Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Ability to Abandon CVR A Holder may at any time, at such Holder’s option, abandon all of such Holder’s remaining rights in a CVR by transferring such CVR to Parent without consideration therefor. Nothing in this Agreement is intended to prohibit Parent from offering to acquire CVRs for consideration in its sole discretion.
Presentation of Potential Target Businesses The Company shall cause each of the Initial Shareholders to agree that, in order to minimize potential conflicts of interest which may arise from multiple affiliations, the Initial Shareholders will present to the Company for its consideration, prior to presentation to any other person or company, any suitable opportunity to acquire an operating business, until the earlier of the consummation by the Company of a Business Combination or the liquidation of the Company, subject to any pre-existing fiduciary obligations the Initial Shareholders might have.
Eligibility to Work The Contractor must ascertain and validate that all proposed staff resources, including all employees, subcontractors and agents, (hereinafter “Contractor Staff Member”), are either U.S. citizens or non-U.S. citizens.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
WARRANTY OF CONTRACTOR’S ABILITY TO PERFORM The Contractor warrants that, to the best of its knowledge, there is no pending or threatened action, proceeding, or investigation, or any other legal or financial condition, that would in any way prohibit, restrain, or diminish the Contractor’s ability to satisfy its Contract obligations. The Contractor warrants that neither it nor any affiliate is currently on the Suspended Vendor List, Convicted Vendor List, or the Discriminatory Vendor List, or on any similar list maintained by any other state or the federal government. The Contractor shall immediately notify the Department in writing if its ability to perform is compromised in any manner during the term of the Contract. Contractor’s candidates shall complete this Resume Self-Certification Form. Completed Resume Self-Certification Forms shall be submitted within the Contractor’s response to Customer’s requests for quote. “I the undersigned do hereby certify, under the penalty of perjury, that information in my resume submitted for consideration of the State of Florida contract position is true, correct, complete, and made in good faith to the best of my knowledge and belief. If an omission, falsification, misstatement, or misrepresentation has been made regarding my education, work ability, experience, employment history, and/or fitness for employment as a contractor, I may be disqualified as a contractor, and the matter will be reported to appropriate agency or law enforcement personnel. I understand that there may be civil and/or criminal penalties for misrepresenting pertinent information in connection with contract positions, including, but not limited to, penalties available under sections 287.133 or 817.566, Florida Statutes. I further understand that if I am not a United States citizen, violation cases may be reported to the US Department of Homeland Security for potential deportation.” “In addition, I the undersigned do hereby consent to the release of my information by employers, educational institutions, law enforcement agencies, and other individuals and organizations to investigators and other authorized agents of Florida for verification and investigation purposes. I understand that any documents submitted to procure a contract(s) with the State of Florida, including resumes, are public records.” Print Full Legal Name of Candidate Candidate’s Signature Date Candidate’s Form of Identification Presented Identification number Contractor’s Witness Signature One Date Contractor’s Witness Signature Two Date Print Name Contractor’s Witness One Print Name Contractor’s Witness Two Customers shall complete this Contractor Selection Justification Form for each candidate selected and attach all completed forms to the purchase order. Date: Contractor’s Name: Contractor’s Contact Information: Candidate’s Name: Address: _ Phone: _ Email: Date Candidate will be available: _ Hourly rate of candidate: $ Position candidate recommended for: _ Justification for selection of candidate: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Agency: Division/Section/Unit: _ Printed Name: _ Title: _ Signature _ Date: Contractor's Name: Quarter: Purchase Order (PO) Number: PO Total $ Amount: PO Starting Date Ending Date Please review the attached Rating Definitions and provide your opinion by rating the following:
1. Effectiveness performing tasks 2. Quality & completeness of work 3 ❒ 3 ❒ 2 ❒ 2 ❒ 1 ❒ 1 ❒
Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of:
i. Prohibiting the use of all forms of tobacco products, including but not limited to cigarettes, cigars, pipes, water pipes (hookah), bidis, kreteks, electronic cigarettes, smokeless tobacco, snuff and chewing tobacco;
ii. Designating the property to which this Policy applies as a "designated area,” which must at least comprise all buildings and structures where activities funded under this Grant Agreement are taking place, as well as Grantee owned, leased, or controlled sidewalks, parking lots, walkways, and attached parking structures immediately adjacent to this designated area;
iii. Applying to all employees and visitors in this designated area; and
iv. Providing for or referring its employees to tobacco use cessation services.
B. If Grantee cannot meet these minimum standards, it must obtain a waiver from the System Agency.
Ability to Bear Economic Risk Each Purchaser acknowledges that investment in the Securities involves a high degree of risk, and represents that it is able, without materially impairing its financial condition, to hold the Securities for an indefinite period of time and to suffer a complete loss of its investment.
Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
