Liability towards the Contracting Authority Sample Clauses

Liability towards the Contracting Authority. The Parties undertake to bear liability for all Services that they have provided regarding Project’s implementation and in particular: To compliance of the Services with the specifications given in the Main Contract and its appendices; To compliance with the performance times in relation with the various calendars and schedules provided by the Main Contract and its appendices. The financial consequences of any breach by the Parties of their contractual obligations shall be distributed using the following methods: In the event of a breach which is clearly attributable to a single Party all consequences shall be borne by the Party in breach; In the event of a breach which is not attributable to a single Party the various liabilities shall be determined in meetings of the Consortium, for the purposes of equitable distribution of the prejudicial consequences between the Parties in question based on their share of the working days; If an amicable agreement cannot be reached a provisional distribution shall be made in the meetings of the Consortium, between all Parties, in proportion to their respective shares of the Contract, except for any which are able to demonstrate that it is impossible that their participation may have contributed to the loss. Each Party also undertakes to bear liability for any penalties applied by the Contracting Authority in the event of late performance of their obligations. These penalties shall be borne by the Parties in accordance with the above-mentioned distribution methods for the liabilities. On a preventative basis the Parties shall inform the Lead Partner of any foreseeable delays in performing their tasks, in order that any measures which may compensate for the expected delays may be taken without delay, or that measures may be implemented to prevent penalties being applied.
Sample 1
AutoNDA by SimpleDocs

Related to Liability towards the Contracting Authority

  • The Contracting Authority shall designate a Project Manager for the Project. The Project Manager is authorized to act on behalf of the Contracting Authority to perform specific responsibilities under the Agreement.

  • Contracting authority The contracting authority of this public contract is Enabel, the Belgian development agency, public-law company with social purposes, with its registered office at Xxx Xxxxx 000, 0000 Xxxxxxxx xx Xxxxxxx (enterprise number 0264.814.354, RPM/RPR Brussels). Enabel has the exclusive competence for the execution, in Belgium and abroad, of public service tasks of direct bilateral cooperation with partner countries. Moreover, it may also perform other development cooperation tasks at the request of public interest organisations, and it can develop its own activities to contribute towards realisation of its objectives. For this procurement contract, Xxxxxx is represented by person(s) who shall sign the award letter and are mandated to represent the organisation towards third parties.

  • Where one Contracting Party or its designated agency has guaranteed any indemnity against non-commercial risks in respect of an investment by any of its investors in the territory of the other Contracting Party and has made payment to such investors in respect of their claims under this Agreement, the other Contracting Party agrees that the first Contracting Party or its designated agency is entitled by virtue of subrogation to exercise the rights and assert the claims of those investors. The subrogated rights or claims shall not exceed the original rights or claims of such investors.

  • Where a Contracting Party expropriates the assets of a company which is incorporated or constituted under the law in force in any part of its own territory, and in which investors of the other Contracting Party own shares, it shall ensure that the provisions of this Article are applied so as to guarantee prompt, adequate and effective compensation in respect of their investment to such investors of the other Contracting Party who are owners of those shares.

  • Representative's Authority to Contract By signing this contract, the representative of the contractor thereby represents that such person is duly authorized by the contractor to execute this contract on behalf of the contractor and that the contractor agrees to be bound by the provisions thereof.

  • Authority to Bind Contractor The signatory for the Contractor represents that he/she has been duly authorized to execute this Contract on behalf of the Contractor and has obtained all necessary or applicable approvals to make this Contract fully binding upon the Contractor when his/her signature is affixed, and accepted by the State.

  • Technical or Contractual Problems Contractor shall meet with the Department's personnel, or designated representatives, to resolve technical or contractual problems occurring during the contract term or to discuss the progress made by Contractor and the Department in the performance of their respective obligations, at no additional cost to the Department. The Department may request the meetings as problems arise and will be coordinated by the Department. The Department shall provide Contractor a minimum of three full working days notice of meeting date, time, and location. Face-to-face meetings are desired; however, at Contractor's option and expense, a conference call meeting may be substituted. Contractor’s consistent failure to participate in problem resolution meetings, Contractor missing or rescheduling two consecutive meetings, or Contractor’s failure to make a good faith effort to resolve problems may result in termination of the contract.

  • Balancing Authority Area Notification At least three months before Initial Synchronization Date, the Interconnection Customer shall notify the CAISO and Participating TO in writing of the Balancing Authority Area in which the Large Generating Facility intends to be located. If the Interconnection Customer intends to locate the Large Generating Facility in a Balancing Authority Area other than the Balancing Authority Area within whose electrically metered boundaries the Large Generating Facility is located, and if permitted to do so by the relevant transmission tariffs, all necessary arrangements, including but not limited to those set forth in Article 7 and Article 8 of this LGIA, and remote Balancing Authority Area generator interchange agreements, if applicable, and the appropriate measures under such agreements, shall be executed and implemented prior to the placement of the Large Generating Facility in the other Balancing Authority Area.

  • SCOPE OF THE CONTRACT 4.1 The Contractor shall perform the Services set out [in Schedule 1] [below2] in accordance with the Contract.

  • PARTIES TO THE CONTRACT This Contract is solely between the Company and the SBA which administers the FHCF. In no instance shall any insured of the Company or any claimant against an insured of the Company, or any other third party, have any rights under this Contract, except as provided in Article XIV. The SBA will only disburse funds to the Company, except as provided for in Article XIV of this Contract. The Company shall not, without the prior approval of the Office of Insurance Regulation, sell, assign, or transfer to any third party, in return for a fee or other consideration any sums the FHCF pays under this Contract or the right to receive such sums.

Time is Money Join Law Insider Premium to draft better contracts faster.