Issue of a Completion Sample Clauses
Issue of a Completion. Certificate by the Corporation shall not relieve the Contractor of any of its obligations and/or liabilities under the Contract.
Extension of time for completion (i) Without prejudice to any other provision of this Agreement for and in respect of extension of time, the Contractor shall be entitled to extension of time in the Project Completion Schedule (the “Time Extension”) to the extent that completion of any Project Milestone is or will be delayed by any of the following, namely: (a) delay in providing the Right of Way of Construction Zone, environmental clearances or approval of railway authorities, specified in Clause 3.1 (iv); (b) Change of Scope (unless an adjustment to the Scheduled Completion Date has been agreed under Article 13); (c) occurrence of a Force Majeure Event; (d) any delay, impediment or prevention caused by or attributable to the Authority, the Authority's personnel or the Authority's other contractors on the Site; and (e) any other cause or delay which entitles the Contractor to Time Extension in accordance with the provisions of this Agreement. (ii) The Contractor shall, no later than 15 (fifteen) business days from the occurrence of an event or circumstance specified in Clause 10.5 (i), inform the Authority’s Engineer by notice in writing, with a copy to the Authority, stating in reasonable detail with supporting particulars, the event or circumstances giving rise to the claim for Time Extension in accordance with the provisions of this Agreement. Provided that the period of 15 (fifteen) business days shall be calculated from the date on which the Contractor became aware, or should have become aware, of the occurrence of such an event or circumstance. Provided further that notwithstanding anything to the contrary contained in this Agreement, Time Extension shall be due and applicable only for the Works which are affected by the aforesaid events or circumstances and shall not in any manner affect the Project Completion Schedule for and in respect of the Works which are not affected hereunder. (iii) On the failure of the Contractor to issue to the Authority’s Engineer a notice in accordance with the provisions of Clause 10.5 (ii) within the time specified therein, the Contractor shall not be entitled to any Time Extension and shall forfeit its right for any such claims in future. For the avoidance of doubt, in the event of failure of the Contractor to issue notice as specified in this clause 10.5 (iii), the Authority shall be discharged from all liability in connection with the claim. (iv) The Authority’s Engineer shall, on receipt of the claim in accordance with the provisions of Clause 10.5 (ii), examine the claim expeditiously within the time frame specified herein. In the event the Authority’s Engineer requires any clarifications to examine the claim, the Authority’s Engineer shall seek the same within 15 (fifteen) days from the date of receiving the claim. The Contractor shall, on receipt of the communication of the Authority’s Engineer requesting for clarification, furnish the same to the Authority’s Engineer within 10 (ten) days thereof. The Authority’s Engineer shall, within a period of 30 (thirty) days from the date of receipt of such clarifications, forward in writing to the Contractor its determination of Time Extension. Provided that when determining each extension of time under this Clause 10.5, the Authority’s Engineer shall review previous determinations and may increase, but shall not decrease, the total Time Extension. (v) If the event or circumstance giving rise to the notice has a continuing effect: (a) a fully detailed claim shall be considered as interim; (b) the Contractor shall, no later than 10 (ten) days after the close of each month, send further interim claims specifying the accumulated delay, the extension of time claimed, and such further particulars as the Authority’s Engineer may reasonably require; and (c) the Contractor shall send a final claim within 30 (thirty) days after the effect of the event or the circumstance ceases. Upon receipt of the claim hereunder, the Authority’s Engineer shall examine the same in accordance with the provisions of Clause 10.5 (iv) within a period of 30 (thirty) days of the receipt thereof
Date of Completion The Developer must ensure that the Developer’s Works reach Completion on or before the date or milestone referred to in clause 1 of Schedule 3 of this document.
TIME OF COMPLETION The Owner shall issue a Notice to Proceed identifying the date for commencement of the Work. The commencement date shall be 10 or more days after the date the notice is issued. The Contractor shall achieve substantial completion of the Work within _____________________ (____) calendar days after the commencement date, as such completion date may be extended by approved Change Orders. The time set forth for completion of the Work is an essential element of the Contract.
Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:
Time for Completion The Contractor shall deliver the material and/or services called for in the specifications/proposal and within the delivery time specified and in accordance with the terms of the contract. Work shall be completed within 30 days from the Notice to Proceed issued by the City of Sparks Purchasing Division. The Contractor shall not alter or vary any terms or conditions contained or incorporated herein, including but not limited to, the quantity, price, delivery date or date designated as After Receipt of Order (ARO) or date for commencement or completion of services as mutually agreed upon, unless such alteration or variation is consented to in writing by a duly authorized representative of the City. The City reserves the right to cancel resultant Contract upon ten days written notice in the event the type and quality of the product or work performance is unsatisfactory or in default, subject to Contractor’s right to cure as outlined in termination clause. This is a non-exclusive Contract and the City reserves the right to acquire the material and/or services at its discretion, from other sources during the term of this Contract.
