OWNER’S RIGHT TO STOP THE WORK If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Owner’s Right to Suspend Work The Owner reserves the right, with or without the concurrence of the Design Professional, to suspend the Work at any time or from time to time at the Owner's sole discretion, upon giving Contractor five days advanced written notice thereof. If the Owner exercises this right and then resumes the Work covered hereby, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the suspension and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's suspension, to include compensation based upon the rate for Time Dependent Overhead Costs. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Right to Stop Work If Contractor fails to correct any defective Work or repeatedly fails to perform the Work in accordance with the Contract Documents, Owner shall have the right to order Contractor to stop performing the Work, or any portion thereof, until the cause for such order is eliminated.
STATE'S RIGHT TO STOP THE WORK 3.3.1 If the Contractor fails to correct defective Work as required by Paragraph 13.2 or persistently fails to carry out the Work in accordance with the Contract Documents, the State, by a written order signed personally or by an agent specifically so empowered by the State in writing, may order the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of the State to the stop the Work shall not give rise to any duty on the part the State to exercise this right for the benefit of the Contractor or any other person or entity, except to the extent required by Subparagraph 6.1.3.
STATE's Right to Suspend the Operations The STATE and/or the STATE's Authorized Representative has the authority to suspend portions or all of the operations due to causes including, but not limited to:
Drawings Submitted During the Contract Term Where required to develop maintain and deliver diagrams or other technical schematics regarding the scope of work, Contractor shall do so on an ongoing basis at no additional charge, and must, as a condition of payment, update drawings and plans during the Contract term to reflect additions, alterations, and deletions. Such drawings and diagrams shall be delivered to the Authorized User’s representative.
Right to Opt Out IF YOU DO NOT WISH TO ARBITRATE DISPUTES YOU MAY DECLINE TO HAVE YOUR DISPUTES WITH US ARBITRATED BY NOTIFYING US IN WRITING WITHIN 30 DAYS OF THE LATER OF YOUR FIRST ACCESS TO OR USE OF THE SITES, BY MAIL TO 000 XXXXXXXXXXX XXXX, XXXXXXXX, XXX XXXX 00000. YOUR WRITTEN NOTIFICATION TO US MUST INCLUDE YOUR NAME, ADDRESS AND TELEPHONE NUMBER AS WELL AS A CLEAR STATEMENT THAT YOU DO NOT WISH TO RESOLVE DISPUTES WITH YS THROUGH ARBITRATION. YOUR DECISION TO OPT OUT OF THIS ARBITRATION PROVISION WILL HAVE NO ADVERSE EFFECT ON YOUR RELATIONSHIP WITH US OR PRODUCTS AND SERVICES PROVIDED BY US.
Right to Open Up 13.3 Subject to Clause 13.4 (Right to Open Up), the Authority's Representative shall have the right at any time prior to[:
Right of Refusal The proposing vendor has the right not to sell under the awarded agreement with a TIPS member at vendor's discretion unless required by law.
