FUGITIVE DUST EMISSION CONTROL Sample Clauses

FUGITIVE DUST EMISSION CONTROL. The A-E shall comply with the requirements of the OC Waste & Recycling Fugitive Dust Emission Control Plan in conformance with the SCAQMD Rule 403. The A-E shall also notify OC Waste & Recycling any condition that could lead to noncompliance with the permit requirements. The A-E shall submit a Dust Control Plan to be received and approved by the County. If the A-E fails or refuses to correct the noncompliance immediately, OC Waste & Recycling may terminate the A-E’s right to proceed with the work, by written notice to the A-E. In such event, OC Waste & Recycling may take over the work and prosecute the same to completion, by contract or otherwise at the A-E’s expense, and may take possession of and utilize in completing the work such materials, appliances, and plants as may be on the site of the work and necessary therefore. Whether or not the A-E’s right to proceed with the work is terminated, the A-E and the A-E’s Sureties shall be liable for any damage to the County resulting from the A-E’s refusal or failure to complete the work within the specified time. The A-E shall not be entitled to any time extensions or compensation for any cost due to any such action as a result of the A-E’s failure to comply with those provisions of the OC Waste & Recycling Fugitive Dust Emission Control Plan within the A-E’s control. The A-E shall be responsible for ensuring that all sub A-E(s) comply with the provisions of this section. The A-E shall be liable for any action or fine imposed by the SCAQMD on those incidents of noncompliance that are within the A-E’s area of responsibility. OC Waste & Recycling’s Fugitive Dust Emission Control Plan (SCAQMD Rule 403-Fugitive Dust-April 1993) is available for review by the A-E in the offices of the OC Waste & Recycling Project Manager.

FUGITIVE DUST EMISSION CONTROL. The Contractor shall comply with the requirements of the County Fugitive Dust Emission Control Plan in conformance with the SCAQMD Rule 403. The Contractor shall also notify County of any condition that could lead to noncompliance with the permit requirements. The Contractor shall submit a Dust Control Plan to be received and approved by the County. If the Contractor fails or refuses to correct the noncompliance immediately, County may terminate the Contractor’s right to proceed with the work, by written notice to the Contractor. In such event, County may take over the work and prosecute the same to completion, by Contract or otherwise at the Contractor’s expense, and may take possession of and utilize in completing the work such materials, appliances, and plants as may be on the site of the work and necessary therefore. Whether or not the Contractor’s right to proceed with the work is terminated, the Contractor and the Contractor’s Sureties shall be liable for any damage to the County resulting from the Contractor’s refusal or failure to complete the work within the specified time. The Contractor shall not be entitled to any time extensions or compensation for any cost due to any such action as a result of the Contractor’s failure to comply with those provisions of the County Fugitive Dust Emission Control Plan within the Contractor’s control. The Contractor shall be responsible for ensuring that all Subcontractor(s) comply with the provisions of this section. The Contractor shall be liable for any action or fine imposed by the SCAQMD on those incidents of noncompliance that are within the Contractor’s area of responsibility. The County’s Fugitive Dust Emission Control Plan (SCAQMD Rule 403-Fugitive Dust-April 1993) is available for Contractor’s review in the offices of the Contract Administrator.

See All (14)

FUGITIVE DUST EMISSION CONTROL. Contractor shall comply with SCAQMD Rule 403 including, if applicable to prepare and submit to County and for acceptance by SCAQMD a Fugitive Dust Emission Control Plan, as required for Project work. Contractor shall also notify OWNER of any condition that could lead to noncompliance with the Rule 403 requirements. If a Fugitive Dust Emissions Control Plan is required pursuant to Rule 403, Contractor may not conduct any activities governed by SCAQMD Rule 403 until OWNER has accepted Contractor's Plan and the Plan is accepted by SCAQMD. If Contractor fails or refuses to immediately correct any noncompliance with the provisions of this Section, OWNER may terminate Contractor's right to proceed with the work and OWNER may exercise its rights under the "TERMINATION FOR CAUSE" Section of these General Conditions. Whether or not Contractor's right to proceed with the work is terminated, Contractor and the Contractor's sureties shall be liable for any damage to the OWNER resulting from Contractor's refusal or failure to complete the work within the specified time. Contractor shall not be entitled to any time extensions or compensation for any cost due to any such action as a result of Contractor's failure to comply with the provisions of the accepted Fugitive Dust Emission Control Plan. Contractor shall be responsible for ensuring that all Subcontractor(s) comply with the provisions of this Section. Contractor shall be liable for any action or fine imposed by the SCAQMD on those incidents of noncompliance that are within the Contractor's area of responsibility.