Final Completion The full and final completion of all Work in accordance with the Contract Documents.
Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.
Sale : Completion On Or Before The Completion Date a. Within ninety (90) days from the date of successful sale (the expiry date of which period referred to as “the Completion Date”), the Purchaser shall deposit with the Assignee’s Solicitors simultaneously:- (i) The balance of the purchase price i.e a sum equivalent to 90% of the successful bid price (referred to as “the Balance Sum”) either by way of IBG or XXXXXX or bank draft or cashier’s order crossed “A/C PAYEE ONLY” made payable to HONG XXXXX BANK BERHAD. The amount of the bank draft or cashier’s order shall include outstation clearing charges which shall be borne by the Purchaser, failing which the deficiency shall be recoverable from the Purchaser; and (ii) A copy of the requisite consents or confirmations (as the case may be) of the Developer and/or Proprietor and/or State Authorities and/or relevant bodies approving the sale (including transfer or assignment) in favour of the Purchaser, if necessary and/or required, subject firstly to the Assignee being satisfied with the conditions if imposed, otherwise the Assignee may elect to terminate the sale under Xxxxxx 11. - Extension b. The Completion Date will not be extended unless the Purchaser shall have at least fourteen (14) days before the Completion Date applied in writing for an extension of time to the Assignee and the Assignee may at its absolute discretion without assigning any reason whatsoever either:- (i) Reject such request in which event all monies paid by the Purchaser hitherto including the Deposit shall be forfeited absolutely and immediately for which the Purchaser shall not be entitled to nor have any or further reimbursements, claims and demands whatsoever in nature and howsoever caused against the Assignee, the Assignee’s Solicitors, the Auctioneer or their respective servants or agents and any other party on account thereof; or (ii) Agree to grant an extension of time subject to conditions imposed by the Assignee including but not limited to the imposition of non- refundable late payment charges / compensation charges on the balance unpaid or outstanding purchase price at such rate as the Assignee shall determine and to be calculated on a daily basis for the whole duration of the extended period granted and also to pay such sum within the time and in the manner as stipulated by the Assignee. Such decision by the Assignee shall be binding on the Purchaser. - Charges c. Notwithstanding any contrary terms and conditions which may be imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto on the Assignee in granting the consent or confirmation (as the case may be) to the sale herein, it is hereby agreed that only arrears of quit rent, assessment rate and service charges (collectively referred to as “the Outstanding Charges”) within a period of six (6) years prior to the date of successful sale of the Property which are lawfully and rightfully due and payable to the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto up to the date of successful sale of the Property shall be deducted from the purchase price upon receipt of the Balance Sum PROVIDED THAT the Assignee reserves the right to refuse to pay nor shall the Assignee be obliged to pay:- (i) Any Outstanding Charges that are time-barred i.e. charges which have remained unpaid for more than six (6) years prior to the date of successful sale of the Property irrespective of any payment or acknowledgement or judgment made or obtained on the said charges; (ii) Any Outstanding Charges that are excessively charged resulted from eg duplicate or double counting, wrong calculation or any other similar circumstances; (iii) Any Outstanding Charges wrongfully imposed including but not limited to being charged without any basis whatsoever; and/or (iv) Any bills issued by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto for the Outstanding Charges but only received by the Assignee or the Assignee’s Solicitors more than seventy-five (75) days from the date of the successful sale. Such decision by Assignee on what is due and payable shall be binding on the Purchaser of which the Purchaser hereby expressly agrees. d. The Outstanding Charges due and payable immediately after the date of successful sale of the Property shall be solely borne and paid by the Purchaser. e. Where applicable, it shall be the duty of the Purchaser to obtain at the Purchaser’s own costs the particulars as stated in Section 22D(4) of the Housing Development (Control and Licensing) Act 1966 and to obtain copies of the charges payable from the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto and to forward copies thereof together with the calculations as to the apportionment of the respective parties’ liability thereof to the Assignee’s Solicitors for the Assignee’s approval. For this purpose, the Purchaser shall also furnish the Assignee’s Solicitors with the Purchaser’s account details in order for the Assignee to process payment of the Assignee’s portion of the Outstanding Charges pursuant to and in accordance with Clause 8(c) above. f. In the event the Purchaser shall pay such arrears (if any) of the Outstanding Charges in advance to the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto:- (i) The Purchaser is not entitled to deduct the payment towards the arrears (if any) from the Balance Sum; (ii) Due apportionment and reimbursement for the payment (if any) made by the Purchaser towards the arrears shall only be made after the Assignee has received the Balance Sum and subject to the Assignee’s approval and other provisions of these Conditions of Sale. For this purpose, the Purchaser shall produce receipts evidencing payment together with the Purchaser’s account details in order for the Assignee to reimburse the Purchaser in accordance with this Clause 8(f)(ii) accordingly. g. Nothing herein shall impose any obligation on the part of the Assignee to pay any outstanding water, electricity, telephone, utilities, gas, sewerage, taxes, rates, bills, any