ENVIRONMENT AND DECOMMISSIONING Sample Clauses

ENVIRONMENT AND DECOMMISSIONING. 8.1 The Purchaser shall at its cost and expense perform and shall be responsible for decommissioning and/or removing and/or making safe all plant, equipment and machinery, wells and other installations (including pipelines) and facilities rexxxxxg to operations under the Licences and/or under each and any Operating Agreement or other Licensed Interest Document to the extent that such obligations are attributable to the Interests whether such Losses and Expenses are incurred under or pursuant to any of the Licensed Interest Documents or under statutory, common law or other obligation or under any former licences and/or each and any operating agreement or other licensed interest document to which a Target Company was a party or are attributable to the interests previously owned by a Target Company, whether such Losses and Expenses are incurred under or pursuant to any of such licensed interest documents or under statutory, common law or other obligation. 8.2 The Purchaser covenants that it shall indemnify and hold the Seller and its Connected Persons harmless against: (a) any and all Losses and Expenses which the Seller or any of its Connected Persons may incur arising out of or in connection with the Decommissioning Liabilities regardless of whensoever such Decommissioning Liabilities may arise or may have arisen, regardless of whosoever is or was a licensee under the relevant licence or a party to the relevant operating agreement or owned or leased the relevant property and regardless of whether such Losses and Expenses arise as a consequence of negligence on the part of the Seller or any of its Connected Persons or any other operator or any of its Connected Persons provided that for the avoidance of doubt the Purchaser shall not be required to reimburse the Seller for amounts actually expended by the Seller or any other person prior to the Closing Date in respect of Decommissioning Liabilities; and (b) the Environmental Liabilities regardless of whensoever such Environmental Liabilities may arise or may have arisen, regardless of whosoever is or was a licensee under the relevant licence or a party to the relevant operating agreement or owned or leased the relevant property and regardless of whether such Losses and Expenses arise as a consequence of negligence or breach of any Environmental Law on the part of the Seller or any of its Connected Persons or any other person. 8.3 Notwithstanding the provisions of Clauses 8.2(a) and 8.2(b) in the event that any...
Sample 1
AutoNDA by SimpleDocs

Related to ENVIRONMENT AND DECOMMISSIONING

  • Working Environment The Parties agree that a safe and clean working environment is essential in order to carry out work assignments in a satisfactory manner. It will be the Employer's responsibility to ensure that all working areas and Employer-owned vehicles are maintained in a safe and clean condition.

  • Work Environment It is mutually agreed that the prevention of accidents and injuries to state employees will result in greater efficiency of operations of state government. Toward this end, the Employer shall make every reasonable effort to provide and maintain safe and healthy working conditions and the Union shall fully cooperate by encouraging all employees to perform their assigned tasks in a safe manner.

  • Environmental and Safety Matters (a) The Company and its Subsidiaries have at all times complied in all material respects with all applicable Environmental and Safety Requirements, which compliance has included obtaining and complying in all material respects at all times with all material permits, licenses and other authorizations required pursuant to Environmental and Safety Requirements for the occupation of their facilities and the operation of their respective businesses. (b) Except as set forth in Section 4.27(b) of the Disclosure Schedule, since February 19, 2008, neither the Company nor any of its Subsidiaries has received any notice, report, order, or directive regarding any, and is not subject to any litigation, proceedings or order regarding any, actual or alleged violation of Environmental and Safety Requirements, or any liability or potential liability arising under Environmental and Safety Requirements, in effect prior to and as of the date of the applicable Closing, relating to the business, the Owned Real Property or Leased Real Property. (c) Except as set forth in Section 4.27(c) of the Disclosure Schedule, neither the Company nor any of its Subsidiaries has treated, stored, disposed of, arranged for or permitted the disposal of, transported, handled, released, or exposed any Person to, any substance (including without limitation any hazardous substance), owned or operated any property or facility which is or has been contaminated by any substance, so as to give rise to any current or future liabilities under any Environmental and Safety Requirements in effect at the time of such treatment, storage, disposal, transportation, handling, release or exposure. (d) Except as set forth in Section 4.27(d) of the Disclosure Schedule, neither the Company nor any of its Subsidiaries has assumed, undertaken, or provided any indemnity with respect to, any liability of any other Person relating to Environmental and Safety Requirements. (e) The Company has furnished to Investor true and correct copies of all environmental audits, reports, assessments and all other documents materially bearing on environmental, health or safety liabilities relating to the past or current operations or facilities of the Company and all of its Subsidiaries, in each case which are in its possession or under its reasonable control.

