Determination of Landlord Delay. If Tenant contends that a Landlord Delay has occurred, Tenant shall notify Landlord in writing of the event which constitutes such Landlord Delay. Such notice may be via electronic mail to Landlord's construction representative described below, provided that if Tenant notifies Landlord's construction representative via electronic mail, then Tenant must also deliver notice to Landlord's other notice addresses required under the Lease within one(1) Business Day after delivery of such electronic mail. Tenant will additionally use reasonable efforts to mitigate the effects of any Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If such actions, inaction or circumstance described in the Notice set forth in (i) above of this Section 5.2 of this Work Letter (the "Delay Notice") are not cured by Landlord within one (1) business day of Landlord's receipt of the Delay Notice and if such action, inaction or circumstance otherwise qualify as a Landlord Delay, then a Landlord Delay shall be deemed to have occurred commencing as of the date of Landlord's receipt of the Delay Notice and ending as of the date such delay ends; notwithstanding the foregoing, if, solely as a result of a Landlord Delay, and notwithstanding Tenant's mitigation efforts described above, the date of Substantial Completion of the Tenant Improvements is delayed for a longer period than the actual length of the Landlord Delay (due to the need to reschedule subcontractors or suppliers and/or resequence elements of work, or to other reasons arising as a result of such Landlord Delay to the extent each such reason was specifically described in the Delay Notice), then, for the purposes of determining the abatement to be afforded Tenant resulting from such Landlord Delay, the Landlord Delay will be deemed to be the number of days Tenant's Substantial Completion of the Tenant Improvements is delayed as a result of such Landlord Delay. If and to the extent Tenant incurs increased costs of design or construction of the Tenant Improvements as a direct result of any Landlord Delay, Landlord will be responsible for such increased costs.

Determination of Landlord Delay. If Tenant contends that a Landlord Delay has occurred, Tenant shall notify Landlord in writing of (i) the event which constitutes such Landlord Delay and (ii) the date upon which such Landlord Delay is anticipated to end. If such actions, inaction or circumstance described in the notice set forth in (i) above of this Section 5.2 of this Tenant Work Letter (the “Delay Notice”) are not cured by Landlord within two (2) business days of Landlord’s receipt of the Delay Notice and if such action, inaction or circumstance otherwise qualify as a Landlord Delay, then a Landlord Delay shall be deemed to have occurred commencing as of the date of Landlord’s receipt of the Delay Notice and ending as of the date such delay ends.

Determination of Landlord Delay. If Tenant contends that a Landlord Delay has occurred, Tenant shall notify Landlord in writing (the "Delay Notice") of the event which constitutes such Landlord Caused Date Delay. If such actions, inaction or circumstance described in the Delay Notice are not cured by Landlord within one (1) business day of Landlord’s receipt of the Delay Notice and if such action, inaction or circumstance otherwise qualify as a Landlord Delay, then a Landlord Delay shall be deemed to have occurred commencing as of the date of Landlord’s receipt of the Delay Notice and ending as of the date such delay ends.

