointing the Settlement Administrator to send Class Notice and administer the Settlement;
6. providing that Class Members will have until a date certain to object to or file a request for exclusion from the Settlement, as provided herein;
