Final Capacity Liquidated Damages Sample Clauses

Final Capacity Liquidated Damages. (a) Contractor agrees that if based on the results of the Facility Capacity calculation performed in accordance with Exhibit 16A, the Facility shall have failed to achieve the Guaranteed Capacity, Contractor shall pay to Owner upon Facility Substantial Completion an amount equal to *** (the “Final Capacity Liquidated Damages”).
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
Final Capacity Liquidated Damages. Contractor agrees that if based on the Final Test Results of the Facility Capacity calculation performed in accordance with Exhibit 14C, the Facility shall have failed to achieve the Guaranteed Capacity, Contractor shall pay to Owner upon Substantial Completion an amount equal to the Contract Price multiplied by a fraction, the numerator of which is the Capacity Shortfall and the denominator of which is the Guaranteed Capacity (the “Final Capacity Liquidated Damages”). Payment. Payment of Liquidated Damages shall be made payable within thirty (30) Days after Contractor’s receipt of Owner’s invoice. Liquidated Damages shall bear interest at the interest rate set forth in Section 8.6. Amounts payable by Contractor to Owner pursuant to this Article 17 may be set off by Owner against the payment due for Final Completion under the final Application for Payment. Any amounts that Contractor is obligated to pay to Owner under this Article 17 are subject to the limitations set forth in Article 29.
Sample 1
Final Capacity Liquidated Damages. (a) Contractor agrees that if based on the results of the Facility Capacity calculation performed in accordance with Exhibit 16A, the Facility shall have failed to achieve the Guaranteed Capacity, Contractor shall pay to Owner upon Facility Substantial Completion an amount equal to (a) the Contract Price multiplied by the quotient of the *** divided by the *** (expressed as a percentage) plus (b) the *** (if any) due or that will be due under the ***, without duplication (the “Final Capacity Liquidated Damages”). *** CONFIDENTIAL MATERIAL REDACTED AND SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION. (b) In the event Contractor has paid Final Capacity Liquidated Damages pursuant to Section 17.5(a), and, following additional Capacity Tests conducted in compliance with the provisions set forth in Section 15.5, if the Facility Capacity calculation resulting from the last of such additional Capacity Tests (i) reduces the Capacity Shortfall, Owner shall reimburse Contractor the corresponding amount of Final Capacity Liquidated Damages resulting from such reduction or (ii) increases the Capacity Shortfall, Contractor shall pay to Owner additional Final Capacity Liquidated Damages calculated in accordance with Section 17.5(a).
Sample 1

Related to Final Capacity Liquidated Damages

  • Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.

  • Payment of Liquidated Damages If you supply all or some of your milk to a third party during a Month you must, if required by DFMC, immediately pay to DFMC liquidated damages for that Month calculated as follows: $X = W cents x (Y – Z) Where: $X is the amount payable by you to DFMC for the relevant Month. If $X is a negative amount, no amount is payable by you. Y is the average monthly litres you have supplied to DFMC based on the 12 months immediately preceding the relevant Month (or in the event you have not supplied DFMC for 12 months, the average monthly litres you have supplied to DFMC during the period you have supplied DFMC). Z is the number of litres supplied to DFMC by you for the relevant Month.

  • Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.

  • Action in Shareholder Capacity Only The parties acknowledge that this Agreement is entered into by Shareholder solely in such Shareholder’s capacity as the Beneficial Owner of such Shareholder’s Owned Securities and nothing in this Agreement restricts or limits any action taken by such Shareholder in its capacity as a director or officer of the Company or any of its Affiliates and the taking of any actions (or failure to act) in its capacity as an officer or director of the Company, or any of its Affiliates, will not be deemed to constitute a breach of this Agreement, regardless of the circumstances thereto.

  • Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.

  • Action in Stockholder Capacity Only Stockholder makes no agreement or understanding herein as director or officer of the Company. Stockholder signs solely in his capacity as a recordholder and beneficial owner of the Shares, and nothing herein shall limit or affect any actions taken in his capacity as an officer or director of the Company.

  • Agent in Individual Capacity Xxxxx Fargo and its Affiliates may make loans to, issue letters of credit for the account of, accept deposits from, provide Bank Products to, acquire Equity Interests in, and generally engage in any kind of banking, trust, financial advisory, underwriting, or other business with any Loan Party and its Subsidiaries and Affiliates and any other Person party to any Loan Document as though Xxxxx Fargo were not Agent hereunder, and, in each case, without notice to or consent of the other members of the Lender Group. The other members of the Lender Group acknowledge (and by entering into a Bank Product Agreement, each Bank Product Provider shall be deemed to acknowledge) that, pursuant to such activities, Xxxxx Fargo or its Affiliates may receive information regarding a Loan Party or its Affiliates or any other Person party to any Loan Documents that is subject to confidentiality obligations in favor of such Loan Party or such other Person and that prohibit the disclosure of such information to the Lenders (or Bank Product Providers), and the Lenders acknowledge (and by entering into a Bank Product Agreement, each Bank Product Provider shall be deemed to acknowledge) that, in such circumstances (and in the absence of a waiver of such confidentiality obligations, which waiver Agent will use its reasonable best efforts to obtain), Agent shall not be under any obligation to provide such information to them. The terms “Lender” and “Lenders” include Xxxxx Fargo in its individual capacity.

  • Legal Capacity All parties to the Mortgage Note and the Mortgage had legal capacity to enter into the Mortgage Loan and to execute and deliver the Mortgage Note and the Mortgage, and the Mortgage Note and the Mortgage have been duly and properly executed by such parties. The Mortgagor is a natural person;

  • Up-Front Payment At all times during the Effective Period other than those periods for which payment of all Billed Amounts is By Invoice, Customer shall maintain on file with 8x8 or the billing 8x8 Affiliate (as applicable) complete, accurate, and up-to-date information for at least one valid, working credit card or Customer account (sufficient to permit ACH withdrawals). Payment of all Billed Amounts – other than those for which 8x8 has agreed to payment By Invoice – shall be by charge to such credit card(s) or by ACH withdrawal from such account(s), at or near time of billing, and Customer hereby authorizes 8x8 to make such charges or withdrawals. Where payment is by such charge or withdrawal, (a) 8x8 shall post a statement of the Billed Amounts in the relevant account at or near the time of the first attempted charge or withdrawal and shall thereafter make commercially reasonable efforts to notify Customer by email and/or telephone if the charge or withdrawal is not successful and (b) Billed Amounts shall be due within fourteen (14) days of such posting.

  • Shareholder Capacity By executing and delivering this -------------------- Agreement, Shareholder makes no agreement or understanding herein in his capacity as a director or officer of the Company or any subsidiary of the Company. Shareholder signs solely in his capacity as the beneficial owner of Shareholder's Shares and nothing herein shall limit or affect any actions taken by Shareholder in his capacity as an officer or director of the Company or any subsidiary of the Company.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!