Related to Determination of Landlord Delay

Definition of Landlord With regard to obligations imposed upon Landlord pursuant to this Lease, the term “Landlord,” as used in this Lease, shall refer only to Landlord or Landlord’s then-current successor-in-interest. In the event of any transfer, assignment or conveyance of Landlord’s interest in this Lease or in Landlord’s fee title to or leasehold interest in the Property, as applicable, Landlord herein named (and in case of any subsequent transfers or conveyances, the subsequent Landlord) shall be automatically freed and relieved, from and after the date of such transfer, assignment or conveyance, from all liability for the performance of any covenants or obligations contained in this Lease thereafter to be performed by Landlord and, without further agreement, the transferee, assignee or conveyee of Landlord’s in this Lease or in Landlord’s fee title to or leasehold interest in the Property, as applicable, shall be deemed to have assumed and agreed to observe and perform any and all covenants and obligations of Landlord hereunder during the tenure of its interest in the Lease or the Property. Landlord or any subsequent Landlord may transfer its interest in the Premises or this Lease without Tenant’s consent.
Exemption of Landlord from Liability Landlord shall not be liable for any damage or injury to the person, business (or any loss of income therefrom), goods, wares, merchandise or other property of Tenant, Tenant's employees, invitees, customers or any other person in or about the Property, whether such damage or injury is caused by or results from: (a) fire, steam, electricity, water, gas or rain; (b) the breakage, leakage, obstruction or other defects of pipes, sprinklers, wires, appliances, plumbing, air conditioning or lighting fixtures or any other cause; (c) conditions arising in or about the Property or upon other portions of the Project, or from other sources or places; or (d) any act or omission of any other tenant of the Project. Landlord shall not be liable for any such damage or injury even though the cause of or the means of repairing such damage or injury are not accessible to Tenant. The provisions of this Section 6.02 shall not, however, exempt Landlord from liability for Landlord's gross negligence or willful misconduct.
Limitation of Landlord’s Liability 35.1. If Landlord is in default under this Lease and, as a consequence, Tenant recovers a monetary judgment against Landlord, the judgment shall be satisfied only out of (a) the proceeds of sale received on execution of the judgment and levy against the right, title and interest of Landlord in the Building and the Project, (b) rent or other income from such real property receivable by Landlord or (c) the consideration received by Landlord from the sale, financing, refinancing or other disposition of all or any part of Landlord’s right, title or interest in the Building or the Project. 35.2. Landlord shall not be personally liable for any deficiency under this Lease. If Landlord is a partnership or joint venture, then the partners of such partnership shall not be personally liable for Landlord’s obligations under this Lease, and no partner of Landlord shall be sued or named as a party in any suit or action, and service of process shall not be made against any partner of Landlord except as may be necessary to secure jurisdiction of the partnership or joint venture. If Landlord is a corporation, then the shareholders, directors, officers, employees and agents of such corporation shall not be personally liable for Landlord’s obligations under this Lease, and no shareholder, director, officer, employee or agent of Landlord shall be sued or named as a party in any suit or action, and service of process shall not be made against any shareholder, director, officer, employee or agent of Landlord. If Landlord is a limited liability company, then the members of such limited liability company shall not be personally liable for Landlord’s obligations under this Lease, and no member of Landlord shall be sued or named as a party in any suit or action, and service of process shall not be made against any member of Landlord except as may be necessary to secure jurisdiction of the limited liability company. No partner, shareholder, director, employee, member or agent of Landlord shall be required to answer or otherwise plead to any service of process, and no judgment shall be taken or writ of execution levied against any partner, shareholder, director, employee, member or agent of Landlord. 35.3. Each of the covenants and agreements of this Article shall be applicable to any covenant or agreement either expressly contained in this Lease or imposed by Applicable Laws and shall survive the expiration or earlier termination of this Lease.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”): (i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord; (ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed; (iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord; (iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; (v) Construction of any Change Requests; (vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible); (vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; (viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; (ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or (x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Landlord’s Election Tenant’s request for consent to any Transfer shall he accompanied by a written statement setting forth the details of the proposed Transfer, including the name, business and financial condition of the prospective Transferee, financial details of the proposed Transfer (e.g., the term and the rent and security deposit payable), and any other related information that Landlord may reasonably require. Landlord shall have the right: (a) to withhold consent to the Transfer, if reasonable, (b) to grant consent, (c) to terminate this Lease as to the portion of the Premises affected by any proposed Transfer, in which event Landlord may enter into a lease directly with the proposed Transferee, or (d) to consent on the condition that Landlord be paid, as Additional Rent hereunder, fifty percent (50%) of all subrent or other consideration to be paid to Tenant under the terms of the Transfer in excess of the total rent due hereunder (including, if such Transfer is an assignment or if such Transfer is to occur directly or indirectly in connection with the sale of any assets of Tenant, fifty percent (50%) of the amount of the consideration attributable to the Transfer of the Lease, as reasonably determined by Landlord). The grounds on which Landlord may reasonably withhold its consent to any requested Transfer include, without limitation, that: (i) the proposed Transferee’s contemplated use of the Premises following the proposed Transfer is reasonably similar to the use of the Premises permitted hereunder, (ii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient business reputation or experience to operate a successful business of the type and quality permitted under this Lease, (iii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient net worth, working capital, anticipated cash flow and other indications of financial strength to meet all of its obligations under this Lease, (iv) the proposed Transfer would breach any covenant of Landlord respecting a radius restriction, location, use or exclusivity in any other lease, financing agreement, or other agreement relating to the Property, and (v) in Landlord’s reasonable business judgment, the possibility of a release of Hazardous Materials is materially increased as a result of the Transfer or if Landlord does not receive sufficient assurances that the proposed Transferee has the experience and financial ability to remedy a violation of Hazardous Materials and to fulfill its obligations under Articles 13 and 14. Landlord need only respond to any request by Tenant hereunder within a reasonable time of not less than ten (10) business days alter receipt of all information and other submission required in connection with such request.
Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord's reasonable control, and subject to all other terms of this Article 1 1, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Landlord shall repair any injury or damage to the improvements which exist in the Premises as of the Lease Commencement Date (the "Original Improvements") and shall return such Original Improvements to their original condition. Prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord's review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant's business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant's occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises, provided that if the Premises are so damaged that it is not reasonably practicable for Tenant to continue its business operations from any portion of the Premises, then the Rent shall be fully abated during such time.
DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion. b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination. c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease. d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
Landlord Default If Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement or any obligation of Landlord, if any, under any agreement affecting the Leased Property, the performance of which is not Tenant’s obligation pursuant to this Agreement, and any such default shall continue for a period of thirty (30) days after Notice thereof from Tenant to Landlord and any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct the same, Tenant may declare the occurrence of a “Landlord Default” by a second Notice to Landlord and to such Facility Mortgagee. Thereafter, Tenant may forthwith cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys’ fees and court costs) incurred by Tenant in curing the same, together with interest thereon (to the extent permitted by law) from the date Landlord receives Tenant’s invoice until paid, at the Overdue Rate. Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof. If Tenant and Landlord shall fail, in good faith, to resolve any such dispute within ten (10) days after Landlord’s Notice of dispute, either may submit the matter for resolution in accordance with Article 22.

Determination of Landlord Delay Sample Clauses

Filter & Search

Related Clauses

Parent Clauses

Related to Determination of Landlord Delay