See All (13)

FUGITIVE DUST EMISSION CONTROL. The Contractor shall comply with the requirements of the OC Waste & Recycling Fugitive Dust Emission Control Plan in conformance with the SCAQMD Rule

FUGITIVE DUST EMISSION CONTROL. Contractor shall comply with the requirements of the OC Waste & Recycling Fugitive Dust Emission Control Plan in conformance with the SCAQMD Rule 403. The Contractor shall also notify OC Waste & Recycling of any condition that could lead to noncompliance with the permit requirements. Contractor shall submit a Dust Control Plan to be received and approved by the County. If Contractor fails or refuses to correct the noncompliance immediately, OC Waste & Recycling may terminate the Contractor’s right to proceed with the work, by written notice to the Contractor. In such event, OC Waste & Recycling may take over the work and prosecute the same to completion, by Contract or otherwise at the Contractor’s expense, and may take possession of and utilize in completing the work such materials, appliances, and plants as may be on the site of the work and necessary therefore. Whether or not the Contractor’s right to proceed with the work is terminated, the Contractor and the Contractor’s Sureties shall be liable for any damage to the County resulting from the Contractor’s refusal or failure to complete the work within the specified time. The Contractor shall not be entitled to any time extensions or compensation for any cost due to any such action as a result of the Contractor’s failure to comply with those provisions of the OC Waste & Recycling Fugitive Dust Emission Control Plan within the Contractor’s control. The Contractor shall be responsible for ensuring that all Subcontractor(s) comply with the provisions of this section. The Contractor shall be liable for any action or fine imposed by the SCAQMD on those incidents of noncompliance that are within the Contractor’s area of responsibility. OC Waste & Recycling’s Fugitive Dust Emission Control Plan (SCAQMD Rule 403-Fugitive Dust-April 1993) is available for Contractor’s review in the offices of the Site PM.

