Final Tally Sample Clauses

Final Tally. Within seven (7) calendar days after the close of the Claim Period, the Class Action Settlement Administrator shall provide the Parties with the number of valid and timely Claims received.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
Final Tally. The Settlement Administrator shall provide weekly reports to counsel for Defendant and Plaintiffs stating the number of claims received, the number of claims denied, and the number of claims approved. Within seven (7) calendar days after the close of the Claim Period, the Settlement Administrator shall provide the Parties with the total number of valid and timely Claims received and approved.
Sample 1Sample 2
Final Tally. The Settlement Administrator shall provide weekly reports to counsel for Defendant and Plaintiffs stating the number of Claims received, the number of Claims electing the Cash Benefit option, and the number of any Claims electing the Cash Benefit option that have been denied. Within seven (7) calendar days after the close of the Claim Period, the Settlement Administrator shall provide the Parties with the total number of valid and timely Claims received and approved electing the Cash Benefit option, and the number of mattress orders associated with each approved Claim Form, to establish the amount of the Cash Benefit Fund. The Settlement Administrator shall also provide Defendant with a list of Settlement Class Members who submitted a valid and timely Claim electing the Cash Benefit option and the number of mattress orders placed during the Class Period by each Class Member.
Sample 1
Final Tally. The Settlement Administrator shall provide weekly reports to counsel for Defendant and Plaintiffs stating the number of Claims received, the number of Claims electing the Cash Benefit option, the number of any Claims electing the Cash Benefit option that have been denied, the name of any class member(s) that have submitted a valid opt-out request, and the name of any class member(s) that submitted an invalid opt-out request. Within seven (7) calendar days after the close of the Claim Period, the Settlement Administrator shall provide the Parties with the total number of valid and timely Claims received and approved electing the Cash Benefit option. The Settlement Administrator shall separately provide to Defendant, but not Class Counsel, the identities of each such Settlement Class Member and those that have excluded themselves from the Settlement Class.
Sample 1

Related to Final Tally

  • Final Completion Date Final Completion for the Work as defined in Article 6.1.3 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by October 31, 2024.

  • Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.

  • Maximum Occupancy No more than two (2) guests per one (1) resident (who is present) are permitted in a student room/suite/apartment at any given time unless otherwise approved by the University (Residential Life).

  • Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.

  • Cost of the Work The sum of all allowable costs necessarily incurred and paid by Contractor in the proper performance of the Work.

  • Physical/Occupational Therapy This plan covers physical and occupational therapy when: • ordered by a physician; • received from a licensed physical or occupational therapist; • a program is implemented to provide habilitative or rehabilitative services. See Autism Services when physical therapy and occupational therapy services are rendered as part of the treatment of autism spectrum disorder. The amount you pay and any benefit limit will be the same whether the services are provided for habilitative or rehabilitative purposes.

  • Punchlist Upon completion of the Performance Tests and prior to Substantial Completion of a Subproject, Owner and Contractor shall inspect the Subproject, and Contractor shall prepare a proposed Punchlist of items identified as needing to be completed or corrected as a result of such inspection. Contractor shall promptly provide the proposed Punchlist to Owner for its review, together with an estimate of the time and cost necessary to complete or correct each Punchlist item. Contractor shall add to the proposed Punchlist any Punchlist items that are identified by Owner within ten (10) Days after Owner’s receipt of the proposed Punchlist from Contractor, and Contractor shall immediately initiate measures to complete or correct, as appropriate, any item on Contractor’s proposed Punchlist (including those items identified by Owner during Owner’s review) that are not of a Punchlist nature. Notwithstanding anything to the contrary in this Agreement, Contractor and Owner are not required as a condition of Substantial Completion of a Subproject to agree upon and identify every Punchlist item and include it on the Punchlist, but Contractor is required to complete as a condition of Substantial Completion of such Subproject that does not meet the definition of Punchlist as provided in Section 1.1. In the event of a dispute regarding whether a specific item of Work meets the definition of Punchlist under Section 1.1, the Parties shall resolve such dispute in accordance with Section 18.1A. Owner shall provide Contractor with access to the Work after Substantial Completion of a Subproject sufficient to enable Contractor to complete all Punchlist items, so long as such access does not unreasonably interfere with operation of a Subproject after Substantial Completion of the Subproject or the Existing Facility and subject to any reasonable security or safety requirements of Owner. Upon Contractor’s completion or correction of any items necessary to achieve Substantial Completion of a Subproject, as modified by any Owner additions, such Punchlist shall govern Contractor’s performance of the Punchlist items up to Final Completion. All Work on the Punchlist shall be completed by the date required for Final Completion, as specified in Section 5.3C, or Owner may, in addition to any other rights that it may have under this Agreement, complete such Punchlist Work at the expense of Contractor. In the event Owner elects to complete such Punchlist Work, Contractor shall pay Owner, within ten (10) Days after receipt of written notice from Owner, all reasonable costs and expenses incurred by Owner in performing such Punchlist Work, or, at Owner’s sole discretion, Owner may withhold or offset amounts owed to Contractor or collect on the Letter of Credit in accordance with Section 7.8 in the amount of such costs and expenses. Any Defective Work identified after agreement between the Parties of the Punchlist shall be corrected by Contractor as a Warranty item under Article 12.

