Sampling and Analysis The Seller has sole responsibility for quality control of the coal and shall forward its “as loaded” quality to the Buyer as soon as possible. The sampling and analysis of the coal delivered hereunder shall be performed by Buyer and the results thereof shall be accepted and used for the quality and characteristics of the coal delivered under this Agreement. All analyses shall be made in Buyer’s laboratory at Buyer’s expense in accordance with ASTM standards where applicable, or using standards mutually acceptable to both parties. Samples for analyses shall be taken by any ASTM standards or standards mutually acceptable to both parties, and may be composited and shall be taken with a frequency and regularity sufficient to provide reasonably accurate representative samples of the deliveries made hereunder. Seller represents that it is familiar with Buyer’s sampling and analysis practices, and finds them to be acceptable. Buyer shall notify Seller in writing of any significant changes in Buyer’s sampling and analysis practices. Any such changes in Buyer’s sampling and analysis practices shall, except for ASTM or mutually agreeable changes in practices, provide for no less accuracy than the sampling and analysis practices existing at the time of the execution of this Agreement, unless the Parties otherwise mutually agree.
(1) part shall be used for analysis by Buyer; one (l) part shall be used by Buyer as a check sample, if Buyer in its sole judgment determines it is necessary; one (1) part shall be retained by Buyer (LG&E) until the twenty-fifth (25th) of the month following the month of unloading (the “LG&E Disposal Date”) or Buyer (KU) until thirty (30) days after the sample is taken (the “KU Disposal Date”), the LG&E Disposal Date and the KU Disposal Date are collectively the “Disposal Date”), and shall be delivered to Seller for analysis if Seller so requests before the Disposal Date; and one part (“Referee Sample”) shall be retained by Buyer until the Disposal Date. Seller shall be given copies of all analyses made by Buyer by the tenth (10th) business day of the month following the month of unloading. Seller, on reasonable notice to Buyer shall have the right to have a representative present to observe the sampling and analyses performed by Buyer. Unless Seller requests a Referee Sample analysis before the Disposal Date, Buyer’s analysis shall be used to determine the quality of the coal delivered hereunder. The Monthly Weighted Averages shall be determined by utilizing the individual shipment analyses. If any dispute arises before the Disposal Date, the Referee Sample retained by Buyer shall be submitted for analysis to an independent commercial testing laboratory (“Independent Lab”) mutually chosen by Buyer and Seller. For each coal quality specification in question, a dispute shall be deemed not to exist and Buyer’s analysis shall prevail and the analysis of the Independent Lab shall be disregarded if the analysis of the Independent Lab differs from the analysis of Buyer by an amount equal to or less than:
(i) 0.50% moisture
(ii) 0.50% ash on a dry basis
(iii) 100 Btu/lb. on a dry basis (iv) 0.10% sulfur on a dry basis. For each coal quality specification in question, if the analysis of the Independent Lab differs from the analysis of Buyer by an amount more than the amounts listed above, then the analysis of the Independent Lab shall prevail and Buyer’s analysis shall be disregarded. The cost of the analysis made by the Independent Lab shall be borne by Seller to the extent that Buyer’s analysis prevails and by Buyer to the extent that the analysis of the Independent Lab prevails.
Risk Analysis The Custodian will provide the Fund with a Risk Analysis with respect to Securities Depositories operating in the countries listed in Appendix B. If the Custodian is unable to provide a Risk Analysis with respect to a particular Securities Depository, it will notify the Fund. If a new Securities Depository commences operation in one of the Appendix B countries, the Custodian will provide the Fund with a Risk Analysis in a reasonably practicable time after such Securities Depository becomes operational. If a new country is added to Appendix B, the Custodian will provide the Fund with a Risk Analysis with respect to each Securities Depository in that country within a reasonably practicable time after the addition of the country to Appendix B.
Quantitative Analysis Quantitative analysts develop and apply financial models designed to enable equity portfolio managers and fundamental analysts to screen potential and current investments, assess relative risk and enhance performance relative to benchmarks and peers. To the extent that such services are to be provided with respect to any Account which is a registered investment company, Categories 3, 4 and 5 above shall be treated as “investment advisory services” for purposes of Section 5(b) of the Agreement.”
Inspections and Tests 26.1 The Supplier shall at its own expense and at no cost to the Procuring Entity carry out all such tests and/or inspections of the Goods and Related Services as are specified in the SCC.
26.2 The inspections and tests may be conducted on the premises of the Supplier or its Subcontractor, at point of delivery, and/or at the Goods' final destination, or in another place in Kenya as specified in the SCC. Subject to GCC Sub-Clause 26.3, if conducted on the premises of the Supplier or its Subcontractor, all reasonable facilities and assistance, including access to drawings and production data, shall be furnished to the inspectors at no charge to the Procuring Entity.
26.3 The Procuring Entity or its designated representative shall be entitled to attend the tests and/or inspections referred to in GCC Sub-Clause 26.2, provided that the Procuring Entity bear all of its own costs and expenses incurred in connection with such attendance including, but not limited to, all travelling and board and lodging expenses.
