ETHICS IN PUBLIC CONTRACTING This Contract incorporates by reference Article 9 of the Arlington County Purchasing Resolution, as well as all state and federal laws related to ethics, conflicts of interest or bribery, including the State and Local Government Conflict of Interests Act (Code of Virginia § 2.2-3100 et seq.), the Virginia Governmental Frauds Act (Code of Virginia § 18.2-498.1 et seq.) and Articles 2 and 3 of Chapter 10 of Title 18.2 of the Code of Virginia, as amended (§ 18.2-438 et seq.). The Contractor certifies that its proposal was made without collusion or fraud; that it has not offered or received any kickbacks or inducements from any other offeror, supplier, manufacturer or subcontractor; and that it has not conferred on any public employee having official responsibility for this procurement any payment, loan, subscription, advance, deposit of money, services or anything of more than nominal value, present or promised, unless consideration of substantially equal or greater value was exchanged.
Certification of Meeting or Exceeding Tobacco-Free Workplace Policy Minimum Standards A. Grantee certifies that it has adopted and enforces a Tobacco-Free Workplace Policy that meets or exceeds all of the following minimum standards of: i. Prohibiting the use of all forms of tobacco products, including but not limited to cigarettes, cigars, pipes, water pipes (hookah), bidis, kreteks, electronic cigarettes, smokeless tobacco, snuff and chewing tobacco; ii. Designating the property to which this Policy applies as a "designated area,” which must at least comprise all buildings and structures where activities funded under this Grant Agreement are taking place, as well as Grantee owned, leased, or controlled sidewalks, parking lots, walkways, and attached parking structures immediately adjacent to this designated area; iii. Applying to all employees and visitors in this designated area; and iv. Providing for or referring its employees to tobacco use cessation services. B. If Grantee cannot meet these minimum standards, it must obtain a waiver from the System Agency.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Musculoskeletal Injury Prevention and Control The hospital in consultation with the Joint Health and Safety Committee (JHSC) shall develop, establish and put into effect, musculoskeletal prevention and control measures, procedures, practices and training for the health and safety of employees.
Reasonable Suspicion Testing All Employees Performing Safety-Sensitive Functions A. Reasonable suspicion testing for alcohol or controlled substances may be directed by the Employer for any employee performing safety-sensitive functions when there is reason to suspect that alcohol or controlled substance use may be adversely affecting the employee’s job performance or that the employee may present a danger to the physical safety of the employee or another. B. Specific objective grounds must be stated in writing that support the reasonable suspicion. Examples of specific objective grounds include but are not limited to: 1. Physical symptoms consistent with alcohol and/or controlled substance use; 2. Evidence or observation of alcohol or controlled substance use, possession, sale, or delivery; or 3. The occurrence of an accident(s) where a trained manager, supervisor or lead worker suspects alcohol or other controlled substance use may have been a factor.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
CERTIFICATION REGARDING DRUG-FREE WORKPLACE REQUIREMENTS 1. The Contractor certifies that it will provide a drug-free workplace by: a. Publishing a statement notifying employees that the unlawful manufacture, distribution, dispensing, possession or use of a controlled substance is prohibited in the Contractor’s workplace and specifying the actions that will be taken against employees for violation of such prohibition;
Data Practices The Parties acknowledge that this Agreement is subject to the requirements of Minnesota’s Government Data Practices Act, Minnesota Statutes, Section 13.01
Background and Narrative of Budget Reductions 2. Assumptions Used in the Deficit Reduction Plan: - EBF and Estimated New Tier Funding: - Equal Assessed Valuation and Tax Rates: - Employee Salaries and Benefits: - Short and Long Term Borrowing: - Educational Impact: - Other Assumptions: - Has the district considered shared services or outsourcing (Ex: Transportation, Insurance) If yes please explain: