EXTRAS AND CLAIMS Sample Clauses

EXTRAS AND CLAIMS. Except as otherwise provided in this Contract, no payment for extra Work shall be made unless such extra Work and the price therefore have been authorized by advanced written order of HISD pursuant to Article 26. Claims for money other than the amount of each Job Order shall be determined as set forth below. A. Definition. Claim is any demand or assertion by the Contractor that it should be paid more money than the Job Order amount, as adjusted under Article 26, by the Project Manager because of action or inaction on the part of Project Manager, Architect/Engineer, or any party for whom HISD is responsible, or any party with whom HISD has separately contracted for other portions of the Project, including, but not limited to, any demand or assertion that Contractor’s performance has been delayed, interrupted or interfered with, that Contractor’s performance has been accelerated, constructively accelerated, or suspended, that Contractor’s performance has been wrongfully terminated, that the Contract Documents have been misinterpreted, that there has been a failure of payment, that Contractor has encountered concealed or unknown conditions, that Contractor has encountered hazardous materials, that there are problems with the Contract Documents, or the timing of Project Manager approvals or decisions, that actions of HISD have been intentionally wrongful or deceptive, that the amount of time or money granted in a Construction Change Directive is inadequate, that an item treated as a minor change in the Work should have been treated as a Supplemental Job Order, that a time extension grant was inadequate, or that Contractor is entitled to any other relief, on any legal theory, related to the Work and this Contract. B. Within five (5) days of the first occurrence of any event that Contractor has any reason to believe might result in a Claim, or within five (5) days of Contractor’s discovery of the first occurrence of an event that Contractor has any reason to believe might result in a Claim if the first occurrence of the event was willfully hidden from the Contractor, the Contractor shall file a written document clearly captioned “Notice of Claim” with the HISD General Manager. The notice shall clearly set out the specific matter of complaint, and the impact or damages, which may occur or have occurred as a result thereof, to the extent the impact or damages can be assessed at the time of the notice. If the impact or damages cannot be assessed as of the date of t...
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs

Related to EXTRAS AND CLAIMS

  • Litigation and Claims No litigation, claim, investigation, administrative proceeding or similar action (including those for unpaid taxes) against Borrower is pending or threatened, and no other event has occurred which may materially adversely affect Borrower’s financial condition or properties, other than litigation, claims, or other events, if any, that have been disclosed to and acknowledged by Lender in writing.

  • Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.

  • Taxes and Claims 72 Section 8.5 Insurance.............................................................................72 Section 8.6

  • Defense of Third Party Claims In the case of a Third-Party Claim, the Indemnifying Party shall have the right: (a) to control and conduct any proceedings or negotiations in connection therewith and necessary or appropriate to defend the claim, (b) to take all other reasonable steps or proceedings to settle or defend any such Third-Party Claim; provided, that the Indemnifying Party shall not settle any Third-Party Claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, conditioned, or delayed), and (c) to employ counsel designated by the Indemnifying Party to contest any such Third-Party Claim in the name of the Indemnified Party or otherwise. The Indemnifying Party shall, within fifteen (15) days of receipt of a Third-Party Claim Notice (the “Indemnity Notice Period”), give written notice to the Indemnified Party of its intention to assume the defense of such Third-Party Claim. If the Indemnifying Party does not deliver to the Indemnified Party within the Indemnity Notice Period written notice that the Indemnifying Party shall assume the defense of any such Third-Party Claim, then the Indemnified Party may defend against any such Third-Party Claim in any such manner as it may deem appropriate, provided, that the Indemnified Party shall not settle any such Third-Party Claim without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, conditioned, or delayed. In the event that the Indemnifying Party does assume the defense of such Third-Party Claim, the Indemnified Party shall have the right to fully participate in (but not control) such defense (including with counsel of its choice), at its sole expense, and the Indemnifying Party shall reasonably cooperate with the Indemnified Party in connection with such participation. In the event that either the Indemnifying Party or the Indemnified Party assumes the defense of a Third-Party Claim as provided above (the “Controlling Party”), the non-Controlling Party shall have the right to fully participate (but not control) in such defense (including with counsel of its choice), at its sole expense, and the Controlling Party shall reasonably cooperate with the non-Controlling Party in connection with such participation; provided, however, that Buyer and Seller shall each use its commercially reasonable efforts with respect to any information shared pursuant to this Section 7.3(b) to preserve attorney-client privilege.

  • Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.

  • Claims and Suits (a) The Receiver shall have the right, in its discretion, to (i) defend or settle any claim or suit against the Assuming Bank with respect to which the Receiver has indemnified the Assuming Bank in the same manner and to the same extent as provided in Article XII, and (ii) defend or settle any claim or suit against the Assuming Bank with respect to any Liability Assumed, which claim or suit may result in a loss to the Receiver arising out of or related to this Agreement, or which existed against the Failed Bank on or before Bank Closing. The exercise by the Receiver of any rights under this Section 9.3(a) shall not release the Assuming Bank with respect to any of its obligations under this Agreement. (b) In the event any action at law or in equity shall be instituted by any Person against the Receiver and the Corporation as codefendants with respect to any asset of the Failed Bank retained or acquired pursuant to this Agreement by the Receiver, the Receiver agrees, at the request of the Corporation, to join with the Corporation in a petition to remove the action to the United States District Court for the proper district. The Receiver agrees to institute, with or without joinder of the Corporation as coplaintiff, any action with respect to any such retained or acquired asset or any matter connected therewith whenever notice requiring such action shall be given by the Corporation to the Receiver.

  • Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.

  • Defense of Infringement Claims In the event Licensee or Licensor becomes aware that Licensee’s or any of its Affiliates’ or any Sublicensees’ practice of the Licensed Patents is the subject of a claim for patent infringement by a Third Party, that Party shall promptly notify the other, and the Parties shall consider the claim and the most appropriate action to take. Licensee shall cause each of its Affiliates and each Sublicensee to notify Licensee promptly in the event such entity becomes aware that its practice of the Licensed Patents is the subject of a claim of patent infringement by another. To the extent Licensor takes any action, Licensor (or the ReGenX Licensors) shall have the right to require Licensee’s reasonable cooperation in any such suit, upon written notice to Licensee; and Licensee shall have the obligation to participate upon Licensor’s request, in which event, Licensor shall bear the cost of Licensee’s participation. Without Licensor’s prior written permission, Licensee must not settle or compromise any such suit in a manner that imposes any material obligations or restrictions on Licensor or the ReGenX Licensors or grants any rights to the Licensed Patents other than rights that Licensee has the right to grant under this Agreement.

  • COMPLAINTS AND GRIEVANCES 7.01 If an employee has a complaint concerning the application, interpretation, administration, or alleged violation of any of the provisions of this Agreement, he/she shall take the matter up orally with his/her immediate Supervisor or designate within five (5) business days after the circumstance giving rise to the complaint. The Supervisor or designate will give his/her answer to the 7.02 If such complaint or question is not settled to the satisfaction of the employee, then the following steps of the grievance procedure may be invoked in order. It is understood that a grievance must be lodged within five (5) business days after receiving the Supervisor’s or designate response to the complaint as per article 7.01. STEP 1 Any employee grievance shall be set forth in writing, in duplicate, and shall be presented to the Supervisor. The submissions shall include reference to the specific clause and article of the Agreement allegedly violated or misinterpreted and redress sought. The Supervisor shall review the grievance and reply in writing to the Union within five (5) business days, giving his/her disposition and his/her reason thereof. STEP 2 If a settlement has not been reached under Step 1, the employee may within five (5) business days of the Supervisor's reply, refer the grievance to the Administrator of the Home, at interest, or his/her nominee. The Administrator of the Home or his/her nominee together with the employee and his/her Supervisor, and his/her Xxxxxxx, shall meet within five (5) business days of reference to the Administrator of the Home. The Administrator of the Home shall give his/her reply in writing to the Union within five (5) business days after date of meeting. STEP 3 If settlement has not been reached under Step 2, the employee may refer the grievance to his/her Union Grievance Committee which may within five (5) business days of the Administrator's reply refer the grievance to the Director of Human Resources or his/her designate. Within five (5) business days the Director of Human Resources or his/her designate together with such other representation as may be chosen to represent the Employer shall meet with the Union Grievance Committee to discuss the grievance. At this meeting a full-time representative of the Union may be present, if his/her presence is requested by the Employer or the Union. Written reply to the grievance shall be given to the Union within five (5) business days after such meeting. If a grievance is not settled to the satisfaction of either party to this Agreement by the procedure outlined above, then either party may, within ten (10) working days of the reply of the Director of Human Resources, refer the grievance to arbitration in accordance with the provisions contained in Article 9. 7.03 Any of the time allowances provided in the Article may be extended by mutual agreement in writing between the Union and the Employer. 7.04 Notwithstanding the provisions of the Ontario Labour Relations Act, any grievance not initiated or appealed at any stage of the grievance procedure, including reference to arbitration within the limits stipulated, shall be considered settled on the basis of the last decision and NOT subject to further appeal. 7.05 No employee written reprimand shall be entered in an employee's personnel file unless the employee and Local Recording Secretary or designate are given a copy of such written reprimand. 7.06 Saturdays and Sundays and paid holidays shall not be considered working days within the scope of this Article.

  • Covered Claims Claim" means any claim, dispute or controversy between you and us that in any way arises from or relates to this Agreement, the Account, the issuance of any Card, any rewards program, any prior agreement or account. "Claim" includes disputes arising from actions or omissions prior to the date any Card was issued to you, including the advertising related to, application for or approval of the Account. "Claim" has the broadest possible meaning, and includes initial claims, counterclaims, cross-claims and third-party claims. It includes disputes based upon contract, tort, consumer rights, fraud and other intentional torts, constitution, statute, regulation, ordinance, common law and equity (including any claim for injunctive or declaratory relief). "Claim" does not include disputes about the validity, enforceability, coverage or scope of this Arbitration Provision or any part thereof (including, without limitation, the prohibition against class proceedings, private attorney general proceedings and/or multiple party proceedings described in Paragraph C.7 (the "Class Action Waiver"), the last sentence of Paragraph

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!