Years The determination of the arbitrators shall be limited solely to the issue of whether Landlord's or Tenant's submitted Market Rent is the closest to the actual Market Rent as determined by the arbitrators, taking into account the requirements of item (b), above.
Commencement Date Landlord shall deliver possession of the Premises to Tenant on the date (the “Delivery Date”) that Landlord’s Market Ready Improvements described on EXHIBIT C attached hereto and the Tenant Improvements to be completed by Landlord pursuant to the Work Letter Agreement attached hereto as EXHIBIT D are substantially completed. For purposes of this Lease, Landlord’s Market Ready Improvements and the Tenant Improvements shall be deemed to be “substantially completed” when Landlord’s Market Ready Improvements and the Tenant Improvements have been completed in accordance with any plans and specifications therefor, subject only to the completion of any minor punch-list items, and the City of Sunnyvale has completed a final inspection of such work and issued a temporary certificate of occupancy or other written approvals permitting legal occupancy of the Premises. The term of this Lease (“Term”) shall be seventy-six (76) months commencing on the date (the “Commencement Date”) which is thirty (30) days from the Delivery Date. If the Delivery Date does not occur on or before May 1, 2018, for any reason other than (i) ArcTec’s failure to complete the Final Plans and Specifications (as such term is defined in the Work Letter attached as EXHIBIT D) and submit such Final Plans and Specifications (and any other documentation required by the City of Sunnyvale for the issuance of a building permit for the Tenant Improvements) to Landlord’s general contractor by January 8, 2018, (ii) the City requiring Landlord to stop construction due to its commencement of the Tenant Improvements before the permits therefor were issued or (iii) delays caused by the acts or omission of Tenant, as defined in Paragraph 3(c) below, then the date Tenant is otherwise obliged to commence payment of Rent shall be delayed by one (1) additional day for each day the Delivery Date is delayed beyond such date.
Tax Periods Beginning Before and Ending After the Closing Date The Company or the Purchaser shall prepare or cause to be prepared and file or cause to be filed any Returns of the Company for Tax periods that begin before the Closing Date and end after the Closing Date. To the extent such Taxes are not fully reserved for in the Company’s financial statements, the Sellers shall pay to the Company an amount equal to the unreserved portion of such Taxes that relates to the portion of the Tax period ending on the Closing Date. Such payment, if any, shall be paid by the Sellers within fifteen (15) days after receipt of written notice from the Company or the Purchaser that such Taxes were paid by the Company or the Purchaser for a period beginning prior to the Closing Date. For purposes of this Section, in the case of any Taxes that are imposed on a periodic basis and are payable for a Taxable period that includes (but does not end on) the Closing Date, the portion of such Tax that relates to the portion of such Tax period ending on the Closing Date shall (i) in the case of any Taxes other than Taxes based upon or related to income or receipts, be deemed to be the amount of such Tax for the entire Tax period multiplied by a fraction the numerator of which is the number of days in the Tax period ending on the Closing Date and the denominator of which is the number of days in the entire Tax period (the “Pro Rata Amount”), and (ii) in the case of any Tax based upon or related to income or receipts, be deemed equal to the amount that would be payable if the relevant Tax period ended on the Closing Date. The Sellers shall pay to the Company with the payment of any taxes due hereunder, the Sellers’ Pro Rata Amount of the costs and expenses incurred by the Purchaser or the Company in the preparation and filing of the Tax Returns. Any net operating losses or credits relating to a Tax period that begins before and ends after the Closing Date shall be taken into account as though the relevant Tax period ended on the Closing Date. All determinations necessary to give effect to the foregoing allocations shall be made in a reasonable manner as agreed to by the parties.
Initial Term This Agreement shall become effective as of the date first written above (the “Start Date”) and shall continue thereafter throughout the period that ends two (2) years after the Start Date (the “Initial Term”).
Vesting Commencement Date Exercise Price per Share: Total Number of Shares: Type of Option: Non-Qualified Stock Option/Incentive Stock Option
Original Term The weighted average original term for the Receivables is at least 65 months.
Term Commencement Date The term of this Agreement shall commence on , 2020 (the “Commencement Date”) and, unless earlier terminated in accordance with the terms of this Agreement, shall end on June 30, 2055 (the “Term”).
Fixed Term The initial term of this Agreement (the "Fixed Term") shall commence on the Commencement Date and shall expire on the fifteenth (15th) anniversary of the Commencement Date.
Start Date The Executive’s employment with the Company shall commence on March 30, 2018 (the “Start Date”).
months All unpaid principal and accrued and unpaid interest with respect to each Term Loan is due and payable in full on the Maturity Date. Each Term Loan may only be prepaid in accordance with Sections 2.2(c) and 2.2(d).
