WORK JURISDICTION Par.
1. It is agreed by the parties to this Agreement that all work specified in Article IV shall be performed exclusively by Elevator Constructor Mechanics, Elevator Constructor Helpers, Elevator Constructor Apprentices and Elevator Constructor Assistant Mechanics in the employ of the Company.
(a) The handling and unloading of all equipment coming under the jurisdiction of the Elevator Constructor, from the time such equipment arrives at or near the building site, shall be handled and unloaded by the Elevator Constructors. Mechanical equipment such as a fork lift or truck mounted swing boom may be used by the Elevator Constructors. A xxxxxxx, xxxxx or material hoist can be used under the supervision of Elevator Constructors to handle and unload the heavy material described in Par. 5(a). Where unusual conditions are expected to exist prior to delivery of equipment at or near the building site in regard to handling and unloading of equipment in the primary or secondary jurisdiction of the local union, the Company shall contact the Local's Business Representative to make appropriate arrangements for the handling and unloading of such equipment. In areas outside the jurisdiction of the local union, the Company shall contact the Regional Director.
(b) The erecting and assembling of all elevator equipment to wit: electric, hydraulic, steam, belt, dumbwaiters, residence elevators, parking garage elevators (such as Xxxxxx, Pigeon Hole, or similar types of elevators), shuttles, compressed air and handpower, automatic people movers, monorails, airport shuttles and like-named devices used in the transportation of people for short distances of travel (less than 5 miles), as well as vertical reciprocating conveyor systems.
(c) It is understood and agreed that the preassembly of all escalators, moving stairways and link belt carriers that may be done in the factory shall include the following:
1. Truss or truss sections with tracks, drive units, machines, handrail drive sheaves, drive chains, skirts on the incline sections but not curved sections, step chains and steps installed and permanently aligned.
2. Balustrade brackets may be shipped attached but not aligned.
3. Setting of all controllers and all wiring and conduit from the controller. All other work on escalators, moving stairways and link belt carriers shall be performed in the field by Elevator Constructor Mechanics, Helpers, Apprentices and Assistant Mechanics either before or after the truss or truss sections are joined and/or hoisted and placed in permanent position. This includes any and all work not done in the factory. The erecting and assembly of all theater stage and curtain elevator equipment and guides and rigging thereto, organ consoles and orchestra elevators shall be performed by Elevator Constructor Mechanics, Helpers, Apprentices and Assistant Mechanics.
(d) All wiring, conduit, and raceways from main line feeder terminals on the controller to other elevator apparatus and operating circuits. Controllers are not to be shipped from the factory with extended wiring attached thereto.
(e) The erecting of all guide rails.
(f) The installation of all grating under the control of the Company. The installation of all counterweight screens, overhead work, either wood or iron, and all material used for mounting of elevator apparatus in machine room, overhead or below.
(g) The drilling of overhead beams for attaching machines, sheaves, kick angles, and all other elevator equipment.
(h) The setting of all templates.
(i) All foundations, either of wood or metal, that should take the place of masonry.
(j) The assembly of all cabs complete.
(k) The installation of all indicators.
(1) The erecting of all electrical or mechanical automatic or semi-automatic gates complete.
