Developer’s Submittals, Including and Schedules. Developer’s submittals shall comply with the provisions and requirements of the Specifications including, without limitation Submittals.
Developer’s Submittals, Including and Schedules Sample Clauses
Related to Developer’s Submittals, Including and Schedules
Exhibits and Schedules The exhibits and schedules attached to this Agreement are incorporated herein and shall be considered a part of this Agreement for the purposes stated herein.
Clauses and Schedules Any reference in this Agreement to a Clause or a sub-clause or a Schedule is, unless otherwise stated, to a clause or a sub-clause hereof or a schedule hereto.
Shift Schedules 1501 Shift schedules for a minimum of a four (4) week period shall be posted at least two (2) weeks in advance of the beginning of the scheduled period. Shifts within the minimum four (4) week period shall not be altered after posting except by mutual agreement between the nurse(s) concerned and the Employer. Requests for specific days off duty shall be submitted in writing at least two (2) weeks prior to posting and granted, if possible in the judgment of the Employer. 1502 Requests for interchanges in posted shifts or a portion thereof shall also be submitted in writing, co-signed by the nurse willing to exchange shifts with the applicant. Where reasonably possible, interchanges in posted shifts are to be completed within the posted shift schedule. It is understood that any change in shifts or days off initiated by the nurses and approved by the Employer shall not result in overtime costs to the Employer. 1503 Night shift shall be considered as the first shift of each calendar day. 1504 Master rotations for each nursing unit shall be planned by the Employer in meaningful consultation with the nurse(s) concerned. The process for meaningful consultation shall include: Employer proposes a master rotation including the Employer established criteria and provides to Nurses concerned Nurses are provided reasonable time to submit feedback and/or an alternate master rotation for consideration. The amended or new master rotation is provided to Nurses for review. Nurses are provided with a reasonable time to submit feedback. At each step of the consultation process the Union will be provided with the new or revised master rotation to ensure contract compliance. Employer has the sole discretion to select the new master rotation and provides rationale for the selection. Master Rotations shall, unless otherwise mutually agreed between the nurse(s) concerned and the Employer, observe the conditions listed hereinafter:
Appendixes The following attachment and other attachments and individual agreements confirmed by both parties constitute an integral part of this Agreement and have the same legal effect as this Agreement. Attachment: Application Form for Withdrawals.
Schedules and Exhibits All of the schedules and exhibits attached to this Agreement shall be deemed incorporated herein by reference.
Annexes The Annexes form an integral part of this Agreement.
Annexes, Appendices and Footnotes The annexes, appendices and footnotes to this Agreement constitute an integral part of this Agreement.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Second Schedule Second Schedule THIS AGREEMENT under seal made the twenty-seventh day of October One thousand nine hundred and sixty-four BETWEEN THE HONOURABLE XXXXX XXXXX, M.L.A. Premier and Treasurer of the State of Western Australia acting for and on behalf of the said State and instrumentalities thereof from time to time (hereinafter called “the State”) of the one part and HAMERSLEY IRON PTY. LIMITED a company incorporated under the Companies Xxx 0000 of the State of Victoria and having its registered office and principal place of business in that State at 00 Xxxxxxx Xxxxxx Melbourne and its registered office in the State of Western Australia at 37 Saint George’s Terrace Perth (hereinafter called “the Company” which expression will include the successors and assigns of the Company including where the context so admits the assignees and appointees of the Company under clause 20 of the agreement hereinafter referred to) of the other part.
Exhibits The exhibits to this Agreement are hereby incorporated and made a part hereof and are an integral part of this Agreement.