26.4 Whenever the Supplier is ready to carry out any such test and inspection, it shall give a reasonable advance notice, including the place and time, to the Procuring Entity. The Supplier shall obtain from any relevant third party or manufacturer any necessary permission or consent to enable the Procuring Entity or its designated representative to attend the test and/or inspection.
26.5 The Procuring Entity may require the Supplier to carry out any test and/or inspection not required by the Contract but deemed necessary to verify that the characteristics and performance of the Goods comply with the technical specifications codes and standards under the Contract, provided that the Supplier's reasonable costs and expenses incurred in the carrying out of such test and/or inspection shall be added to the Contract Price. Further, if such test and/or inspection impedes the progress of manufacturing and/or the Supplier's performance of its other obligations under the Contract, due allowance will be made in respect of the Delivery Dates and Completion Dates and the other obligations so affected.
26.6 The Supplier shall provide the Procuring Entity with a report of the results of any such test and/or inspection.
26.7 The Procuring Entity may reject any Goods or any part thereof that fail to pass any test and/or inspection or do not conform to the specifications. The Supplier shall either rectify or replace such rejected Goods or parts thereof or make alterations necessary to meet the specifications at no cost to the Procuring Entity, and shall repeat the test and/or inspection, at no cost to the Procuring Entity, upon giving a notice pursuant to GCC Sub- Clause 26.4.
26.8 The Supplier agrees that neither the execution of a test and/or inspection of the Goods or any part thereof, nor the attendance by the Procuring Entity or its representative, nor the issue of any report pursuant to GCC Sub-Clause 26.6, shall release the Supplier from any warranties or other obligations under the Contract.
Independent Analysis Each Party hereby confirms that its decision to execute this Agreement has been based upon its independent assessment of documents and information available to it, as it has deemed appropriate.
Sampling The Licensee agrees that the Composition is purchased as a “Work Made for Hire” whereby the clearing of any sampled materials is the responsibility of Licensee.
Escrow Analysis If applicable, with respect to each Mortgage Loan, the Seller has within the last twelve months (unless such Mortgage was originated within such twelve month period) analyzed the required Escrow Payments for each Mortgage and adjusted the amount of such payments so that, assuming all required payments are timely made, any deficiency will be eliminated on or before the first anniversary of such analysis, or any overage will be refunded to the Mortgagor, in accordance with RESPA and any other applicable law;
Inspection/Testing In order to assess Supplier’s work quality and/or compliance with this Order, upon reasonable notice by Buyer: (a) all goods, materials and services related to the items purchased hereunder, including, raw materials, components, assemblies, work in process, tools and end products shall be subject to inspection and testing by Buyer, its customer, representative or regulatory authorities at all places, including sites where the goods are made or located or the services are performed, whether at Supplier’s premises or elsewhere; and (b) all of Supplier’s facilities, books and records relating to this Order shall be subject to inspection by Buyer or its designee. If specific Buyer and/or Buyer’s customer tests, inspection and/or witness points are included in this Order, the goods shall not be shipped without an inspector’s release or a written waiver of test/inspection/witness with respect to each such point; however, Buyer shall not be permitted to unreasonably delay shipment; and Supplier shall notify Buyer in writing at least twenty (20) days prior to each of Supplier’s scheduled final and, if applicable, intermediate test/inspection/witness points. Supplier agrees to cooperate with such/audit inspection including, completing and returning questionnaires and making available its knowledgeable representatives. Buyer’s failure to inspect or test goods, materials or services or Buyer’s failure to reject or detect defects by inspection or testing shall not relieve Supplier from its warranty obligations or any of its other obligations or responsibilities under this Order. Supplier agrees to provide small business as well as minority and/or women owned business utilization and demographic data upon request.
Inspection and Testing Each Constructing Entity shall cause inspection and testing of the Interconnection Facilities that it constructs in accordance with the provisions of this section. The Construction Parties acknowledge and agree that inspection and testing of facilities may be undertaken as facilities are completed and need not await completion of all of the facilities that a Constructing Entity is building.
Tests 7.7.1 If the Contract Documents, laws, ordinances, rules, regulations or orders of any public authority having jurisdiction require any portion of the Work to be inspected, tested or approved, the Contractor shall give the Architect timely notice of its readiness so the Architect may observe such inspection, testing or approval. The Contractor shall bear all costs of such inspections, tests or approvals conducted by public authorities.
7.7.2 If the Architect determines that any Work requires special inspection, testing, or approval which Subparagraph 7.7.1 does not include, he or she will, upon written authorization from the State, instruct the Contractor to order such special inspection, testing or approval, and the Contractor shall give notice as provided in Subparagraph 7.7.1. If such special inspection or testing reveals a failure of the Work to comply with the requirements of the Contract Documents, the Contractor shall bear all costs thereof, including compensation for the Architect's additional services made necessary by such failure; otherwise the State shall bear such costs, and an appropriate Change Order shall be issued.
7.7.3 Required certificates of inspection, testing or approval shall be secured by the Contractor and promptly delivered by him to the Architect.
7.7.4 If the Architect is to observe inspections, tests or approvals required by the Contract Documents, he will do so promptly.