Related to FUGITIVE DUST EMISSION CONTROL

Erosion Control a. The Purchaser shall construct slash and debris erosion barriers, dips, water bars or ditches in skid trails and landings as directed by the Forest Officer. b. The kinds and frequency of erosion control structures shall be adjusted to soil types, topography and climatic conditions as directed by the Forest Officer. c. The Purchaser is required to recontour any excavated skid trails, and provide for effective erosion control in the trail location as directed by the Forest Officer. d. Erosion control work shall commence as soon as skidding is completed on each skid trail or landing, and must be kept current with unit operations. e. Erosion control work shall be completed and approved by the Forest Officer in unfinished units before operations cease for inactive periods including heavy winter snowfall, spring breakup and restricted dates. f. All erosion control work in each unit shall be completed prior to notification pursuant to Section VII.M.7.
Interconnection Customer Compensation for Actions During Emergency Condition The CAISO shall compensate the Interconnection Customer in accordance with the CAISO Tariff for its provision of real and reactive power and other Emergency Condition services that the Interconnection Customer provides to support the CAISO Controlled Grid during an Emergency Condition in accordance with Article 11.6.
System Access Control Data processing systems used to provide the Cloud Service must be prevented from being used without authorization.
Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain. (b) Employees shall not be required to start a concrete pour in Inclement Weather. (c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear. (d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay. (e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
Access Control Supplier will maintain an appropriate access control policy that is designed to restrict access to Accenture Data and Supplier assets to authorized Personnel. Supplier will require that all accounts have complex passwords that contain letters, numbers, and special characters, be changed at least every 90 days, and have a minimum length of 8 characters.
Network Access Control The VISION Web Site and the Distribution Support Services Web Site (the “DST Web Sites”) are protected through multiple levels of network controls. The first defense is a border router which exists at the boundary between the DST Web Sites and the Internet Service Provider. The border router provides basic protections including anti-spoofing controls. Next is a highly available pair of stateful firewalls that allow only HTTPS traffic destined to the DST Web Sites. The third network control is a highly available pair of load balancers that terminate the HTTPS connections and then forward the traffic on to one of several available web servers. In addition, a second highly available pair of stateful firewalls enforce network controls between the web servers and any back-end application servers. No Internet traffic is allowed directly to the back-end application servers. The DST Web Sites equipment is located and administered at DST’s Winchester data center. Changes to the systems residing on this computer are submitted through the DST change control process. All services and functions within the DST Web Sites are deactivated with the exception of services and functions which support the transfer of files. All ports on the DST Web Sites are disabled, except those ports required to transfer files. All “listeners,” other than listeners required for inbound connections from the load balancers, are deactivated. Directory structures are “hidden” from the user. Services which provide directory information are also deactivated.
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Data Transmission Control Except as necessary for the provision of the Cloud Services in accordance with the Agreement, Personal Data must not be read, copied, modified or removed without authorization during transfer. Where data carriers are physically transported, adequate measures are implemented at SAP to provide the agreed-upon service levels (for example, encryption and lead-lined containers).
Traffic Measurement and Billing over Interconnection Trunks 6.1 For billing purposes, each Party shall pass Calling Party Number (CPN) information on at least ninety-five percent (95%) of calls carried over the Interconnection Trunks. 6.1.1 As used in this Section 6, “Traffic Rate” means the applicable Reciprocal Compensation Traffic rate, Measured Internet Traffic rate, intrastate Switched Exchange Access Service rate, interstate Switched Exchange Access Service rate, or intrastate/interstate Tandem Transit Traffic rate, as provided in the Pricing Attachment, an applicable Tariff, or, for Measured Internet Traffic, the FCC Internet Order. 6.1.2 If the originating Party passes CPN on ninety-five percent (95%) or more of its calls, the receiving Party shall xxxx the originating Party the Traffic Rate applicable to each relevant minute of traffic for which CPN is passed. For any remaining (up to 5%) calls without CPN information, the receiving Party shall xxxx the originating Party for such traffic at the Traffic Rate applicable to each relevant minute of traffic, in direct proportion to the minutes of use of calls passed with CPN information. 6.1.3 If the originating Party passes CPN on less than ninety-five percent (95%) of its calls and the originating Party chooses to combine Reciprocal Compensation Traffic and Toll Traffic on the same trunk group, the receiving Party shall xxxx the higher of its interstate Switched Exchange Access Service rates or its intrastate Switched Exchange Access Services rates for all traffic that is passed without CPN, unless the Parties agree that other rates should apply to such traffic. 6.2 At such time as a receiving Party has the capability, on an automated basis, to use such CPN to classify traffic delivered over Interconnection Trunks by the other Party by Traffic Rate type (e.g., Reciprocal Compensation Traffic/Measured Internet Traffic, intrastate Switched Exchange Access Service, interstate Switched Exchange Access Service, or intrastate/interstate Tandem Transit Traffic), such receiving Party shall xxxx the originating Party the Traffic Rate applicable to each relevant minute of traffic for which CPN is passed. If the receiving Party lacks the capability, on an automated basis, to use CPN information on an automated basis to classify traffic delivered by the other Party by Traffic Rate type, the originating Party will supply Traffic Factor 1 and Traffic Factor
