Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement.
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Delivery Schedule The scheduled months of delivery of the Aircraft are listed in the attached Table 1. Exhibit B describes certain responsibilities for both Customer and Boeing in order to accomplish the delivery of the Aircraft.
Project Location & Description The Project, for which the provision of financial assistance is the subject of this Agreement, is hereby described as follows:
Recovery Schedule If the initial schedule or any current updates fail to reflect the Work’s actual plan or method of operation, or a contractual milestone date is more than fifteen (15) days behind, Owner may require that a recovery schedule for completion of the remaining Work be submitted. The Recovery Schedule must be submitted within seven (7) calendar days of Owner’s request. The Recovery Schedule shall describe in detail Construction Contractor’s plan to complete the remaining Work by the required Contract milestone date. The Recovery Schedule submitted shall meet the same requirements as the original Construction Schedule. The narrative submitted with the Recovery Schedule should describe in detail all changes that have been made to meet the Contract milestone dates.
Shipping must be Freight On Board Destination to the delivery location designated on the Customer purchase order The Contractor will retain title and control of all goods until delivery is completed and the Customer has accepted the delivery. All risk of transportation and all related charges are the responsibility of the Contractor. The Customer will notify the Contractor and H-GAC promptly of any damaged goods and will assist the Contractor in arranging for inspection. The Contractor must file all claims for visible or concealed damage. Unless otherwise stated in the Agreement, deliveries must consist only of new and unused merchandise.
Shift Schedule The words "shift schedule" when used in this Agreement shall mean a timetable of the shifts and off days assigned to a position or group of positions which commences at the beginning of a pay period and includes one complete rotation of said shifts.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Wage Schedule The pay rate (including increments and stated extras) as agreed to and hereinafter in this Schedule provided, shall be in effect during the term of the Agreement, from April 1, 2019 to March 31, 2022.
Work Location While employed by the Company hereunder, the Executive shall perform his duties (when not traveling or engaged elsewhere in the performance of his duties) at the offices of the Company in Bermuda. The Executive shall travel to such places on the business of the Company in such manner and on such occasions as the Company may from time to time reasonably require.
