ACCEPTANCE OF CONTRACT/TERMS AND CONDITIONS (a) This Contract integrates, merges, and supersedes any prior offers, negotiations, and agreements concerning the subject matter hereof and constitutes the entire agreement between the parties. (b) SELLER's acknowledgment, acceptance of payment, or commencement of performance, shall constitute SELLER's unqualified acceptance of this Contract. (c) Unless expressly accepted in writing by LOCKHEED XXXXXX, additional or differing terms or conditions proposed by SELLER or included in SELLER's acknowledgment are objected to by LOCKHEED XXXXXX and have no effect. (d) The headings used in this Contract are inserted for the convenience of the parties and shall not define, limit, or describe the scope or the intent of the provisions of this Contract.
MODIFICATION OF CONTRACT TERMS The terms and conditions set forth in the Contract shall govern all transactions by Authorized User(s) under this Contract. The Contract may only be modified or amended upon mutual written agreement of the Commissioner and Contractor. The Contractor may, however, offer Authorized User(s) more advantageous pricing, payment, or other terms and conditions than those set forth in the Contract. In such event, a copy of such terms shall be furnished to the Authorized User(s) and Commissioner by the Contractor at the time of such offer. Other than where such terms are more advantageous for the Authorized User(s) than those set forth in the Contract, no alteration or modification of the terms of the Contract, including substitution of Product, shall be valid or binding against Authorized User(s) unless authorized by the Commissioner or specified in the Contract Award Notification. No such alteration or modification shall be made by unilaterally affixing such terms to Product upon delivery (including, but not limited to, attachment or inclusion of standard pre-printed order forms, product literature, “shrink wrap” terms accompanying software upon delivery, or other documents) or by incorporating such terms onto order forms, purchase orders or other documents forwarded by the Contractor for payment, notwithstanding Authorized User’s subsequent acceptance of Product, or that Authorized User has subsequently processed such document for approval or payment.
CONTRACT TERMS AND CONDITIONS This section sets forth the terms and conditions of the Contract.
DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.
Issuance and Terms of Equipment Notes The Equipment Notes shall be dated the date of issuance thereof, shall be issued in three separate series consisting of Series A, Series B and Series C and in the maturities and principal amounts and shall bear interest as specified in Schedule I hereto. On the date of the consummation of the Transactions, each Equipment Note shall be issued to the Subordination Agent on behalf of the Pass Through Trustees under the Pass Through Trust Agreements. The Equipment Notes shall be issued in registered form only. The Equipment Notes shall be issued in denominations of $1,000 and integral multiples thereof, except that one Equipment Note of each Series may be in an amount that is not an integral multiple of $1,000. Each Equipment Note shall bear interest at the Debt Rate (calculated on the basis of a year of 360 days comprised of twelve 30-day months) on the unpaid Original Amount thereof from time to time outstanding, payable in arrears on April 1, 1998, and on each October 1 and April 1 thereafter until maturity. The Original Amount of each Equipment Note shall be payable on the dates and in the installments equal to the corresponding percentage of the Original Amount as set forth in Schedule I hereto which shall be attached as Schedule I to the Equipment Notes. Notwithstanding the foregoing, the final payment made under each Equipment Note shall be in an amount sufficient to discharge in full the unpaid Original Amount and all accrued and unpaid interest on, and any other amounts due under, such Equipment Note. Each Equipment Note shall bear interest at the Payment Due Rate (calculated on the basis of a year of 360 days comprised of twelve 30-day months) on any part of the Original Amount, Make-Whole Amount, if any, and, to the extent permitted by applicable Law, interest and any other amounts payable thereunder not paid when due for any period during which the same shall be overdue, in each case for the period the same is overdue. Amounts shall be overdue if not paid when due (whether at stated maturity, by acceleration or otherwise). Notwithstanding anything to the contrary contained herein, if any date on which a payment under any Equipment Note becomes due and payable is not a Business Day then such payment shall not be made on such scheduled date but shall be made on the next succeeding Business Day and if such payment is made on such next succeeding Business Day, no interest shall accrue on the amount of such payment during such extension.
