Emergencies 10.3.1 In an emergency affecting safety of persons or property, the Contractor shall act, at the Contractor's discretion, to prevent threatened damage, injury or loss. Additional compensation or extension of time claimed by the Contractor on account of an emergency shall be determined as provided in Paragraph 4.3 and Article 7.
Service Interruptions When necessary by reason of accident or emergency, or for repairs, alterations, replacements or improvements which in the reasonable judgment of Landlord are desirable or necessary to be made, or by reason of event(s) of Force Majeure, Landlord reserves the right to interrupt, curtail, stop or suspend (i) the furnishing of heating, elevator, air conditioning, and cleaning services and (ii) the operation of the plumbing and electric systems. Landlord shall exercise reasonable diligence to eliminate the cause of any such interruption, curtailment, stoppage or suspension, but there shall be no diminution or abatement of rent or other compensation due from Landlord to Tenant hereunder, nor shall this Lease be affected or any of the Tenant’s obligations hereunder reduced, and the Landlord shall have no responsibility or liability for any such interruption, curtailment, stoppage, or suspension of services or systems, except as provided herein. Landlord shall schedule all non-emergency interruptions, curtailments, stops or suspensions of services or systems in advance after consultation with Tenant, and shall make commercially reasonable efforts to avoid the same interfering with Tenant’s business. Notwithstanding the foregoing, Tenant shall be entitled to a proportionate abatement of Base Rent in the event of a Landlord Service Interruption (as defined below). For the purposes hereof, a “Landlord Service Interruption” shall occur in the event (i) the Premises shall lack any service which Landlord is required to provide hereunder thereby rendering at least fifty (50%) percent of the usable area of the Premises untenantable for the entirety of the Landlord Service Interruption Cure Period (as defined below), (ii) such lack of service was not caused by the act or omission of Tenant or any Tenant Party; (iii) Tenant in fact ceases to use at least fifty (50%) percent of the Premises for the entirety of the Landlord Service Interruption Cure Period; and (iii) such interruption of service was the result of causes, events or circumstances within the Landlord’s reasonable control and the cure of such interruption is within Landlord’s reasonable control. During such Landlord Service Interruption Period, Landlord will, if reasonably practical, cooperate with Tenant to arrange for the provision of any interrupted services on an interim basis via temporary measures until final corrective measures can be accomplished and Tenant will permit Landlord the necessary access to the Premises to remedy such lack of service, subject to the provisions of Section 9.06. For the purposes hereof, the “Landlord Service Interruption Cure Period” shall be defined as seven (7) consecutive Business Days after Landlord’s receipt of written notice from Tenant of the Landlord Service Interruption. This Section 6.03 shall be Tenant’s sole and exclusive remedy on account of an interruption of services or Landlord default resulting in an interruption of services other than Tenant’s right to obtain affirmative injunctive relief. This Section 6.03 shall not apply to any interruption or failure of services required to be provided by Landlord under Section 6.02(a) or Exhibit E attached hereto, which is caused in whole or in part by any act or omission of Tenant or any Tenant Party, or by any occurrence described in Section 16.09, or by any cause whatsoever other than those set forth in the first sentence of this Section 6.03. Notwithstanding the foregoing, if either Landlord or Tenant disputes in good faith whether, or the extent to which, an event is subject to the provisions of this Section 6.03, or the amount of Tenant’s abatement of Base Rent hereunder, such dispute shall be resolved in accordance with Section 16.17 of this Lease; provided, however, that in the event that it is ultimately determined that there was a Landlord Service Interruption, then Tenant shall have the right to a retroactive equitable abatement of Base Rent for the period as set forth above, provided that, if the Term expires before Tenant’s entire retroactive abatement has been effected, then Landlord shall immediately refund to Tenant any overpayment of Rent due under the Lease not yet received on account of the retroactive abatement.
Interruptions There shall be no abatement of rent and Lessor shall not be liable in any respect whatsoever for the inadequacy, stoppage, interruption or discontinuance of any utility or service due to riot, strike, labor dispute, breakdown, accident, repair or other cause beyond Lessor's reasonable control or in cooperation with governmental request or directions.
Service Interruption Landlord shall not be liable in damages for any failure or interruption of any utility service to the Premises, except to the extent that any failure or interruption arises from the gross negligence or willful misconduct of Landlord. No failure or interruption of utility service for any reason shall entitle Tenant to terminate this Lease; provided, however, that if the failure or interruption of any Service to be repaired or maintained by Landlord and not the service provider continues for a period of forty-eight (48) hours or more, Tenant shall be entitled to an equitable abatement of Minimum Rent. Landlord shall not be obligated to provide any service or maintenance or to make any repairs pursuant to this Lease when such service, maintenance or repair is made necessary because of any wrongful act or misuse of any utility service by Tenant, Tenant's agents, employees, servants, contractors, subtenants or licensees. Landlord reserves the right to stop any Service when Landlord deems such stoppage necessary, whether by reason of accident or emergency, or for repairs or improvements or otherwise, provided, that any such period of stoppage shall be only so long as is reasonably required to effect any necessary repairs or maintenance. Landlord shall not be obligated to inspect the Premises and shall not be obligated to make any repairs or perform any maintenance hereunder unless first notified of the need thereof in writing or, in an emergency, verbally, followed by a written confirmation, by Tenant. Upon receipt of any such notice, Landlord shall commence any required repair work of an emergency nature as soon as possible and work as expeditiously as possible to complete such work. All other work of a non-emergency nature shall be performed as promptly as possible. If Landlord shall fail to commence emergency repairs or maintenance to be performed by Landlord and not the service provider within twenty-four (24) hours after said notice, or non-emergency repairs or maintenance within five (5) days after said notice, then Tenant shall be entitled to an equitable abatement of Minimum Rent for so long as such failure continues and an extension of the Lease Term for a period equal to the period of rent abatement.
