Inspection of Completed Work Sample Clauses

Inspection of Completed Work. 40 Should the District’s Representative or the Architect determine that it is necessary or advisable to make an 41 inspection of work already completed at any time before final inspection and acceptance of the Work, by 42 removing or exposing any work, the Entity shall, upon instruction of the District’s Representative, promptly 43 furnish all necessary facilities, labor, and materials to do so. If the work is found to be defective in any respect 44 due to the fault of the Entity or any subcontractor, the Entity shall bear all expenses of such examination and 45 satisfactory reconstruction. If, however, the work is found to meet the requirements of the Construction 46 Documents, the additional cost of labor and material necessarily involved in the examination and replacement 47 shall be allowed the Entity and a Change Order shall be issued for such cost and any time extension justified 48 by delays to the critical path.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Inspection of Completed Work. Upon substantial completion of work, Owner agrees to conduct an inspection of the work with Home Works Painting. All defects and uncompleted items should be noted at this time. The inspection must occur under normal lighting conditions (i.e. no spotlight or flashlight), without magnification, and from a normal viewing position (39 inches or one meter from the painted surface), in accordance with the PDCA Standards.
Sample 1Sample 2Sample 3See All (4)
Inspection of Completed Work. In addition to any testing and inspection required by the Contract Documents, the Inspector may require special inspection of any portion of the Work already completed as to which there is a reasonable question as to whether it was completed in accordance with the requirements of the Contract Documents. In such event, the Contractor shall remove or undo all portions of the Work as are necessary to facilitate inspection of the questioned portion of the Work. If the questioned portion of the Work is found not to conform with the Contract Documents, the Contractor shall pay all costs of the re-examination and correction of the Work, including repair or replacement of previously completed Work that was removed or undone to permit the inspection. If the questioned Work is found to conform with the Contract Documents, the District shall pay the cost of the re-examination and any repair or replacement of previously completed Work that was removed or undone to permit the inspection.
Sample 1
Inspection of Completed Work. At the request of the Owner, approximately eight (8) months after the issuance of a Certificate of Substantial Completion, Architect/Engineer shall assist the Owner with an inspection of the contractors' work, prepare a report of all observed defective materials, equipment and workmanship which requires corrective actions under any applicable warranties and submit same to the contractor(s).
Sample 1Sample 2
Inspection of Completed Work a. Without limiting COUNTY’S disclaimer of responsibility for the work, upon completion of the work, COUNTY and SUBRECIPIENT shall inspect the work completed by the Contractor. Upon completion and acceptance of the work by SUBRECIPIENT, COUNTY shall make final payment to the SUBRECIPIENT in accordance with Section 119 above.
Sample 1
Inspection of Completed Work. The Developer shall notify the Township, with a copy to the Township Engineer, by written notice (the “Developer’s Notice of Completion”) delivered in a manner provided in 24(h) hereof, when the Required Improvements have been completed (the “Completed Work”) or when any phase of the project (delineated in the Inspection Milestones Exhibit “F” hereof) has been completed. Within fifteen (15) calendar days of receiving the Developer’s Notice of Completion, the Township shall direct the Township Engineer to inspect the Completed Work. The Township Engineer shall make an inspection of the Completed Work and shall file a written report with the Township, with a copy to the Developer, within thirty (30) calendar days of the date of the Township’s receipt of the Developer’s notice of completion of the Required Improvements. If the Township Engineer finds any or all of the Required Improvements not completed as required by the terms of this Agreement, the Township Engineer shall include a specific description of the deficiencies in the Completed Work and shall delineate such deficiencies in the Township Engineer’s written report to the Township and to the Developer.
Sample 1

Related to Inspection of Completed Work

  • Certification of Completion Upon completion of administration of the Settlement, the Settlement Administrator will provide a written declaration under oath to certify such completion to the Court and counsel for all Parties.

