GENERAL COMPLIANCE WITH RESPECT TO THE APARTMENT Subject to Clause 12 above, the Allottee shall, after taking possession, be solely responsible to maintain the [Apartment/Plot] at his/her own cost, in good repair and condition and shall not do or suffer to be done anything in or to the Building, or the [Apartment/Plot], or the staircases, lifts, common passages, corridors, circulation areas, atrium or the compound which may be in violation of any laws or rules of any authority or change or alter or make additions to the [Apartment/Plot] and keep the [Apartment/Plot], its walls and partitions, sewers, drains, pipe and appurtenances thereto or belonging thereto, in good and tenantable repair and maintain the same in a fit and proper condition and ensure that the support, shelter etc. of the Building is not in any way damaged or jeopardized. The Allottee further undertakes, assures and guarantees that he/she would not put any sign-board / name-plate, neon light, publicity material or advertisement material etc. on the face / facade of the Building or anywhere on the exterior of the Project, buildings therein or Common Areas. The Allottees shall also not change the colour scheme of the outer walls or painting of the exterior side of the windows or carry out any change in the exterior elevation or design. Further the Allottee shall not store any hazardous or combustible goods in the [Apartment/Plot] or place any heavy material in the common passages or staircase of the Building. The Allottee shall also not remove any wall, including the outer and load bearing wall of the [Apartment/Plot]. The Allottee shall plan and distribute its electrical load in conformity with the electrical systems installed by the Promoter and thereafter the association of allottees and/or maintenance agency appointed by association of allottees. The Allottee shall be responsible for any loss or damages arising out of breach of any of the aforesaid conditions.
COMPLIANCE WITH RESPECT TO THE APARTMENT 15.1. Subject to para 1 2 above, the Allottee sha ll, after taking possession, be solely responsible to maintain the Apartment at his/her own cost, in good repair and condition and shall not do or suffer to be done anything in or to the Building, or the Apartment or the staircases, lifts, common passages, corridors, circulation areas, atrium or the compound which may be in viol ation of any loss or rules of any authority or change or alter or make additions to the Apartment and keep the Apartment, its walls and partitions, sewers, drains, pipe and appurtenances thereto or belonging thereto, in good and tenantable repair and maintain the same in a fit and proper condition and ensuring that the support, shelter etc. of the Building is not in any way damaged or jeopardized.
15.2. The Allottee further undertakes, assures and guarantees that he/she would not put any sign-board/name-plate, neon light, publicity material or advertisement material etc. on the face façade of the Building or anywhere on the exterior of the Project, buildings therein or Common Areas. The Allottees, shall also not change the colour scheme of the outer walls or painting of the exterior side of the windows or carry out any change in the exterior elevation or design. Further the Allottee shall not store any hazardous or combustible goods in the Apartment or place any heavy material in the common passages or staircase of the Building. The Allottee shall also not remove any wall including the outer and load bearing wall of the Apartment.
15.3. The Allottee shall plan distribute its electrical load inconformity with the electrical systems installed by the Promoter/Developer and thereafter the association of allottees and / or maintenance agency appointed by association of allottees. The Allottee shall be responsible for any loss or damages arising out of breach of any of the aforesaid conditions and the allottee shall not raise any objection whatsoever if the Promoter/Developer in future purchases the land adjacent to the said land and amalgamate the same for construction of another phase or block and for such construction the common entrance road is to be used for free access to the Phase/Block.
Prior Notice to Owners with Respect to Certain Matters Subject to the provisions and limitations of Section 4.04, with respect to the following matters, the Owner Trustee shall not take action unless at least 30 days before the taking of such action, the Owner Trustee shall have notified the Certificateholders in writing of the proposed action and the Owners shall not have notified the Owner Trustee in writing prior to the 30th day after such notice is given that such Owners have withheld consent or provided alternative direction:
(a) the initiation of any claim or lawsuit by the Issuer (except claims or lawsuits brought in connection with the collection of the Receivables) and the compromise of any action, claim or lawsuit brought by or against the Issuer (except with respect to the aforementioned claims or lawsuits for collection of the Receivables);
(b) the election by the Issuer to file an amendment to the Certificate of Trust (unless such amendment is required to be filed under the Statutory Trust Statute);
(c) the amendment of the Indenture by a supplemental indenture in circumstances where the consent of any Noteholder is required;
(d) the amendment of the Indenture by a supplemental indenture in circumstances where the consent of any Noteholder is not required and such amendment materially adversely affects the interests of the Owners;
(e) the amendment, change or modification of the Administration Agreement, except to cure any ambiguity or to amend or supplement any provision in a manner or add any provision that would not materially adversely affect the interests of the Owners; or
(f) the appointment pursuant to the Indenture of a successor Note Registrar, paying agent for the Notes or Indenture Trustee or pursuant to this Agreement of a successor Certificate Registrar, or the consent to the assignment by the Note Registrar, Paying Agent, Indenture Trustee or Certificate Registrar of its obligations under the Indenture or this Agreement, as applicable.