Interruption of Services Tenant agrees that Landlord shall not be liable in damages, by abatement of Rent or otherwise, for failure to furnish or delay in furnishing any service, or for any diminution in the quality or quantity thereof, when such failure or delay or diminution is occasioned, in whole or in part, by repairs, renewals, or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, or other fuel at the Building after reasonable effort so to do, by any accident or casualty whatsoever, by act or default of Tenant or other parties, or by any other cause beyond Landlord’s reasonable control; and such failures or delays or diminution (any such event, a “Service Failure”) shall never be deemed to constitute an eviction or disturbance of Tenant’s use and possession of the Premises or relieve Tenant from paying Rent or performing any of its obligations under this Lease. Notwithstanding the foregoing, if the Premises, or a material portion of the Premises, is made untenantable (that is, Tenant cannot conduct its business in such portion) or inaccessible for a period in excess of five (5) consecutive business days as a result of the Service Failure that has been caused by Landlord’s act or omission with respect to matters within Landlord’s control (“Controlled Service Failure”), then Tenant, as its sole remedy, shall be entitled to receive an abatement of Rent payable hereunder during the period beginning on the sixth (61 ) consecutive business day of the Controlled Service Failure and ending on the day the service has been restored. If the entire Premises has not been rendered untenantable or inaccessible by such a Controlled Service Failure, the amount of abatement that Tenant is entitled to receive by reason of such a Controlled Service Failure shall be prorated based upon the percentage of the Premises rendered untenantable or inaccessible and not used by Tenant. Notwithstanding the foregoing, business days during which the Premises or a material portion thereof are untenantable or inaccessible, or during which all or nearly all the Premises are unusable, by reason of a Service Failure which arises from a fire or other casualty which is covered by the provisions of ARTICLE 13 shall in no event be considered in determining whether Tenant is entitled to an abatement of Rent under this Section 8.03 (in such event the provisions of Section 13.01 shall govern Tenant’s rights). In no event shall Landlord be liable to Tenant for any loss or damage, including the theft of Tenant’s property, arising out of or in connection with the failure of any security services, personnel or equipment.
Mail Service Interruption If by reason of any interruption of mail service, actual or threatened, any notice to be given to the Trustee would reasonably be unlikely to reach its destination by the time notice by mail is deemed to have been given pursuant to Section 14.3, such notice shall be valid and effective only if delivered at the appropriate address in accordance with Section 14.3.
Interruption Subject to Section 11, any failure to furnish, delay in furnishing, or diminution in the quality or quantity of any service resulting from any application of Law, failure of equipment, performance of maintenance, repairs, improvements or alterations, utility interruption, or event of Force Majeure (each, a “Service Interruption”) shall not render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder. Notwithstanding the foregoing, if all or a material portion of the Premises is made untenantable or inaccessible for more than three (3) consecutive business days after notice from Tenant to Landlord by a Service Interruption that (a) does not result from a Casualty (defined in Section 11), a Taking (defined in Section 13) or an Act of Tenant (defined in Section 10.1), and (b) can be corrected through Landlord’s reasonable efforts, then, as Tenant’s sole remedy, Monthly Rent shall xxxxx for the period beginning on the day immediately following such 3-business-day period and ending on the day such Service Interruption ends, but only in proportion to the percentage of the rentable square footage of the Premises made untenantable or inaccessible and not occupied by Tenant.
Emergency If a well goes out of control or a fire, blow out, sabotage or other emergency occurs prior to the effective date of a Party’s withdrawal, the withdrawing Party shall remain liable for its Participating Interest share of the costs of such emergency, regardless of when they are incurred.
Interruption of Use Tenant agrees that Landlord shall not be liable for damages, by abatement of Rent or otherwise, for failure to furnish or delay in furnishing any service (including telephone and telecommunication services), or for any diminution in the quality or quantity thereof, when such failure or delay or diminution is occasioned, in whole or in part, by breakage, repairs, replacements, or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, or other fuel at the Building or Project after reasonable effort to do so, by any riot or other dangerous condition, emergency, accident or casualty whatsoever, by act or default of Tenant or other parties, or by any other cause beyond Landlord's reasonable control; and such failures or delays or diminution shall never be deemed to constitute an eviction or disturbance of Tenant's use and possession of the Premises or relieve Tenant from paying Rent or performing any of its obligations under this Lease. Furthermore, Landlord shall not be liable under any circumstances for a loss of, or injury to, property or for injury to, or interference with, Tenant's business, including, without limitation, loss of profits, however occurring, through or in connection with or incidental to a failure to furnish any of the services or utilities as set forth in this Article 6.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