Litigation Control (a) With respect to any Mortgage Loan (other than a Non-Serviced Mortgage Loan), any Serviced Companion Loan or any related REO Loan or related REO Property, the Special Servicer shall, in accordance with the Servicing Standard, direct, manage, prosecute and/or defend any action brought by a Mortgagor, guarantor, or other obligor on the related Note or any Affiliates thereof (each a “Borrower-Related Party”) against the Trust, the Master Servicer and/or the Special Servicer or any predecessor master servicer or special servicer, and represent the interests of the Trust in any litigation relating to the rights and obligations of the Trust, or of the Mortgagor or other Borrower-Related Party under the related Mortgage Loan documents, or with respect to the related Mortgaged Property or other collateral securing such Mortgage Loan (or Serviced Whole Loan), or otherwise with respect to the enforcement of the obligations of a Borrower-Related Party under the related Mortgage Loan documents (“Trust-Related Litigation”). In the event that the Master Servicer is named in any Trust-Related Litigation but the Special Servicer is not named in such Trust-Related Litigation (regardless of whether the Trust is named in such Trust-Related Litigation), the Master Servicer shall notify the Special Servicer of such litigation as soon as practicable but in any event no later than within ten (10) Business Days of the Master Servicer receiving service of such Trust-Related Litigation. (b) To the extent the Master Servicer is named in the Trust-Related Litigation, and neither the Trust nor the Special Servicer is named, in order to effectuate the role of the Special Servicer as contemplated by the immediately preceding Section 3.32(a), the Master Servicer shall (i) provide monthly status reports to the Special Servicer, regarding such Trust-Related Litigation; (ii) seek to have the Trust replace the Master Servicer as the appropriate party to the lawsuit; and (iii) so long as the Master Servicer remains a party to the lawsuit, consult with and act at the direction of the Special Servicer with respect to decisions and resolutions related to the interests of the Trust in such Trust-Related Litigation, including but not limited to the selection of counsel; provided that the Master Servicer shall have the right to engage separate counsel relating to claims against the Master Servicer to the extent set forth in Section 3.32(e); and provided, however, that if there are claims against the Master Servicer and the Master Servicer has not determined that separate counsel is required for such claims, such counsel shall be reasonably acceptable to the Master Servicer. (c) The Special Servicer shall not (i) undertake (or direct the Master Servicer to undertake) any material settlement of any Trust-Related Litigation or (ii) initiate any material Trust-Related Litigation unless and until it has notified in writing the Directing Certificateholder (only if the related Mortgage Loan is not an Excluded Loan as to such party and prior to the occurrence and continuance of a Consultation Termination Event) (to the extent the identity of the Directing Certificateholder is actually known to the Special Servicer; provided that the Special Servicer shall make due inquiry of the Certificate Administrator as to the identity of the Directing Certificateholder) and the related holder of any Serviced Companion Loan (if such matter affects such related Serviced Companion Loan) (to the extent the identity of the holder of such Serviced Companion Loan is actually known to the Special Servicer), and the Directing Certificateholder (only if the related Mortgage Loan is not an Excluded Loan with respect to the Directing Certificateholder or the Holder of the majority of the Controlling Class and prior to the occurrence and continuation of a Control Termination Event) has not objected in writing within five (5) Business Days of having been notified thereof and having been provided with all information that the Directing Certificateholder has reasonably requested with respect thereto promptly following its receipt of the subject notice (it being understood and agreed that if such written objection has not been received by the Special Servicer within such five (5) Business Day period, then the Directing Certificateholder shall be deemed to have approved the taking of such action); provided that, if the Special Servicer determines (consistent with the Servicing Standard) that immediate action is necessary to protect the interests of the Certificateholders and, with respect to a Serviced Whole Loan, the related Companion Holders, the Special Servicer may take such action without waiting for the Directing Certificateholder’s response. (d) Notwithstanding the foregoing, neither the Special Servicer nor the Master Servicer shall follow any advice, direction or consultation provided by the Directing Certificateholder or the Risk Retention Consultation Party (or any other party to this Agreement) that would require or cause the Special Servicer or the Master Servicer, as applicable, to violate any applicable law, be inconsistent with the Servicing Standard, require or cause the Special Servicer or the Master Servicer, as applicable, to violate provisions of this Agreement, require or cause the Special Servicer or the Master Servicer, as applicable, to violate the terms of any Mortgage Loan or Serviced Whole Loan, expose any Certificateholder or any party to this Agreement or their Affiliates, officers, directors or agents to any claim, suit or liability, cause any REMIC created hereunder to fail to qualify as a REMIC, result in the imposition of a “prohibited transaction” or “prohibited contribution” tax under the REMIC Provisions or materially expand the scope of the Special Servicer’s or the Master Servicer’s, as the case may be, responsibilities under this