Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.
Term Extension It is understood and agreed that the State may extend the Term an additional period of time, not to exceed one hundred-eighty (180) days beyond the expiration date of this Grant Contract, under the same terms and conditions. In no event, however, shall the maximum Term, including all extensions or renewals, exceed a total of sixty (60) months.
TAM Extension Service The TAM Extension Service is an extension of a Red Hat Enterprise Linux TAM Service to provide additional technical knowledge such as SAP implementations on Red Hat Enterprise Linux. The TAM Extension Service requires a separate active and paid standard TAM Service Subscription.
Contract Term Extension “Contract Term Extension” means an extension of the term of this contract, at the request of Purchaser, under this Subsection. This Subsection does not obligate Contracting Officer to grant Contract Term Extension. When such extension is made, Forest Service shall make an appraisal using standard Forest Service methods and appraisal data in effect 45 days prior to the original Termination Date. Bid Premium Rates shall be added to such appraised rates to establish Flat Rates or Tentative Rates for the extension period. In event rates so established would develop Current Contract Value immediately prior to such an extension that is less than Current Contract Value at that time, Flat Rates and Tentative Rates in effect immediately prior to extension shall be retained for the extension period. In consideration for granting an extension, Purchaser shall pay the Government for Purchaser’s failure to cut and remove timber meeting Utilization Standards prior to Contract Term Extension, an amount that shall be the total of the costs to the Government resulting from the delay in harvest of Included Timber. Such costs will be determined by Forest Service and shall include, but not be limited to, the following:
Extension Terms County may, at its sole option, extend the term of this Agreement beyond the Initial Term for up to ___ additional one-year terms at the same rates and under the same terms provided for herein (each such period being an “Extension Term”). County shall notify Contractor of its election for an Extension Term(s) as provided for in §6.
Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).
Termination of the Lease In terminating the Lease, the following procedures shall be followed by the Authority and Tenant:
Territorial Extension At the time of signature of this Agreement, or at any time thereafter, the provisions of this Agreement may be extended to such territories for whose international relations the Government of the United Kingdom are responsible as may be agreed between the Contracting Parties in an Exchange of Notes.
Interim Extension Amendment a. Prior to or on the expiration date of this Contract, the Parties agree that this Contract can be extended as provided under this Section.
EXPIRATION DATE AND EXTENSION This Contract expires January 31, 2023, unless it is terminated sooner pursuant to Article XX of the General Terms and Conditions, which are incorporated into this Contract by reference. This Contract may be extended up to three additional one-year periods upon request of Sourcewell and with written agreement by the Contractor, not to exceed a total of four years.
