Final Extension of Time Sample Clauses

Final Extension of Time. If necessary or required, the Contractor shall make a written request for a substantial or final extension of time to complete the Work, which shall be evaluated in accordance with these General Conditions. The Project Manager shall issue a voucher calling for payment of any part or all of the balance due for Work performed under the Contract, including monies retained hereunder, less any and all deductions authorized to be made by the City, whether under this Contract or under Law, less an amount that is double the amount the City considers necessary to ensure the Contractor's completion of the balance of the Work. Such a payment shall be considered a partial payment and not a final payment. No substantial completion payment shall be made under this Section where the Contractor has failed to complete the Work within the time fixed for such completion in the Contract Documents, as the same may have been extended, until an extension or extensions of time for the completion of the Work have been acted upon pursuant to Section 3.06. No further partial payments shall be made to the Contractor after the City issues a Certificate of Substantial Completion, except the substantial completion payment and vouchers for progress payments that were properly filed with the City prior to the date of issuance of the Certificate of Substantial Completion. However, the City may grant a waiver for further partial payments after the date of substantial completion to permit payments for change order work, Extra Work and/or release of retainage and deposits pursuant to Sections 5.02 and 5.05. The Contractor shall request such a waiver regarding further partial payments in writing. If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or due to issuance of change notes affecting final completion, and the Project Manager so confirms, the Director, upon request by the Contractor and certification by the Project Manager, and without terminating the Contract, direct payment of the balance due for that portion of the Work as fully complete and accepted. The Contractor acknowledges that nothing contained in this Section is intended to or shall in any way diminish the force and effect of Section 3.06 hereof.
Sample 1
AutoNDA by SimpleDocs

Related to Final Extension of Time

  • Extension of Time If the Executive shall be in violation of any provision of this Article 6, then each time limitation set forth in this Article 6 shall be extended for a period of time equal to the period of time during which such violation or violations occur. If the Company seeks injunctive relief from such violation in any court, then the covenants set forth in this Article 6 shall be extended for a period of time equal to the pendency of such proceeding including all appeals by the Executive.

  • No Extension of Time If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures set forth herein.

  • Delays and Extension of Time If the Contractor is delayed at any time in the progress of providing goods and/or services by an act or neglect of the District, or by changes ordered in the work, or by labor disputes, strikes, insurrections, fire, acts of God; unusual but well documented and excusable delays in performance, or other causes beyond the Contractor’s control, or by delay authorized by the District, then the contract Term of service may be extended by a contract amendment for such reasonable time as the District and the Contractor may agree.

  • Extension of Time Limits The time limits referred to in this Article may be extended by mutual agreement of the parties in writing.

  • Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely:

  • DELAYS AND EXTENSIONS OF TIME 8.3.1 If the Contractor is delayed at any time in the progress of the Work by any act or failure to act by the State or the Architect, or by any employee of either, or by any separate contractor employed by the State, or by changes ordered in the Work, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any causes beyond the Contractor's control, or by delay authorized by the State pending alternative dispute resolution proceedings, or by any other cause which may justify the delay, then the Contract Time shall be extended by Change Order for such reasonable time as recommended by the Architect and approved by the State.

  • Extension of Defects Liability Period The Defects Liability Period shall be deemed to be extended till the identified Defects under Clause 17.2 have been remedied or rectified.

  • EXTENSION OF USE The Contract may be extended to additional States or governmental jurisdictions upon mutual written agreement between New York State (the lead contracting State) and the Contractor. Political subdivisions and other authorized entities within each participating State or governmental jurisdiction may also participate in the Contract if such State normally allows participation by such entities. New York State reserves the right to negotiate additional minimum NYS Vehicle Discounts based on any increased volume generated by such extensions.

  • Calculation of Time Periods Unless otherwise specified, in computing any period of time described in this Agreement, the day of the act or event after which the designated period of time begins to run is not to be included and the last day of the period so computed is to be included, unless such last day is a Saturday, Sunday or legal holiday under the laws of the State in which the Property is located, in which event the period shall run until the end of the next day which is neither a Saturday, Sunday or legal holiday. The final day of any such period shall be deemed to end at 5 p.m., local time.

  • Calculation of Time For the purposes of this Agreement, “days” refers to calendar days unless otherwise specified.

Time is Money Join Law Insider Premium to draft better contracts faster.