Extensions of Time 34.1 If at any time during performance of the Contract, the Supplier or its subcontractors should encounter conditions impeding timely delivery of the Goods or completion of Related Services pursuant to GCC Clause 13, the Supplier shall promptly notify the Procuring Entity in writing of the delay, its likely duration, and its cause. As soon as practicable after receipt of the Supplier's notice, the Procuring Entity shall evaluate the situation and may at its discretion extend the Supplier's time for performance, in which case the extension shall be ratified by the parties by amendment of the Contract.
DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.
Extensions and Renewals All extensions or renewals of leaves shall be applied for and granted in writing.
Definitions and Other Provisions of General Application SECTION 101.
Delays and Extensions The CONSULTANT agrees that no charges or claim for damages shall be made by it for any minor delays from any cause whatsoever during the progress of any portion of the Services specified in this Contract. Such delays, if any, shall be compensated for by an extension of time for such period as may be determined by the LPA subject to the CONSULTANT's approval, it being understood, however, that permitting the CONSULTANT to proceed to complete any services, or any part of them after the date to which the time of completion may have been extended, shall in no way operate as a waiver on the part of the LPA of any of its rights herein. In the event of substantial delays or extensions, or change of any kind, not caused by the CONSULTANT, which causes a material change in scope, character or complexity of work the CONSULTANT is to perform under this Contract, the LPA at its sole discretion shall determine any adjustments in compensation and in the schedule for completion of the Services. CONSULTANT must notify the LPA in writing of a material change in the work immediately after the CONSULTANT first recognizes the material change.
PROVISIONS OF LAW It is understood and agreed that this Memorandum of Understanding is subject to all current and future applicable Federal, State and County laws; Federal and State regulations; the Charter of the County of Los Angeles, and any lawful rules and regulations enacted by County's Civil Service Commission, Employee Relations Commission, or similar independent commissions of the County. If any part or provision of this Memorandum of Understanding is in conflict or inconsistent with such applicable laws, rules or regulations, or is otherwise held to be invalid or unenforceable by any tribunal of competent jurisdiction, such part or provision shall be suspended and superseded by such applicable law, regulations, or rules, and the remainder of this Memorandum of Understanding shall not be affected thereby.
Provisions of the Agreement a reference to any Clause or Schedule is, except where it is expressly stated to the contrary, a reference to such clause of, or schedule to, this Agreement. A reference in a Schedule to any paragraph is, except where it is expressly stated to the contrary, a reference to a paragraph in that Schedule;
TYPES OF CONTRACT MODIFICATIONS In order to expedite processing of a contract modification, where proposed changes involve more than one category below, each change should be submitted to OGS as a separate request.
Administrator Allowances and Conditions of Practice 4.1. Creation of New Designations/Positions
CONCLUSIONS OF LAW 4 1. The conduct described in the Findings of Fact constitute grounds for disciplinary 5 action pursuant to A.R.S. §§ 32-3552(A)(1) and (3) and violate the provisions of A.R.S. § 32- 6 3501(9)(i) which states, “Any conduct or practice which is contrary to recognized standards of 7 ethics of the respiratory therapy profession or any conduct or practice which does or might 8 constitute a danger to the health, welfare or safety of the patient or the public.”