Arbitrator's Jurisdiction The arbitrator shall take such evidence as in his judgment is appropriate for resolution of the dispute; however, he shall confine himself to the issues for arbitration and shall have no authority to determine any other issue not so submitted which is not directly essential to reaching a determination on the dispute at hand. The arbitrator shall have no power to recommend any right or relief for any period of time prior to the effective date of the Agreement under which the grievance was initiated. In those issues wherein the grievant’s relief sought involves back pay or lost wages covering a period of an Employee’s payroll separation due to suspension or discharge, the amount of the award shall be less any unemployment compensation or interim earnings, received by the aggrieved Employee. Second jobs or sources of income which the Employee received while under employment will not be considered interim income and will not be deducted when awarding lost wages or back pay. The decision of the arbitrator shall be submitted in writing to the parties within thirty (30) calendar days of the hearing’s conclusion unless the deadline is mutually extended by the parties. The decision and award of the arbitrator shall be final and binding on the Union, its members, the aggrieved Employee(s) and the CITY. With respect to grievances involving misapplication or misinterpretation of this Agreement, the grievance and arbitration procedure contained in this Article shall be the sole and exclusive remedy available to employees, and the parties hereto as this procedure is intended to supersede all conflicting provisions of the Ohio Revised Code regarding any and all matters subject to the grievance procedures of this Contract or otherwise made subject to this Agreement. With respect to grievances involving disciplinary suspensions, demotions or dismissals the election of remedies, as set forth above, shall be mutually exclusive. Choice of binding arbitration shall thereafter preclude appeal to Civil Service or to Court. Appeal to Civil Service shall preclude access to binding arbitration. With respect to cases of suspension, demotion and discharge, the arbitrator shall decide:
Jurisdiction; Venue In the event that any action is brought to enforce any provision of this Contract, the parties agree to exclusive jurisdiction in Thurston County Superior Court for the State of Washington and agree that in any such action venue shall lie exclusively at Olympia, Washington.
Venue; Jurisdiction (a) Any action or proceeding brought by either party seeking to enforce any provision of, or based on any right arising out of, this Agreement must be brought against any of the parties in the courts of the State of New York. Each party (i) hereby irrevocably submits to the jurisdiction of the state courts of the State of New York and to the jurisdiction of any United States District Court in the State of New York, for the purpose of any suit, action, or other proceeding arising out of or based upon this Agreement or the subject matter hereof brought by any party or its successors or assigns, (ii) hereby waives, and agrees not to assert, by way of motion, as a defense, or otherwise, in any such suit, action, or proceeding, any claim that it is not subject personally to the jurisdiction of the above-named courts, that its property is exempt or immune from attachment or execution, that the suit, action or proceeding is brought in an inconvenient forum, that the venue of the suit, action, or proceeding is improper or that this Agreement or the subject matter hereof may not be enforced in or by such court, and (iii) hereby waives and agrees not to seek any review by any court of any other jurisdiction that may be called upon to grant an enforcement of the judgment of any such New York state or federal court.
(b) Process in any action or proceeding seeking to enforce any provision of, or based on any right arising out of, this Agreement may be served on any party anywhere in the world. Each party consents to service of process by registered mail at the address to which notices are to be given and further consent that any service of process, writ, judgment or other notice of legal process shall be deemed and held in every respect to be effectively served upon it in connection with proceedings in the State of New York, if delivered to CT Corporation System, whose current address is 000 Xxxxxx Xxxxxx, 00xx Xxxxx, Xxx Xxxx, Xxx Xxxx 00000, which each party irrevocably designates and appoints as its authorized agent for the service of process in the courts in the State of New York. Nothing herein shall affect the right of a party to serve process in any other manner permitted by applicable law. Each party further agrees that final judgment against it in any such action or proceeding arising out of or relating to this Agreement shall be conclusive and may be enforced in any other jurisdiction within or outside the United States of America by suit on the judgment, a certified or exemplified copy of which shall be conclusive evidence of the fact and of the amount of its liability.
(c) Each party agrees that it shall not, and that it shall instruct those in its control not to, take any action to frustrate or prevent the enforcement of any writ, decree, final judgment, award (arbitral or otherwise) or order entered against it with respect to this Agreement or the XOMA Patent Rights and shall agree to be bound thereby as if issued or executed by a competent judicial tribunal having personal jurisdiction situated in its country of residence or domicile.