Agreement. (e) Notwithstanding the right of the Special Servicer to represent the interests of the Trust in Trust-Related Litigation, and subject to the rights of the Special Servicer to direct the Master Servicer’s actions in this Section 3.32, the Master Servicer shall retain the right to make determinations relating to claims against the Master Servicer, including but not limited to the right to engage separate counsel and to appear in any proceeding on its own behalf in the Master Servicer’s reasonable discretion, the cost of which shall be subject to indemnification as and to the extent provided in this Agreement. (f) Further, nothing in this section shall require the Master Servicer to take or fail to take any action which, in the Master Servicer’s good faith and reasonable judgment, may (i) result in a violation of the REMIC Provisions or (ii) subject the Master Servicer to liability or materially expand the scope of the Master Servicer’s obligations under this Agreement. (g) Notwithstanding the Master Servicer’s right to make determinations relating to claims against the Master Servicer, the Special Servicer shall have the right at any time in accordance with the Servicing Standard to (i) direct the Master Servicer to settle any claims asserted against the Master Servicer (whether or not the Trust or the Special Servicer is named in any such claims or Trust-Related Litigation) (and with respect to any material settlements, with the consent of or in consultation with the Directing Certificateholder prior to the occurrence and continuance of a Control Termination Event or the occurrence and continuance of a Consultation Termination Event, respectively (in each case, other than a Mortgage Loan that is an Excluded Loan as to such party)) and (ii) otherwise reasonably direct the actions of the Master Servicer relating to claims against the Master Servicer (whether or not the Trust or the Special Servicer is named in any such claims or Trust-Related Litigation), provided in either case that (A) such settlement or other direction does not require any admission of liability or wrongdoing on the part of the Master Servicer, (B) the cost of such settlement or any resulting judgment is and shall be paid by the Trust and payment of such cost or judgment is provided for in this Agreement, (C) the Master Servicer is and shall be indemnified as and to the extent provided in this Agreement for all costs and expenses of the Master Servicer incurred in defending and settling the Trust-Related Litigation and for any judgment, (D) any such action taken by the Master Servicer at the direction of the Special Servicer shall be deemed (as to the Master Servicer) to be in compliance with the Servicing Standard and (E) the Special Servicer provides the Master Servicer with assurance reasonably satisfactory to the Master Servicer as to the items in clauses (A), (B) and (C). (h) In the event both the Master Servicer and the Special Servicer or Trust are named in Trust-Related Litigation, the Master Servicer and the Special Servicer shall cooperate with each other to afford the Master Servicer and the Special Servicer the rights afforded to such party in this Section 3.32. This Section 3.32 shall not apply in the event the Special Servicer authorizes the Master Servicer, and the Master Servicer agrees (both authority and agreement to be in writing), to make certain decisions or control certain Trust-Related Litigation on behalf of the Trust in accordance with the Servicing Standard. Notwithstanding the foregoing, (i) in the event that any action, suit, litigation or proceeding names the Trustee in its individual capacity, or in the event that any judgment is rendered against the Trustee in its individual capacity, the Trustee, upon prior written notice to the Master Servicer or the Special Servicer, as the case may be, may retain counsel and appear in any such proceeding on its own behalf in order to protect and represent its interests (but not to otherwise direct, manage or prosecute such litigation or claim); (ii) in the event of any action, suit, litigation or proceeding, other than an action, suit, litigation or proceeding relating to the enforcement of the obligations of a Mortgagor, guarantor or other obligor under the related Mortgage Loan documents, or otherwise relating to one or more Mortgage Loans or Mortgaged Properties, neither the Master Servicer nor the Special Servicer shall, without the prior written consent of the Trustee, (A) initiate an action, suit, litigation or proceeding in the name of the Trustee, whether in such capacity or individually, (B) engage counsel to represent the Trustee, or (C) prepare, execute or deliver any government filings, forms, permits, registrations or other documents or take any other similar actions with the intent to cause, and that actually causes, the Trustee to be registered to do business in any state (provided that neither the Master Servicer nor the Special Servicer shall be responsible for any delay due to the unwillingness of the Trustee to grant such consent); and (iii) in the event that any court finds that the Trustee is a necessary party in respect of any action, suit, litigation or proceeding relating to or arising from this Agreement or any Mortgage Loan, the Trustee shall have the right to retain counsel and appear in any such proceeding on its own behalf in order to protect and represent its interests, whether as Trustee or individually (but not to otherwise direct, manage or prosecute such litigation or claim); provided, however, that nothing in this Section 3.32(h) shall be interpreted to preclude the Special Servicer (with respect to any material Trust-Related Litigation, with the consent or consultation of the Directing Certificateholder prior to the occurrence and continuance of a Control Termination Event or the occurrence and continuance of a Consultation Termination Event, respectively, to the extent required in Section 3.32(c) and only to the extent such Mortgage Loan is not an Excluded Loan as to such party) from initiating any action, suit, litigation or proceeding in its name as representative of the Trustee of the Trust.

FUGITIVE DUST EMISSION CONTROL Sample Clauses

Filter & Search

Related Clauses

Parent Clauses

Related to FUGITIVE DUST EMISSION CONTROL