type of interest, fine, penalty, losses incurred by reason of any breach of written laws, late payment charges, damages, compensation, other form of maintenance or management charges (including but not limited to security charges, charges incurred in relation to car park / accessory parcel, deposits, sinking / building / common / maintenance / management fund), costs for renovation / alteration / additional works, contribution, subscription, licence, dues, levies, insurance, premium, rents, commission, fees, costs and expenses (including but not limited to legal fees, disbursements, stamp duty, registration fees, administrative or vetting fees and transfer costs), other outgoings and charges in any form whatsoever (including for any increase in area of the Property imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto irrespective of whether the same was imposed or incurred before the date of successful auction, any penalty thereof in connection with incidental to or pursuant to the Assignment the Memorandum of Transfer and all other documents necessary for affecting the transfer or subsequent transfer [as the case may be] or assigning the beneficial ownership of the Property to the Purchaser or that as may be due to or imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto notwithstanding that the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto may require such payments to be made by the Assignee). The Purchaser hereby expressly agrees that such costs and expenses shall be solely borne and paid by the Purchaser. h. Any other costs, expenses and charges not specifically mentioned and/or specified in Clause 8.c, Clause 8.d, Clause 8.e, Clause 8.f and Clause 8.g hereof which are outstanding shall be solely borne and paid by the Purchaser. i. Upon payment of all monies mentioned and/or specified in Clause 6.d, Clause 7.a, Clause 8.a(i), Clause 8.c, Clause 8.d, Clause 8.e, Clause 8.f, Clause 8.g and Clause 8.h above and subject to the fulfillment of Clause 9 below by the Purchaser, the Assignee shall:- (i) Execute or cause to be executed as soon as possible at the Purchaser’s own costs and expenses (including legal fees, stamp duty and registration fees) an Assignment (in the form and substance acceptable to and upon the terms and conditions stipulated by the Assignee at its absolute discretion) in favour of the Purchaser of all the rights title interests and benefits under the Sale and Purchase Agreement entered into between the Developer and/or Proprietor of the Property and the Assignor or the original purchaser(s) when the Assignor is not the original purchaser of the Property. Where applicable, the Assignee shall be entitled to have a sufficient covenant of indemnity inserted in the Assignment in order for the Purchaser to assume all liabilities and obligations pertaining to the Property. The Assignee shall not be required to assign the Property to any person other than the Purchaser; and (ii) Deliver to the Purchaser or the Purchaser’s Solicitors the duly executed Assignment and certified true copy(ies) of the Sale and Purchase Agreement and previous Assignment within the Assignee’s custody. If any of the aforesaid documents is not available, the Assignee shall use its best endeavors to provide certified true copy(ies) or such other acceptable documentary evidence of previous transactions thereof. j. Where applicable, the Purchaser undertakes to forward to the Developer the duly stamped Assignment, the duly stamped Proclamation of Sale and the Memorandum together with the full payment of all sums and outgoings due to the Developer under the Sale and Purchase Agreement as required by Section 22D(2) of the Housing Development (Control and Licensing) Act 1966 within fourteen (14) days from the date of stamping of the Assignment and to forward a copy of the cover letter or acknowledgment of receipt by the Developer to the Assignee or the Assignee’s Solicitors within seven (7) days after the issuance of the cover letter or acknowledgment of receipt. - Charge / Transfer k. If the separate document of title or strata title for the Property has been issued whether before on or after the date of auction sale, the Assignee shall not be required to procure a Memorandum of Transfer nor to register its charge as prescribed by the National Land Code 1965 or Sarawak Land Code or the Land Ordinance Cap. 68 of the Laws of Sabah (where applicable) in favour of the Purchaser from the Developer and/or Proprietor (as the case may be). l. The transfer of the Property from the Developer and/or Proprietor (as the case may be) shall be prepared and procured by the Purchaser at the Purchaser’s own costs (including costs of transfer from the Developer and/or Proprietor to the Assignor where necessary) and expenses who undertakes to pay such sums and comply with the conditions (if any) imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies pertaining to the registration of such transfer of the Property. m. The Purchaser undertakes to inform the local authority of the change of ownership and to file the necessary form within fourteen (14) days from the date of stamping of the Assignment.
DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be: § 3.2 The Contract Time shall be measured from the date of commencement of the Work.
Value of Completed Work If the Engineer defaults in the performance of this contract or if the State terminates this contract for fault on the part of the Engineer, the State will give consideration to the following when calculating the value of the completed work: (1) the actual costs incurred (not to exceed the rates set forth in Attachment E, Fee Schedule) by the Engineer in performing the work to the date of default; (2) the amount of work required which was satisfactorily completed to date of default; (3) the value of the work which is usable to the State; (4) the cost to the State of employing another firm to complete the required work; (5) the time required to employ another firm to complete the work; and (6) other factors which affect the value to the State of the work performed.