  • Environment, Health, and Safety (a) To the Knowledge of AIDEA and the Acquired Companies, except as disclosed in Disclosure Schedules 3.16(b), (d), and (e), the Acquired Companies have complied with all Environmental, Health, and Safety Laws. No action, suit, proceeding, hearing, investigation, charge, complaint, claim, demand, or notice has been filed or commenced against any of the Acquired Companies alleging any failure to so comply. Without limiting the generality of the preceding sentence, the Acquired Companies, to the Knowledge of AIDEA and the Acquired Companies, have obtained and been in compliance with all of the terms and conditions of all permits, licenses, and other authorizations that are required under, and have complied with all other limitations, restrictions, conditions, standards, prohibitions, requirements, obligations, schedules, and timetables that are contained in, all Environmental, Health, and Safety Laws. (b) Except as disclosed in Disclosure Schedule 3.16(b), neither the Acquired Companies nor AIDEA with respect to the Acquired Companies, to the Knowledge of AIDEA and the Acquired Companies, has any Liability arising out of events or circumstances occurring under any Environmental, Health, and Safety Laws for contamination of, damage to, or polluting any site, location, property, natural resources, the air, or any body of water (surface or subsurface), or for any illness of, or personal injury to, or death of, any employee or other individual related to the foregoing. (c) To the Knowledge of AIDEA and the Acquired Companies, all equipment and personal property owned, leased, or used in the Operations are and have been free of hydrocarbon contamination, asbestos, PCBs, dioxins, and any other hazardous, toxic, radioactive, or dangerous substances, except for the liquefied natural gas and compressed natural gas the Acquired Companies produce, store, and handle, and except for the fuel, lubricants, refrigerants, and solvents that are used in the ordinary course of business in conducting the Operations. The liquefied natural gas and compressed natural gas of the Acquired Companies, and the fuel, lubricants, refrigerants, and solvents used in its Operations, have all been stored, handled, transported, used, and disposed of in accordance with all Environmental, Health, and Safety Laws and consistent with all standard industry practices. (d) Except as disclosed on Disclosure Schedule 3.16(d), all real property the Acquired Companies owns is, to the Knowledge of AIDEA and the Acquired Companies, free from contamination by any substance regulated under, or defined as or considered “hazardous” or “toxic” or “radioactive” or “contamination” or “pollution” under, any Environmental, Health, and Safety Laws, including but not limited to hydrocarbons, asbestos, PCBs, and dioxins. AIDEA has provided IGU with true and complete copies of all environmental assessments, studies, and reports (1) of which AIDEA and the Acquired Companies have Knowledge and (2) that reference the real property any of the Acquired Companies owns, leases, or uses. Although neither AIDEA nor the Acquired Companies has conducted any environmental assessments regarding the leased real property used by the Acquired Companies, neither AIDEA nor the Acquired Companies has Knowledge of any environmental contamination on or under the portions of any leased or used real property where any of the Operations have been conducted. (e) Except as disclosed on Disclosure Schedule 3.16(e), neither the Acquired Companies nor AIDEA has Knowledge of any leak, spill, release, discharge, or disposal of any substance regulated under, or defined as or considered “hazardous” or “toxic” or “radioactive” or “contamination” or “pollution” under any Environmental, Health, and Safety Laws that has occurred on, in, or under the real property any of the Acquired Companies owns, leases, or uses, or has ever owned, leased, or used, in conducting the Operations, that was reportable or should have been reported to any government or governmental agency, or that was or could have been subject to clean up or remediation, under any Environmental, Health, and Safety Laws. (f) Except as disclosed on Disclosure Schedule 3.16(f), to the Knowledge of AIDEA and the Acquired Companies, there is no underground storage tank present on any real property any of the Acquired Companies owns, leases, or uses or has owned, leased or used, in conducting the Operations.

