Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
ROAD WORK PHASE APPROVAL Purchaser shall obtain written approval from the Contract Administrator upon completion of each of the following phases of road work: Drainage installation Subgrade compaction Rock compaction SUBSECTION RESTRICTIONS
FAA APPROVAL This Agreement may be subject to approval of the FAA. If the FAA disapproves this Agreement, it will become null and void, and both Parties will bear their own expenses relative to this Agreement, up to the date of disapproval.
Regulatory Approval 25.1 The Parties understand and agree that this Agreement and any amendment or modification hereto will be filed with the Commission for approval in accordance with Section 252 of the Act and may thereafter be filed with the FCC. The Parties believe in good faith and agree that the services to be provided under this Agreement are in the public interest. Each Party covenants and agrees to fully support approval of this Agreement by the Commission or the FCC under Section 252 of the Act without modification.
AGREEMENT APPROVAL This agreement constitutes the entire agreement between the parties and supersedes any previously executed agreements, representations, verbal or written, to buy and/or sell the property. Neither this agreement, nor any interest herein, shall be transferred or assigned by Buyer without the prior written consent of Seller.
Project Approval The County may issue a Job Order Authorization for the Work, to include the firm-fixed-price of the Job Order and the project duration. Contractor agrees that all clauses of this Contract are applicable to any Job Order issued hereunder. The County reserves the right to reject a Contractor’s Quote based on unjustifiable quantities and/or methods, performance periods, inadequate documentation, or other inconsistencies or deficiencies on the Contractor’s part in the sole opinion of the County. The County reserves the right to issue a unilateral Job Order authorization for the Work if a Quote price cannot be mutually agreed upon. This is based upon unjustifiable quantities in the sole opinion of the County. The County also reserves the right to not issue a Job Order Authorization if the County’s requirement is no longer valid or the project is not funded. In these instances, the Contractor has no right of claim to recover Quote expenses. The County may pursue continuing valid requirements by other means where Contract was not reached with the Contractor.
Regulatory Approvals All Requisite Regulatory Approvals shall have been obtained and shall remain in full force and effect and all statutory waiting periods in respect thereof shall have expired, and no such Requisite Regulatory Approval shall have resulted in the imposition of any Materially Burdensome Regulatory Condition.
Final Approval Hearing “Final Approval Hearing” shall mean the hearing at which the Court will consider and finally decide whether to enter the Final Judgment.
Approval Procedure 1. To request approval to receive shared leave hours, an employee or their representative must submit the following documentation to Human Resource Services:
CONTRACT APPROVAL All Membership Contracts are subject to final approval by Crunch Management. Crunch reserves the right to refuse this contract for any reason at our sole discretion.