  • Substantial Completion “Substantial Completion” means the stage in the progress of the Work when the Work, or designated portions thereof, may still require minor modifications or adjustments but, in the Owner’s opinion, the Work has progressed to the point such that all parts of the Work under consideration are fully operational and usable for intended purposes, as evidenced by a Certificate of Substantial Completion approved by the Owner. If a Certificate of Occupancy is required by public authorities having jurisdiction over the Work, said certificate shall be issued before the Work or any portion thereof is considered substantially complete. When the Contractor considers that the Work, or a portion thereof which the Owner agrees to accept separately, is substantially complete, the Contractor shall notify Owner’s Designated Representative (sometimes referred to as the “ODR”) and request a determination as to whether the Work or designated portion thereof is substantially complete. If the ODR does not consider the Work substantially complete, the ODR will notify the Contractor giving reasons therefore. Failure on the Owner’s part to list a reason does not alter the responsibility of the Contractor to complete all Work in accordance with the terms of this Agreement. After satisfactorily completing items identified by Owner’s Designated Representative, the Contractor shall then submit another request for the ODR to determine Substantial Completion. If The ODR considers the Work substantially complete, The ODR will prepare and deliver a certificate of Substantial Completion which shall establish the date of Substantial Completion, shall include a punch list of items to be completed or corrected before final completion and final payment, shall establish the time within which the Contractor shall finish the punch list, and shall establish responsibilities of the Owner and the Contractor for security, maintenance, heat, utilities, damage to the Work, warranty and insurance. Failure to include an item on the punch list does not alter the responsibility of the Contractor to complete all Work in accordance with the terms and conditions of this Agreement. The certificate of Substantial Completion shall be signed by the Owner and the Contractor to evidence acceptance of the responsibilities assigned to them in such certificate. Substantial Completion (as defined in this agreement) for all stages of the Work shall be achieved on or before the following Substantial Completion date: DATE FOR SUBSTANTIAL COMPLETION: TBD Under no circumstances will the time for Substantial Completion exceed this date without a written amendment to this Agreement. THE TIMES SET FORTH IN THE CONSTRUCTION DOCUMENTS ARE AN ESSENTIAL ELEMENT OF THE AGREEMENT. TIME LIMITS STATED IN THE CONTRACT DOCUMENTS ARE OF THE ESSENCE OF THIS AGREEMENT.

  • Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Architect, the State shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof, as provided in the Contract Documents.

  • Payment for Material Completion The Contractor may request payment of the remaining contract balance, including retainage, less amounts credited the Owner or incurred as liquidated damages, and less amounts withheld for the Punchlist by reason of Minor Items or Permitted Incomplete Work (See Paragraph 6.5.3.2). Payment for Material Completion shall be made by a check payable jointly to the Contractor and Surety and shall be mailed to the Surety.

  • After Substantial Completion § 12.2.2.1 In addition to the Contractor’s obligations under Section 3.5, if, within one year after the date of Substantial Completion of the Work or designated portion thereof or after the date for commencement of warranties established under Section 9.9.1, or by terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be not in accordance with the requirements of the Contract Documents, the Contractor shall correct it promptly after receipt of notice from the Owner to do so, unless the Owner has previously given the Contractor a written acceptance of such condition. The Owner shall give such notice promptly after discovery of the condition. During the one-year period for correction of Work, if the Owner fails to notify the Contractor and give the Contractor an opportunity to make the correction, the Owner waives the rights to require correction by the Contractor and to make a claim for breach of warranty. If the Contractor fails to correct nonconforming Work within a reasonable time during that period after receipt of notice from the Owner or Architect, the Owner may correct it in accordance with Section 2.5.

  • TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION (i) The work under this Contract shall commence within seven (7) calendar days of receipt of Notice to Proceed and will be substantially complete within thirty (80) calendar days after the date when the Contract Time commences to run as provided in paragraph 2.03 of the General Conditions and completed and ready for final payment within ninety (90) calendar days after the date when the Contract Time commences to run.

  • Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!