  • Environmental, Health and Safety Matters (a) Comply in all material respects with all applicable Environmental Laws, including, without limitation, obtaining and complying with and maintaining any and all licenses, approvals, notifications, registrations or permits required by applicable Environmental Laws. For purposes of this Section 5.12(a), material noncompliance by the Company, any of its Subsidiaries or any tenant or subtenant, with any applicable Environmental Law shall be deemed not to constitute a breach of this covenant provided that, upon learning of any actual or suspected material noncompliance, the Company and the relevant Subsidiaries shall promptly undertake all reasonable efforts to achieve material compliance (or contest in good faith by appropriate proceedings the alleged violation or applicable Environmental Law at issue and (to the extent required by GAAP) provide on the books of the Company or any of its Subsidiaries, as the case may be, reserves in accordance with GAAP with respect thereto), and provided further that, in any case, such noncompliance, and any other noncompliance with applicable Environmental Law, individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect. (b) Promptly comply in all material respects with all lawful orders and directives of all Governmental Authorities regarding applicable Environmental Laws, except to the extent that the validity thereof is currently being contested in good faith by appropriate proceedings and (to the extent required by GAAP) reserves in accordance with GAAP with respect thereto have been provided on the books of the Company or any of its Subsidiaries, as the case may be. (c) Defend, indemnify and hold harmless the Administrative Agent and the Lenders, and their respective parents, subsidiaries, affiliates, employees, agents, officers and directors, from and against any claims, demands, penalties, fines, liabilities, settlements, damages, costs and expenses of whatever kind or nature, known or unknown, contingent or otherwise, arising out of, or in any way relating to the violation of, noncompliance with or liability under any Environmental Laws applicable to the Company or any of its Subsidiaries or any of their respective operations or properties, or any orders, requirements or demands of Governmental Authorities related thereto, including, without limitation, attorney’s and consultant’s fees, investigation and laboratory fees, response costs, court costs and litigation expenses, except to the extent that any of the foregoing arise out of the gross negligence or willful misconduct of (or, as determined pursuant to a claim initiated by the Company, breach in bad faith of its express obligations under the applicable Loan Documents by) the party seeking indemnification therefor, in each case, as determined by a final non-appealable judgment by a court of competent jurisdiction. This indemnity shall continue in full force and effect regardless of the termination of this Agreement.

  • Environmental Health and Safety i. Environment, Health and Safety Performance. Seller acknowledges and accepts full and sole responsibility to maintain an environment, health and safety management system ("EMS") appropriate for its business throughout the performance of this Contract. Buyer expects that Seller’s EMS shall promote health and safety, environmental stewardship, and pollution prevention by appropriate source reduction strategies. Seller shall convey the requirement of this clause to its suppliers. Seller shall not deliver goods that contain asbestos mineral fibers.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Data Protection Impact Assessment If, pursuant to Data Protection Law, Customer (or its Controllers) are required to perform a data protection impact assessment or prior consultation with a regulator, at Customer’s request, SAP will provide such documents as are generally available for the Cloud Service (for example, this DPA, the Agreement, audit reports or certifications). Any additional assistance shall be mutually agreed between the Parties.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Management of Special and Technical Environment Each certificated support person demonstrates an acceptable level of performance in managing and organizing the special materials, equipment and environment essential to the specialized programs.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!