SETTLEMENT TERMS AND CONDITIONS Without admitting or denying the Department’s findings, Associated is willing to resolve the violations cited herein and in the visitation report by entering into this Agreement and freely and voluntarily waives its right to a hearing under Banking Law Sections 44 and 598 on such violations. Therefore, in consideration of the promises and covenants set forth herein: 1. Associated agrees to take all necessary steps to ensure its compliance with all applicable federal and state laws, regulations, and supervisory requirements relating to its mortgage business, including, but not limited to: a. complying with the requirements of Article 12-D and Article 12-E of the Banking Law, Section 420 of the Superintendent’s Regulations, and Part 38 of the General Regulations; and b. ensuring that its MLOs who conduct mortgage origination activities are licensed pursuant to Article 12-E of the Banking Law and Section 420 of the Superintendent’s Regulations; c. ensuring that its MLOs do not mislead consumers as to their license status; and d. ensuring that its MLOs do not share their unique identifier with any other individual or entity; and e. ensuring that its non-MLO staff does not engage in mortgage activities that require a license; and f. ensuring that its non-MLO staff does not have access to any mortgage loan origination system, software, and documents, and they do not utilize a MLOs unique identifier; and g. ensuring that its books and records, specifically the application logs, are in compliance with Section 410.7 of the Superintendent’s Regulation. 2. Associated agrees to continue to further develop appropriate written compliance policies and procedures designed to ensure compliance with all applicable federal and state laws, regulations, supervisory requirements and guidance letters. The policies and procedures shall, at a minimum: (i) designate an individual responsible for monitoring compliance with all applicable federal and state laws, regulations, supervisory requirements and guidance letters; and (ii) establish a training program to ensure that Associated and its MLO and non-MLO employees understand all applicable federal and state laws, regulations, supervisory requirements and guidance letters. 3. Within ninety (90) days from the effective date of this Agreement, Associated agrees to submit a draft of its compliance policies and procedures to the Department. 4. Within one hundred twenty (120) days from the effective date of this Agreement, Associated agrees to submit a copy of its final compliance policies and procedures to the Department together with a letter from an authorized officer of Associated indicating his/her approval of such policies and procedures. 5. Associated agrees to pay a fine of $ $25,000 payable in two (2) equal installments as follows: $12,500 upon execution of this Agreement $12,500 within 30 days after the execution of this Agreement. 6. Associated further agrees that such payment will be made in immediately available funds in accordance with the Department’s payment instructions.
ADDITIONAL TERMS OF SETTLEMENT 24. This settlement is agreed upon in accordance with section 24.4 of MFDA By-law No. 1 and Rules 14 and 15 of the MFDA Rules of Procedure. 25. The Settlement Agreement is subject to acceptance by the Hearing Panel which shall be sought at a hearing (the “Settlement Hearing”). At, or following the conclusion of, the Settlement Hearing, the Hearing Panel may either accept or reject the Settlement Agreement. MFDA Settlement Hearings are typically held in the absence of the public pursuant to section 20.5 of MFDA By-law No. 1 and Rule 15.2(2) of the MFDA Rules of Procedure. If the Hearing Panel accepts the Settlement Agreement, then the proceeding will become open to the public and a copy of the decision of the Hearing Panel and the Settlement Agreement will be made available at xxx.xxxx.xx. 26. The Settlement Agreement shall become effective and binding upon the Respondent and Staff as of the date of its acceptance by the Hearing Panel. Unless otherwise stated, any monetary penalties and costs imposed upon the Respondent are payable immediately, and any suspensions, revocations, prohibitions, conditions or other terms of the Settlement Agreement shall commence, upon the effective date of the Settlement Agreement. 27. Staff and the Respondent agree that if this Settlement Agreement is accepted by the Hearing Panel: a) the Settlement Agreement will constitute the entirety of the evidence to be submitted respecting the Respondent in this matter; b) the Respondent waives any rights to a full hearing, a review hearing before the Board of Directors of the MFDA or any securities commission with jurisdiction in the matter under its enabling legislation, or a judicial review or appeal of the matter before any court of competent jurisdiction; c) Staff will not initiate any proceeding under the By-laws of the MFDA against the Respondent in respect of the contraventions described in this Settlement Agreement. Nothing in this Settlement Agreement precludes Staff from investigating or initiating proceedings in respect of any contraventions that are not set out in this Settlement Agreement. Furthermore, nothing in this Settlement Agreement shall relieve the Respondent from fulfilling any continuing regulatory obligations; d) the Respondent shall be deemed to have been penalized by the Hearing Panel pursuant to
Loan and Terms of Payment 2.1 Promise to Pay. Borrower hereby unconditionally promises to pay Bank the outstanding principal amount of all Credit Extensions and accrued and unpaid interest thereon as and when due in accordance with this Agreement.
Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.
ADDITIONAL TERMS AND CONDITIONS This Annex A to the Second Amended and Restated Servicing Agreement, dated October 31, 2021 (the “Agreement”), among Xxxxx Bank and Xxxxx Trust Company, as Sellers, the Bank Assets Purchaser and, upon execution of the Joinder Agreement, the Delaware Trust Assets Purchaser, as Purchasers, and Guarantor (solely for purposes of Section 9.5 of the Agreement), is incorporated into and deemed part of the Agreement in all respects.