Project Team County’s Designated Representative for purposes of this Contract is as follows: County’s Road Bond Program Manager Attn: Xxxxxxx Xxxxxx HNTB Corporation 000 X. Xxx Xxxxxxxx Xxxx., Xxxxx 000 Xxxxx Xxxx, Xxxxx 78664_ County shall have the right, from time to time, to change the County’s Designated Representative by giving Engineer written notice thereof. With respect to any action, decision or determination which is to be taken or made by County under this Contract, the County’s Designated Representative may take such action or make such decision or determination or shall notify Engineer in writing of an individual responsible for and capable of taking such action, decision or determination and shall forward any communications and documentation to such individual for response or action. Actions, decisions or determinations by the County’s Designated Representative on behalf of County shall be done in his or her reasonable business judgment unless express standards or parameters therefor are included in this Contract, in which case, actions taken by the County’s Designated Representative shall be in accordance with such express standards or parameters. Any consent, approval, decision or determination hereunder by the County’s Designated Representative shall be binding on County; provided, however, the County’s Designated Representative shall not have any right to modify, amend or terminate this Contract, an Executed Work Authorization, an executed Supplemental Work Authorization or executed Contract Amendment. County’s Designated Representative shall not have any authority to execute a Contract Amendment, Work Authorization or any Supplemental Work Authorization unless otherwise granted such authority by the Xxxxxxxxxx County Commissioners Court. Engineer’s Designated Representative for purposes of this Contract is as follows: LJA Engineering, Inc. Attn: Xxxxxxx Xxxxxxx, PE 0000 Xxxxxx Xxxxxxxxx, Xxxxxxxx XX, Xxxxx 000 Xxxxxx , XX 00000 Engineer shall have the right, from time to time, to change the Engineer’s Designated Representative by giving County written notice thereof. With respect to any action, decision or determination which is to be taken or made by Engineer under this Contract, the Engineer’s Designated Representative may take such action or make such decision or determination or shall notify County in writing of an individual responsible for and capable of taking such action, decision or determination and shall forward any communications and documentation to such individual for response or action. Actions, decisions or determinations by the Engineer’s Designated Representative on behalf of Engineer shall be done in his or her reasonable business judgment unless express standards or parameters therefor are included in this Contract, in which case, actions taken by the Engineer’s Designated Representative shall be in accordance with such express standards or parameters. Any consent, approval, decision or determination hereunder by the Engineer’s Designated Representative shall be binding on Engineer. Engineer’s Designated Representative shall have the right to modify, amend and execute Work Authorizations, Supplemental Work Authorizations and Contract Amendments on behalf of Engineer.
Project Representatives The Contractor designates the following individual as project representative for all matters concerning this Agreement: Xxxxxx Xxxxxxx Intake Specialist 00000 X. Xxxxxx Avenue Detroit, MI 48224 Phone: 313-640-1100 ext. 11 Email: xx@xxxxxxxx.xxx The Authority designates the following individual as Contract Administrator/project representative to be the initial point of contact for all matters concerning this Agreement: Xxxx Xxxxxxxxxxxxx Authority Buyer 000 Xxxx Xxxxxxxx Xxxxxx Xxxxxxx, XX 00000 Email: XxxxxxxxxxxxxX0@xxxxxxxx.xxx The Contractor shall contact only the designated Contract Administrator with any Authority-related questions, work requests, etc., as described in this Agreement, as well as any Authority-related questions, work requests, etc., falling outside the scope of this Agreement. Except for changes to the performance schedule (not including the project’s completion date), the designated project representatives shall have no authority to make promises or binding obligations on behalf of the Authority, as such authority rests with the duly authorized persons executing this Agreement.
Project Steering Committee 1. For a sound implementation and management of the project, a steering committee shall be set up in line with provisions of the programme manual.
Contractor’s Project Manager and Key Personnel Contractor shall appoint a Project Manager to direct the Contractor’s efforts in fulfilling Contractor’s obligations under this Contract. This Project Manager shall be subject to approval by the County and shall not be changed without the written consent of the County’s Project Manager, which consent shall not be unreasonably withheld. The Contractor’s Project Manager shall be assigned to this project for the duration of the Contract and shall diligently pursue all work and services to meet the project time lines. The County’s Project Manager shall have the right to require the removal and replacement of the Contractor’s Project Manager from providing services to the County under this Contract. The County’s Project manager shall notify the Contractor in writing of such action. The Contractor shall accomplish the removal within five (5) business days after written notice by the County’s Project Manager. The County’s Project Manager shall review and approve the appointment of the replacement for the Contractor’s Project Manager. The County is not required to provide any additional information, reason or rationale in the event it The County is not required to provide any additional information, reason or rationale in the event it requires the removal of Contractor’s Project Manager from providing further services under the Contract.
Project Managers The JBE’s project manager is: [Insert name]. The JBE may change its project manager at any time upon notice to Contractor without need for an amendment to this Agreement. Contractor’s project manager is: [Insert name]. Subject to written approval by the JBE, Contractor may change its project manager without need for an amendment to this Agreement.
Contractor’s Project Manager 7.2.1 The Contractor’s Project Manager is designated in Exhibit F (Contractor’s Administration). The Contractor shall notify the County in writing of any change in the name or address of the Contractor’s Project Manager.