Jurisdiction of Courts Québec hereby appoints the person from time to time who holds the position of Delegate General of Québec in New York, Xxx Xxxxxxxxxxx Xxxxx, 00xx xxxxx, Xxx Xxxx, Xxx Xxxx 00000-0000, as its authorized agent (the “Authorized Agent”) upon whom process may be served in any action by any Underwriter, or by any person controlling such Underwriter, and based upon this Agreement which may be instituted in any State or Federal court in The City of New York, and expressly accepts the non-exclusive jurisdiction of any such court in respect of such action. Québec hereby irrevocably waives any immunity to service of process in respect of any such action to which the Authorized Agent might otherwise be entitled. Such appointment shall be irrevocable as long as any of the Securities remain outstanding, except that, if for any reason the Authorized Agent ceases to be able to act as agent or no longer has an address in The City of New York, Québec will appoint another person or persons in The City of New York, selected in its discretion, as Authorized Agent(s). Québec will take any and all action, including the filing of any and all documents and instruments that may be necessary to continue such appointment or appointments in full force and effect as aforesaid. Service of process upon the Authorized Agent together with written notice of such service mailed or delivered to Québec at its address set forth in Section 11, shall be deemed in every respect effective service of process upon Québec. Notwithstanding the foregoing, any action by an Underwriter, or by any person controlling such Underwriter, and based upon this Agreement may be instituted in any competent court in Québec. Québec hereby waives, to the fullest extent permitted by applicable law, any immunity to jurisdiction to which it might otherwise be entitled in any action based on this Agreement which may be instituted as provided in this Section in any State or Federal court in The City of New York or in any competent court in Québec.
TERRITORIAL JURISDICTION The Territorial Jurisdiction of this Collective Agreement is the whole area within the boundaries of the Province of Ontario.
Jurisdictional Disputes 17.01 A xxxx-up meeting will be held with each Contractor not later than the commencement of the Contractor's work on all projects and no assignments shall be made before this xxxx- up. Xxxx-up assignments shall also apply to all sub-contractors. If a jurisdictional dispute arises once the work has commenced, assignments will be made in accordance with procedures, rules and regulations of the National Joint Board Building Trades Department, A.F.L. & C.I.O. The work assignment shall not be completed until a meeting on site has been convened with all Parties involved and until a subsequent meeting (not later than twenty-four (24) hours) has taken place, at which the Contractor shall present the work assignment on paper to all Parties.
17.02 In the event such jurisdictional dispute cannot be settled on a Local basis by the Unions involved, such dispute shall be submitted to the International Unions involved for settlement without permitting it to interfere in any way with the progress of the work at any time. In the event the dispute is not settled by the International Unions involved, it shall then be submitted to the National Joint Board for resolution. It is understood and agreed, however, that if the dispute causes any delay in the progress of the work or gives rise to an apprehended delay, any of the Parties hereto may apply to the Labour Relations Board (Nova Scotia) Construction Panel for an Interim Order under Section 50 of the Trade Union Act, Chapter 311, R.S.N.S. 1967, amended.