Award Subject to Acceptance of Agreement The Award shall be null and void unless the Holder accepts this Agreement by executing it in the space provided below and returning such original execution copy to the Company, or by approving this Agreement by electronic means in a manner that has been approved by the Company.
Files Subject to Florida's Public Records Law Any file, report, record, document, paper, letter, or other material received, generated, maintained or sent by Grantee to Florida Housing or its agent(s) in connection with this agreement is subject to the provisions of Section 119.01- .15, Fla. Stat., as may be amended from time to time (Florida's Public Records Law). Grantee represents and acknowledges that it has read and understands Florida's Public Records Law and agrees to comply with Florida's Public Records Law.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Agreement with Respect to Certain Existing Agreements (a) Subject to the provisions of Section 4.8(b), with respect to agreements existing as of Bank Closing which provide for the rendering of services by or to the Failed Bank, within thirty (30) days after Bank Closing, the Assuming Bank shall give the Receiver written notice specifying whether it elects to assume or not to assume each such agreement. Except as may be otherwise provided in this Article IV, the Assuming Bank agrees to comply with the terms of each such agreement for a period commencing on the day after Bank Closing and ending on: (i) in the case of an agreement that provides for the rendering of services by the Failed Bank, the date which is ninety (90) days after Bank Closing, and (ii) in the case of an agreement that provides for the rendering of services to the Failed Bank, the date which is thirty (30) days after the Assuming Bank has given notice to the Receiver of its election not to assume such agreement; provided, that the Receiver can reasonably make such service agreements available to the Assuming Bank. The Assuming Bank shall be deemed by the Receiver to have assumed agreements for which no notification is timely given. The Receiver agrees to assign, transfer, convey, and deliver to the Assuming Bank all right, title and interest of the Receiver, if any, in and to agreements the Assuming Bank assumes hereunder. In the event the Assuming Bank elects not to accept an assignment of any lease (or sublease) or negotiate a new lease for leased Bank Premises under Section 4.6 and does not otherwise occupy such premises, the provisions of this Section 4.8(a) shall not apply to service agreements related to such premises. The Assuming Bank agrees, during the period it has the use or benefit of any such agreement, promptly to pay to the Receiver or to appropriate third parties at the direction of the Receiver all operating costs with respect thereto and to comply with all relevant terms of such agreement.
(b) The provisions of Section 4.8(a) regarding the Assuming Bank’s election to assume or not assume certain agreements shall not apply to (i) agreements pursuant to which the Failed Bank provides mortgage servicing for others or mortgage servicing is provided to the Failed Bank by others, (ii) agreements that are subject to Sections 4.1 through 4.7 and any insurance policy or bond referred to in Section 3.5(a) or other agreement specified in Section 3.5, and (iii) consulting, management or employment agreements, if any, between the Failed Bank and its employees or other Persons. Except as otherwise expressly set forth elsewhere in this Agreement, the Assuming Bank does not assume any liabilities or acquire any rights under any of the agreements described in this Section 4.8(b).
Action by Owners with Respect to Certain Matters The Owner Trustee shall not have the power, except upon the direction of the Owners, to (a) remove the Administrator under the Administration Agreement pursuant to Section 8 thereof, (b) appoint a successor Administrator pursuant to Section 8 of the Administration Agreement, (c) remove the Servicer under the Sale and Servicing Agreement pursuant to Section 8.01 thereof or (d) except as expressly provided in the Basic Documents, sell the Receivables after the termination of the Indenture. The Owner Trustee shall take the actions referred to in the preceding sentence only upon written instructions signed by the Owners.
Certification of Compliance with the Energy Policy and Conservation Act When appropriate and to the extent consistent with the law, Vendor certifies that it will comply with the Energy Policy and Conservation Act (42 U.S.C. 6321 et seq; 49 C.F.R. Part 18) and any mandatory standards and policies relating to energy efficiency which are contained in applicable state energy conservation plans issued in compliance with the Act. Does Vendor agree? Yes