  • Construction Period During the construction period, Redeveloper agrees to keep the construction area, including completed operations insured against loss or damage by fire, and such other risks, casualties, and hazards as are customarily covered by builders’ risk or extended coverage policies in an amount not less than the replacement value but allowing for reasonable coinsurance clauses and deductibles. In the event of any insured damage or destruction, Redeveloper agrees to use its good faith efforts to commence restoration of the Private Improvements to its prior condition within nine (9) months from the date of the damage or destruction, and shall diligently pursue the same to completion.

  • Substantial Completion Section 7.4.1 When Supplier believes that it has achieved the requirements of Substantial Completion, Supplier shall provide written notice (the “Notice of Substantial Completion”) to System Owner stating that Supplier has achieved Substantial Completion, together with copies of all documents (as identified in the definition of Substantial Completion) that are required to be delivered to System Owner to meet Substantial Completion that have not been previously delivered. Section 7.4.2 Upon receipt of the Notice of Substantial Completion, System Owner shall promptly proceed to obtain Independent Engineer’s review and approval of the Notice of Substantial Completion and the Commissioning Report within a reasonable time, but in no event more than ten (10) Business Days following receipt of the Notice of Substantial Completion and all accompanying documents or such longer period of time as specified in the Construction Schedule (the “Substantial Completion Review Period”). Section 7.4.3 Supplier shall provide System Owner with reasonable notice of the date and time of the inspection or review of the System by a representative of the applicable Governmental Authority or Host Utility, if required, for purposes of achieving Substantial Completion, and System Owner shall have the right to have one or more representatives and the Independent Engineer present during such inspection or review. If the representative of the applicable Governmental Authority or Host Utility notifies Supplier or System Owner that the requirements for achieving Substantial Completion have not been achieved, then Supplier shall promptly take such action as necessary to achieve such requirements and, to the extent applicable, schedule another inspection or review of the System. Such procedure shall be repeated until such inspection or review has been satisfactorily completed and approved. Section 7.4.4 If System Owner and the Independent Engineer approve the Notice of Substantial Completion, System Owner shall, within the Substantial Completion Review Period, (a) notify Supplier of its approval and (b) issue written notice to Supplier to complete the Work (the “Notice to Complete”). Section 7.4.5 If System Owner or the Independent Engineer has a reasonable basis not to approve the Notice of Substantial Completion because the requirements for Substantial Completion have not been met, System Owner shall, within the Substantial Completion Review Period, notify Supplier of its non-approval and include a detailed explanation for the basis thereof. Supplier shall promptly undertake such action or work as necessary to achieve such requirements and shall then issue another Notice of Substantial Completion to System Owner stating that Supplier believes that such requirements have been achieved. Such procedure shall be repeated until Substantial Completion is achieved. If Supplier disputes the reasons stated in System Owner’s notification, then such dispute shall be resolved in accordance with Article XIX.

  • Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!