Management and Control Systems Grantee will: 1. maintain an appropriate contract administration system to ensure that all terms, conditions, and specifications are met during the term of the contract through the completion of the closeout procedures. 2. develop, implement, and maintain financial management and control systems that meet or exceed the requirements of Uniform Statewide Accounting System (UGMS). Those requirements and procedures include, at a minimum, the following: i. Financial planning, including the development of budgets that adequately reflect all functions and resources necessary to carry out authorized activities and the adequate determination of costs; ii. Financial management systems that include accurate accounting records that are accessible and identify the source and application of funds provided under each Contract of this Contract, and original source documentation substantiating that costs are specifically and solely allocable to a Contract and its Contract and are traceable from the transaction to the general ledger; iii. Effective internal and budgetary controls; iv. Comparison of actual costs to budget; determination of reasonableness, allowableness, and allocability of costs; v. Timely and appropriate audits and resolution of any findings; vi. Billing and collection policies; and vii. Mechanism capable of billing and making reasonable efforts to collect from clients and third parties.
Coordination, Oversight and Monitoring of Service Providers As set forth in the Administrative Services Agreement between the Fund and CRMC, CRMC shall coordinate, monitor and oversee the activities performed by the Service Providers with which AFS contracts. AFS shall monitor Service Providers’ provision of services including the delivery of Customer account statements and all Fund-related material, including summary prospectuses and/or prospectuses, shareholder reports, and proxies.
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
Configuration Management The Contractor shall maintain a configuration management program, which shall provide for the administrative and functional systems necessary for configuration identification, control, status accounting and reporting, to ensure configuration identity with the UCEU and associated cables produced by the Contractor. The Contractor shall maintain a Contractor approved Configuration Management Plan that complies with ANSI/EIA-649 2011. Notwithstanding ANSI/EIA-649 2011, the Contractor’s configuration management program shall comply with the VLS Configuration Management Plans, TL130-AD-PLN-010-VLS, and shall comply with the following:
SCOPE OF SERVICES/CASE HANDLING A. Upon execution by GPM, attorneys are retained to provide legal services for the purpose of seeking damages and other relief in the Litigation. Client provides authorization to seek appointment as Lead Plaintiff in the class action, while the Attorneys will seek to be appointed Class Counsel. If this occurs, the Litigation will be prosecuted as a class action. B. If you obtain access to non-public information during the pendency of the Litigation, you must not engage in transactions in securities. C. Attorneys are authorized to prosecute the Litigation. The appointed Lead Plaintiffs will monitor, review and participate with counsel in the prosecution of the Litigation. The Attorneys shall consult with the appointed Lead Plaintiffs concerning all major substantive matters related to the Litigation, including, but not limited to, the complaint, dispositive motions and settlement. Because of potential differences of opinion between Clients concerning, among other things, strategy, goals and objectives of the Litigation, the Attorneys shall consult with the appointed Lead Plaintiffs as to the courses of action to pursue. The Client agrees to abide by the decisions of the appointed Lead Plaintiffs, which shall be final and binding on all Clients. D. GPM is given the authority to opt the Client out of any class action proceeding relating to the claims authorized herein and/or pursue the Client claim individually in a group action, if the Client is not appointed Lead Plaintiff and GPM is not appointed Class Counsel. E. The Attorneys shall provide sufficient resources, including attorney time and capital for payment of costs and expenses, to vigorously prosecute the Litigation. F. Any recovery from defendants that the Attorneys are responsible for will be divided among class members based on the recognized loss by each class member as calculated by a damage allocation plan which will be prepared by a financial expert or consultant, provided to the appointed Lead Plaintiffs, be subject to the Court's approval and will account for such factors as size of securities ownership, date of purchase, date of sale and continued holdings, if any. Under the rules governing class action litigation, while the Lead Plaintiffs recover according to the same formula as other class members, the Court may approve, upon application therefore, reimbursement of the Lead Plaintiffs’ reasonable costs and expenses directly related to the representation of the class. Examples are lost wages and travel expenses associated with testifying in the action.
Construction Phase Services 3.1.1 – Basic Construction Services
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
PRE-CONSTRUCTION PHASE SERVICES The Pre-Construction Phase shall be deemed to commence upon the date specified in a written Notice to Proceed with Pre-Construction Phase Services issued by Owner and shall continue through completion of the Construction Documents and procurement of all major Subcontractor agreements. Contractor is not entitled to reimbursement for any costs incurred for Pre-Construction Phase Services performed before issuance of the written Notice to Proceed. Pre-Construction Phase Services may overlap Construction Phase Services. Contractor shall perform the following Pre-Construction Phase Services:
Use of Basement and Service Areas The basement(s) and service areas, if any, as located within the
