Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-- (i) In the contract price or delivery schedule or both; and (ii) In such other provisions of the contract as may be affected. (2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.
Equitable Adjustment Trading volume amounts, price/volume amounts and similar figures in the Transaction Documents shall be equitably adjusted (but without duplication) to offset the effect of stock splits, similar events and as otherwise described in this Agreement and Warrants.
Equitable Remedy Because of the difficulty of measuring economic losses to the Company as a result of a breach of the restrictive covenants set forth in Sections 5 and 6 hereof, and because of the immediate and irreparable damage that would be caused to the Company for which monetary damages would not be a sufficient remedy, it is hereby agreed that in addition to all other remedies that may be available to the Company or Executive at law or in equity, the Company or Executive shall be entitled to specific performance and any injunctive or other equitable relief as a remedy for any breach or threatened breach of the aforementioned restrictive covenants.
Equitable Relief The parties hereto agree and declare that legal remedies may be inadequate to enforce the provisions of this Agreement and that equitable relief, including specific performance and injunctive relief, may be used to enforce the provisions of this Agreement.
Specific Performance and other Equitable Rights It is recognized and acknowledged that a breach by any party of any material obligations contained in this Agreement will cause the other party to sustain injury for which it would not have an adequate remedy at law for money damages. Accordingly, in the event of any such breach, any aggrieved party shall be entitled to the remedy of specific performance of such obligations and interlocutory, preliminary and permanent injunctive and other equitable relief in addition to any other remedy to which it may be entitled, at law or in equity.
Transfer Void; Equitable Relief Any Proposed Key Holder Transfer not made in compliance with the requirements of this Agreement shall be null and void ab initio, shall not be recorded on the books of the Company or its transfer agent and shall not be recognized by the Company. Each party hereto acknowledges and agrees that any breach of this Agreement would result in substantial harm to the other parties hereto for which monetary damages alone could not adequately compensate. Therefore, the parties hereto unconditionally and irrevocably agree that any non-breaching party hereto shall be entitled to seek protective orders, injunctive relief and other remedies available at law or in equity (including, without limitation, seeking specific performance or the rescission of purchases, sales and other transfers of Transfer Stock not made in strict compliance with this Agreement).
Equitable Treatment ICANN shall not apply standards, policies, procedures or practices arbitrarily, unjustifiably, or inequitably and shall not single out Registry Operator for disparate treatment unless justified by substantial and reasonable cause.
Equitable Adjustments to Prices Whenever any provision of this Indenture requires the Company to calculate the average of the Last Reported Sale Prices, or any function thereof, over a period of multiple days (including to calculate the Stock Price or an adjustment to the Conversion Rate), or to calculate Daily VWAPs over an Observation Period, the Company will make proportionate adjustments, if any, to such calculations to account for any adjustment to the Conversion Rate pursuant to Section 5.05(A)(i) that becomes effective, or any event requiring such an adjustment to the Conversion Rate where the Ex-Dividend Date or effective date, as applicable, of such event occurs, at any time during such period or Observation Period, as applicable.
Legal and Equitable Remedies Because my services are personal and unique and because I may have access to and become acquainted with the Proprietary Information of the Company, the Company shall have the right to enforce this Agreement and any of its provisions by injunction, specific performance or other equitable relief, without bond and without prejudice to any other rights and remedies that the Company may have for a breach of this Agreement.
Equitable Remedies The parties hereto agree that irreparable harm would occur in the event that any of the agreements and provisions of this Agreement were not performed fully by the parties hereto in accordance with their specific terms or conditions or were otherwise breached, and that money damages are an inadequate remedy for breach of this Agreement because of the difficulty of ascertaining and quantifying the amount of damage that will be suffered by the parties hereto in the event that this Agreement is not performed in accordance with its terms or conditions or is otherwise breached. It is accordingly hereby agreed that the parties hereto shall be entitled to an injunction or injunctions to restrain, enjoin and prevent breaches of this Agreement by the other parties and to enforce specifically the terms and provisions hereof in any court of the United States or any state having jurisdiction, such remedy being in addition to and not in lieu of, any other rights and remedies to which the other parties are entitled to at law or in equity.
