Failure to Submit Reports. The Contractor understands that failure to submit all written reports by the deadlines indicated above in Paragraphs III(B)(1) and III(B)(2), or other deadlines established by FCAC, may render the Contractor ineligible to receive the County funding for a minimum of three (3) funding cycles which begins with the subsequent Contract for Services’ s cycle.
Failure to Submit Reports. If a Contractor fails or refuses to provide the reports as required it will be treated as a breach of this Agreement and the Policy, and may be addressed under arbitration provisions pursuant to Article VII (Arbitration of Disputes) of this Agreement.
Failure to Submit Reports. If the Participant fails to submit two or more Reports consecutively by the due dates for submission (or, where the Commonwealth has granted the Participant an extension under clause 7.5(b), the due date for submission as extended under clause 7.5(b)), the Commonwealth may by notice in writing terminate this Funding Agreement.
Failure to Submit Reports. 3 Note: The Project Sponsor is required to provide complete Social Security numbers upon the request of the Agency.
Failure to Submit Reports. If Franchisee fails to submit the profit and loss statements required by this Section 11.3 on a timely basis, then BRCB will be entitled to pursue injunctive relief granting specific performance of this obligation. Franchisee acknowledges that BRCB will be irreparably harmed by the failure to receive timely reports. Pursuit of these remedies by BRCB does not constitute a waiver by BRCB of its right to pursue any and all other remedies available to it, including termination of this Agreement.
Failure to Submit Reports. If a Construction Contractor fails or refuses to provide the reports to the General Construction Contractor as required by Section VI.A, the Agency, upon notice from the General Construction Contractor or the Personal Services Contractor, shall consider but not be required to institute arbitration proceedings against the noncompliant Construction Contractor.
Failure to Submit Reports. Any failure by the Contractor to timely submit any reports, information or certifications required by this Contract, including the items required by Clause 4.28 (Submittal of Data), shall, in addition to any r ights a nd remedies a vailable to the E mployer under law or und er this C ontract, give t he Employer the right to delay reciprocal action for which such information is provided, or the date or event in connection with which the information is provided, for a period equal to any such delay by the Contractor. Any such delay by the Employer shall not affect or delay the scheduled Time for Completion nor the imposition of any delay damages.
Failure to Submit Reports. Any failure of either Party to timely submit any reports, information or certifications required by this Agreement, including the items required by Section 4.2, shall, in addition to any rights and remedies available to the receiving Party under law, give the receiving Party the right to delay reciprocal action for which such information is provided, or the date or event in connection with which the information is provided, for a period equal to any such delay by the delivering Party.
Failure to Submit Reports. Failure by the Grantee to submit the reports required pursuant to Section 2.4(d), 2.7 and 2.9 shall constitute a default, and the City Manager may, subject to any applicable cure period set forth in Article 6, terminate this Agreement in accordance with the provisions of Article 6. Further, the City Manager must approve these reports for the Grantee to be deemed to have met all conditions of the Grant Award.
Failure to Submit Reports. If Company fails to submit any report required by and in accordance with this Agreement, the City’s obligation to pay any Program Grants at the time, if any, will be suspended until Company has provided all required reports; provided, however, that if any report required hereunder is delinquent by more than one
(1) year, the City will have the right to terminate this Agreement following provision of notice and a thirty (30) day opportunity to cure in accordance with this Agreement.