Jurisdiction; Immunities EACH BORROWER, ADMINISTRATIVE AGENT AND EACH BANK HEREBY IRREVOCABLY SUBMIT TO THE JURISDICTION OF ANY NEW YORK STATE OR UNITED STATES FEDERAL COURT SITTING IN NEW YORK CITY OVER ANY ACTION OR PROCEEDING ARISING OUT OF OR RELATING TO THIS AGREEMENT, THE NOTES OR ANY OTHER LOAN DOCUMENT. EACH BORROWER PARTY, ADMINISTRATIVE AGENT, AND EACH BANK IRREVOCABLY AGREE THAT ALL CLAIMS IN RESPECT OF SUCH ACTION OR PROCEEDING MAY BE HEARD AND DETERMINED IN SUCH NEW YORK STATE OR UNITED STATES FEDERAL COURT. EACH BORROWER PARTY, ADMINISTRATIVE AGENT, AND EACH BANK IRREVOCABLY CONSENT TO THE SERVICE OF ANY AND ALL PROCESS IN ANY SUCH ACTION OR PROCEEDING BY THE MAILING OF COPIES OF SUCH PROCESS TO ANY BORROWER PARTY, ADMINISTRATIVE AGENT OR EACH BANK, AS THE CASE MAY BE, AT THE ADDRESSES SPECIFIED HEREIN. EACH BORROWER PARTY, ADMINISTRATIVE AGENT AND EACH BANK AGREE THAT A FINAL JUDGMENT IN ANY SUCH ACTION OR PROCEEDING SHALL BE CONCLUSIVE AND MAY BE ENFORCED IN OTHER JURISDICTIONS BY SUIT ON THE JUDGMENT OR IN ANY OTHER MANNER PROVIDED BY LAW. EACH BORROWER PARTY, ADMINISTRATIVE AGENT AND EACH BANK FURTHER WAIVE ANY OBJECTION TO VENUE IN THE STATE OF NEW YORK AND ANY OBJECTION TO AN ACTION OR PROCEEDING IN THE STATE OF NEW YORK ON THE BASIS OF FORUM NON CONVENIENS. EACH BORROWER PARTY, ADMINISTRATIVE AGENT AND EACH BANK AGREE THAT ANY ACTION OR PROCEEDING BROUGHT AGAINST ANY BORROWER PARTY, ADMINISTRATIVE AGENT OR ANY BANK, AS THE CASE MAY BE, SHALL BE BROUGHT ONLY IN A NEW YORK STATE COURT SITTING IN NEW YORK CITY OR A UNITED STATES FEDERAL COURT SITTING IN NEW YORK CITY. Nothing in this Section shall affect the right of any Borrower Party, Administrative Agent or any Bank to serve legal process in any other manner permitted by law. To the extent that any Borrower Party, Administrative Agent or any Bank have or hereafter may acquire any immunity from jurisdiction of any court or from any legal process (whether from service or notice, attachment prior to judgment, attachment in aid of execution, execution or otherwise) with respect to itself or its property, each Borrower Party, Administrative Agent and each Bank hereby irrevocably waive such immunity in respect of its obligations under this Agreement, the Notes and any other Loan Document. EACH BORROWER PARTY, ADMINISTRATIVE AGENT AND EACH BANK WAIVE ANY RIGHT EACH SUCH PARTY MAY HAVE TO JURY TRIAL IN CONNECTION WITH ANY SUIT, ACTION OR PROCEEDING BROUGHT WITH RESPECT TO THIS AGREEMENT, THE NOTES OR THE LOANS. IN ADDITION, EACH BORROWER PARTY HEREBY WAIVES, IN CONNECTION WITH ANY SUIT, ACTION OR PROCEEDING BROUGHT BY ADMINISTRATIVE AGENT OR THE BANKS WITH RESPECT TO THE NOTES, ANY RIGHT ANY BORROWER PARTY MAY HAVE TO (1) INTERPOSE ANY COUNTERCLAIM THEREIN (OTHER THAN A COUNTERCLAIM THAT IF NOT BROUGHT IN THE SUIT, ACTION OR PROCEEDING BROUGHT BY ADMINISTRATIVE AGENT OR THE BANKS COULD NOT BE BROUGHT IN A SEPARATE SUIT, ACTION OR PROCEEDING OR WOULD BE SUBJECT TO DISMISSAL OR SIMILAR DISPOSITION FOR FAILURE TO HAVE BEEN ASSERTED IN SUCH SUIT, ACTION OR PROCEEDING BROUGHT BY ADMINISTRATIVE AGENT OR THE BANKS) OR (2) HAVE THE SAME CONSOLIDATED WITH ANY OTHER OR SEPARATE SUIT, ACTION OR PROCEEDING. NOTHING HEREIN CONTAINED SHALL PREVENT OR PROHIBIT ANY BORROWER PARTY FROM INSTITUTING OR MAINTAINING A SEPARATE ACTION AGAINST ADMINISTRATIVE AGENT OR THE BANKS WITH RESPECT TO ANY ASSERTED CLAIM.
LAW & JURISDICTION This Call-Off Agreement and/or any non-contractual obligations or matters arising out of or in connection with it, shall be governed by and construed in accordance with the Laws of England and Wales and without prejudice to the dispute resolution procedures set out in Clause CO-14 or CO-19 (Dispute Resolution) each Party agrees to submit to the exclusive jurisdiction of the courts of England and Wales and for all disputes to be conducted within England and Wales.
Legal Jurisdiction The agreement shall be deemed to have been concluded in Jodhpur, Rajasthan and all obligations hereunder shall be deemed to be located at Jodhpur, Rajasthan and Court within Jodhpur, Rajasthan will have Jurisdiction to the exclusion of other courts.
